SlideShare a Scribd company logo
1 of 10
Download to read offline
© 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 339
Risks in Public and Private Partnership Projects –Identification and
Prioritization
Hafeez Ali1, Asha Jose2
1Student: Department of Civil Engineering Indira Gandhi Institute of Engineering and Technology
Kothamangalam, Eranakulam-686691
2Assistant Professor: Department of Civil Engineering Indira Gandhi Institute of Engineering and Technology
Kothamangalam, Eranakulam-686691
---------------------------------------------------------------------***---------------------------------------------------------------------
ABSTRACT
Infrastructure is an important sector which contributes to the growth of overall development of the nation. Recently, Public
Private Partnerships (PPP) has become the key factor to facilitate this development. Due to long concession periods and large
investments, the risk management plays a crucial role in these types of projects.
This thesis deals with the risk quantification and risk allocation of PPP projects using a fuzzy based questionnaire survey. Fuzzy
logic can express and handle vague or imprecise judgments mathematically and therefore can effectively deal with errors due
to human subjectivity. 20 risk factors in PPP projects are summarized from a comprehensive literature review.
Interdependencies among the main risk factors affecting PPP projects are assessed using fuzzy Decision-Making Trial and
Evaluation Laboratory (DEMATEL) approach. Sub risk factors are prioritized using a fuzzy hybrid method involving fuzzy
Failure Mode and Effect Analysis (FMEA) and fuzzy Analytic Hierarchy Process (AHP) method. The obtained results have shown
that approvals and permits, construction cost overrun, construction time overrun and land acquisition risks are the key risks
affecting PPP projects.
Key Words: Public Private Partnership Projects; Risk Management; Fuzzy Logic; Failure Mode and Effect Analysis;
Decision Making Trial and Evaluation Laboratory; Analytic Network Process.
1. INTRODUCTION
PPP is contractual partnership between the public and private sector agencies, specifically targeted towards financing,
designing, implementing and operating infrastructure facilities and services. Moreover, PPP contributes to better quality and
performance of infrastructure projects. Though PPP projects provide a good return in investment, risk involved in such
projects is very significant. The risks need to be thoroughly analyzed, researched and managed to minimize disputes and
costs and maximize the value for money. Risk management involves risk planning, risk identification, qualitative risk
analysis, quantitative risk analysis, risk response planning, risk monitoring and control. Quantitative analysis of risks in
PPP projects provides a very clear picture on the most prominent risk groups. This study uses a fuzzy based risk assessment
approach to quantify risks occurring in PPP projects. A questionnaire survey was conducted among professionals working in
PPP projects and responses of 24 experts are used for the analysis.
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072
When making decisions in a fuzzy environment, the result of decision-making is highly affected by subjective judgments
that are vague and imprecise. To solve this kind of imprecision problem, fuzzy set theory was first introduced by L. A.
Zadeh (1965) as a mathematical way to represent and handle vagueness in decision-making. The concepts of fuzzy set
theory are essential to accounting for the uncertainty and fuzziness of realistic environments. Research subjects are
allocated a value between 0 and 1 to indicate their fuzzy degree. People’s subjective judgments are convertedinto numbers
In particular, to tackle the ambiguities involved in the process of linguistic estimation, it is a beneficial way to convert these
linguistic terms into fuzzy numbers. A linguistic variable is a variable whose values have the form of phrases or sentences
in a natural language. Especially, linguistic variables are used as variables whose values are not numbers but linguistic
terms. The linguistic term approach is a convenient way for decision makers to express their assessments. For dealing
with the ambiguities of human assessments, the linguistic variable ‘‘influence’’ is used with different linguistic terms like very
high, high, low etc. each of which are expressed in fuzzy numbers. A fuzzy hybrid method involving fuzzy Failure Mode and
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072
© 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 340
Questionnaire survey based on fuzzy DEMATEL
process to determine the interdependencies
between the main risk factors
Questionnaire survey based on fuzzy FMEA and
fuzzy AHP methods to rank the sub risks
Validation of the results
Develop a risk breakdown structure
Identify risk factors in PPP projects through
literature survey
Effect Analysis (FMEA), fuzzy Decision-Making Trial and Evaluation Laboratory (DEMATEL) and fuzzy Analytic Hierarchy
Process (AHP) is employed for the purpose.
DEMATEL, originally developed by the Science and Human Affairs Program of the Battelle Memorial Institute of Geneva
between 1972 and 1976, is used for researching and solving the complicated and intertwined problem group. DEMATEL
method allows to explore interrelationships between factors and to develop a cause effect diagram. The main advantage of
fuzzy integrated DEMATEL is to consider fuzziness involved in human decision making. Fuzzy DEMATEL is used in this study to
find the interdependencies between the main risk groups such as financial risks, legal risks, political risks etc.
AHP is a widely used multi-criteria decision-making tool originally developed by Prof. Thomas L. Saaty. AHP uses pair-wise
comparisons which allow verbal judgments and enhances the precision of the results. It is suitable to use fuzzy AHP to assess
the risks of PPP projects, which will encounter many uncertainties during the long concession contract period and have
multiple objectives originating from project stakeholders (Li and Zou, 2011).
Failure Mode and Effect Analysis (FMEA) is a tool for identifying potential modes of failure in asystem, evaluating the main
causes, determining the impact of failures and formulating preventive measures (Mohammadi and Tavakolan, 2013). In this
system, a Risk Priority Number(RPN) for each risk is calculated as the product of the probability of risk occurrence (O),
severity (S) and detection (D). In traditional FMEA, the relative importance ofO, S and D is not taken into account and RPN value
may not truly represent the actual scenario. Fuzzy FMEA is used to overcome these drawbacks. Results of both fuzzy FMEA and
fuzzy AHP technique are taken to rank the risk factors.
2. REASEARCH METHODOLOGY
The research methodology adopted is demonstrated in Fig. 1 and is based on a comprehensive literature review, and
comprehensive questionnaire survey for data collection.
Fig.-1: Research Methodology
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072
© 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 341
Force
Majeure
Natural
Mainte -
nance risks
Operation cost
overruns
Operation
Govern -
ment’s
reliability
Land acquisi
-tion risks
Interest rate
volatility
Inflation rate
volatility
Contractu -al
risks
Change in tax
regulation
Change in
law
Approvals &
permits Change in
market demand
Constru-
ction
Economic
Political
Revenue risks
Concess-
ionaire
event of
default
Availab-
ility of
finance
Legal
Financial
Technology risk
External linkages
Design Changes
Construction
cost overrun
Constru-
ction time
delay
Risk factors
3. RISK IDENTIFICATION AND RISK BREAKDOWN STRUCTURE
The main risk factors and sub risk factors under each main risk in PPP projects identified were through literature survey
Those factors that have been repeatedly identifiedin the literature as critical were only taken up for further analysis. 5 projects
are taken to correlate the results of the literature review with the actual scenario in India. The projects were taken from
Public Private Partnership Projects in India: Compendium of Case Studies. The case studies provided a representation
across various locations and various types of PPP projects. The risk breakdownstructure formed is given in Fig.2.
Fig.- 2: Risk Breakdown Structure
4. ANALYSIS OF MAIN RISK FACTORS
DEMATEL is applied to determine effect and cause criteria, and to obtain the model in terms of linguistics parameterized
with fuzzy numbers. Fuzzy DEMATEL method can be applied to problems that require group decision-making in a fuzzy
environment. The procedure for fuzzy DEMATEL analysis to find the cause and effectrelationship between the main factors
is given below (Tzeng et al., 2007 and Luthra et al., 2016).
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072
© 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 342
Step 1: Respondents are asked to indicate the direct influence that they believe each main risk factor exerts on each of the
others according to an integer scale ranging 0 - 4 and then the responses are entered into a matrix asfuzzy numbers.
Step 2: Defuzzify the TFNs in the matrices into crisp scores (center of area method) to obtain defuzzified DEMATEL
response matrix.
Step 3: Compute the average matrix,X from all 24 responses Each element of this average matrix will be in this case the
mean of the same elements in the different defuzzified response matrices of the respondents.
Step 4: Calculate the initial direct relation matrix. The initial direct relation matrix, N can be obtained by normalizing the
average matrix X. The initial influence which an element exerts and receives from another canbe read from matrix N.
Matrix N portrays the interrelationships among the elements.
Step 5: Calculate the direct/indirect relation matrix T, which is also called the total relation matrix. A continuous decrease
of the indirect effects of problems along the powers of the matrix N (N2, N3, . . . , N∞) guarantees convergent solutions to
matrix inversion.
𝑇 = lim (𝑁 + 𝑁2 + ⋯ + 𝑁𝑘) = (1 − 𝑁)−1 (1)
Step 6: Calculate the sum of the values in each column and each row. This step entails summing the values of each column
and row in the total relation matrix, where Di is the sum of the ith row and Rj is the sum of the jth column.
Step 7: Let i=j; Di = D and Ri = R. A causal diagram can be acquired by mapping the dataset of (D + R, D - R), where the
horizontal axis (D + R) is made by adding D to R, and the vertical axis(D - R) is made by subtracting D from R. In this step, (D
+ R) is defined as prominence and (D −R) is defined as relation. ‘‘Prominence’’ shows how important the criterion is, whereas
‘‘Relation’’ may divide the criteria into the cause and effect groups. When the value (D-R) is positive, the criterion belongs to
the cause group. If the value (D-R) is negative, the criterion belongs to the effect group. Prominence and Relation values are
provided in Table 5.7.
Table-1: Prominence and Relation Values
Factors D R ProminenceD+R RelationD-R
Financial Risks 2.356 3.259 5.615 -0.903
Legal Risks 1.879 1.990 3.869 -0.111
Political Risks 3.010 1.646 4.656 1.364
Economic Risks 2.813 1.993 4.806 0.820
Construction Risks 2.139 3.217 5.356 -1.078
Operation Risks 2.053 2.229 4.282 -0.176
Natural Risks 2.357 2.273 4.630 0.084
As we move along the horizontal axis of the cause effect diagram the prominence of the factors increases. From the causal
diagram (Fig 5.2), it can be inferred that financial risks are the most prominent risk group closely followed by construction
risks. The horizontal axis separates the cause group risks and effect group risks. Fig.
5.2 reveals that political risks, economic risks and natural risks are the cause group risks and financial risks, legal risks,
construction risks and operation risks are the effect group risks. The cause group risks trigger the other risks. Political
risks are the major cause group risks and hence political risks should be given due considerationsin the risk management
process. Construction risks and political risks are easily affected by other risks.
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072
© 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 343
SEVERITY
Rating
Fuzzy
Number
Extremely
significant effect
(4, 5, 6)
Very significant
effect
(3, 4, 5)
Significant
effect
(2, 3, 4)
Slight
effect
(1, 2, 3)
No effect (1, 1, 2)
DETECTION
Rating
Fuzzy
Number
Extremely
significant effect
(4, 5, 6)
Very significant
effect
(3, 4, 5)
Significant
effect
(2, 3, 4)
Slight
effect
(1, 2, 3)
No effect (1, 1, 2)
OCCURRENCE
Rating
Fuzzy
Number
Very high (4, 5, 6)
High (3, 4, 5)
Medium (2, 3, 4)
Low (1, 2, 3)
Very low (1, 1, 2)
Political Risks
Chart 1: Cause Effect Diagram
5. ANALYSIS OF SUB RISK FACTORS
Construction Risks
Financial Risks
A fuzzy hybrid method involving Fuzzy FMEA and Fuzzy AHP (FAHP) methods was adopted to prioritize sub riskfactors in
PPP projects. FMEA takes into consideration the severity, frequency of occurrence and likelihood of detection of a particular
risk factor while AHP explores the relative importance of the risk factors. The integration of fuzzy theory will help to reduce
errors due to human subjectivity. The weights obtained by two method, fuzzyFMEA and FAHP, are multiplied to arrive at a
final weight for each risk factor.
5.1 Fuzzy FMEA
In Failure Mode and Effect Analysis (FMEA) a Risk Priority Number(RPN) for each risk is calculated as the product of the
probability of risk occurrence (O), severity (S) and detection (D). The O rating refers to the frequency of the occurrence of a
particular risk factor. The S rating is used to represent the potential effects associated with the occurrence of a risk factor.
D rating considers the likelihood of detection of a particular risk factor. The RPN represents the level of a particular risk, i.e.
a higher value of RPN means higher level of risk FMEA integrated with fuzzy theory allows risk prioritization to be handled
more efficiently.
Table 2: Fuzzy linguistic scale (Nazeri and Naderikia, 2017)
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072
© 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 344
The Fuzzy FMEA procedure employed for the present study is provided below (Nazeri and Naderikia, 2017).
Step 1: A fuzzy linguistic scale is adopted from Nazeri and Naderikia, 2017 and provided in Table-2 is selected, and
respondents are asked to rate O, S and D according to it.
Step 2: The mean responses are found by taking the average of the fuzzy ratings from the 24 respondents.
Step 3: The mean response in TFN form is defuzzified into crisp score by center of area method.
Step 4: The Risk Priority Number (RPN) is found by, RPN = O ⊗ S ⊗ D. The RPN gives the FMEA weights ofeach risk.
Table 3: Sample FRPN Calculation for Risk Factor “Revenue Risks”
Parameter Average response Crisp score FRPN
Occurrence (3.13, 4.04, 5.04) 4.07
FRPN=4.07 ×4. 09 ×3.25= 54.100
Severity (3.09, 4.09, 5.09) 4. 09
Detection (2.40, 3.18, 4.18) 3.25
Similarly, FRPN values for all sub risks are calculated and listed in Table 4.
Table 4: Fuzzy RPN Values
Sub Risk Factors FRPN Sub RiskFactors FRPN
Design changes 78.001 Change in law 36.452
Land acquisition risks 72.560 Force Majeure 32.541
Availability of finance 71.624 Interest ratevolatility 29.108
Construction time delay 69.231 Operation costoverruns 28.462
Approvals and permits 64.142 Technologyrisk 26.144
Revenue risk 54.112 Maintenancerisks 19.313
Contractual risks 53.451 Inflation ratevolatility 19.142
Change in market demands 48.674 Government’s reliability 17.251
Concessionaire event of default 48.213 Change in taxregulation 15.464
Construction cost overruns 39.13 Externallinkages 10.254
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072
© 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 345
The risks are listed in Table 4 according to their priority order from the FMEA results. Design changes, Land acquisition
risks, availability of finance, construction time delay and approvals and permits are the major risk according to the results
obtained from fuzzy FMEA analysis. Change in tax regulation and external linkages are the least important ones. The FRPN
values are multiplied by FAHP weights to obtain the final weights of each sub factor.
5.2 Fuzzy AHP
Developed by T. L. Saaty in 1970, and refined continuously to date, the AHP breaks down the main problem into more
comprehensible sub-problems. The AHP model is a tree diagram, which in its simplest form, consists of a goal at the top, a
set of alternates for reaching the goal at the lowest level, and a set of criteria connecting the alternates to the goal. For the
present study, project success is the goal. The set of risk factors are taken as the set of criteria forming the last level.
If uncertainty (fuzziness) of human decision making is not taken into account in an AHP problem, the results can be
misleading. FAHP overcomes the inability of AHP to deal with human subjectiveness in the pair wise comparison process.
Instead of a single value, the FAHP generates a range of values to incorporate the decision- makers uncertainty.
The steps employed to find the FAHP weights of risk factors are found from the procedure described below (Li and Zou,
2011;Ayhan, 2013).
Step 1: The results of all the pair wise comparisons are entered into a matrix as fuzzy numbers according to a linguistic scale
Step 2: Preferences of each respondent are averaged and is calculated to form a pair wise comparison matrix (which is
average of all 24 responses)
Step 3: The local weights of sub risk factors are found using Eq. 2.
𝑤𝑆𝑅𝑖 𝑛
𝑖=
1
𝑆𝑅
𝑖𝑗
𝑛
𝑗=
1
𝑛
𝑖=
1
𝑆𝑅
𝑖𝑗
(2)
𝐴
𝑆 is the ith row and jth column fuzzy element of updated sub risk pair wise comparison matrix and 𝑤𝑆𝑅 is the
𝑖𝑗 𝑖
local fuzzy weight of sub risk factor in ith row of sub risk comparison matrix
Step 4: The weights of the main risk factors are found by employing Eq. 3.
𝑤𝑀𝑅𝑖 𝑛
𝑖=
1
𝑀𝑅
𝑖𝑗
𝑛
𝑗=
1
𝑛
𝑖=
1
𝑀𝑅
𝑖𝑗
(3)
𝐴
𝑀 is the ith row and jth column fuzzy element of main risk pair wise comparison matrix and 𝑤𝑀𝑅 is the fuzzy
𝑖𝑗 𝑖
weight of main risk factor in ith row of main risk pair wise comparison matrix. The calculations are similar to that of
calculations to find the weights of sub risk factors
Step 5: The global weights of each sub risk factor is found by the following Eq. 4
𝑊SR𝑖 = 𝑆𝑅𝑖 ⊗ 𝑊
𝑀𝑅𝑖 (4)
𝑊
SR𝑖 is the global fuzzy weight of sub risk factor in ith row of sub risk pair wise comparison matrix.
Step 6: 𝑊 𝑆𝑅𝑖 is defuzzified into a crisp score using centre of area method. FAHP weights for the sub risks are provided
in Table 5.
= ∑ 𝐴 ⊗ ∑ ∑ 𝐴
= ∑ 𝐴 ⊗ ∑ ∑ 𝐴
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072
© 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 346
Table-5: FAHP Weights of Sub Risk Factors
Main Risk
Factors
Weights, 𝑾
𝑴𝑹𝒊
Sub Risk
Factors
Local Weights,
𝒘𝑺𝑹𝒊
Global weights,
𝑾𝑺𝑹𝒊
FAHP
Weight Crisp
Score
Financial
Risks
(0.10, 0.23,
0.58)
Availability of
finance
(0.36,0.63, 1.17) (0.04, 0.15, 0.67) 0.286
Revenue risk (0.03, 0.05, 0.09) (0.00, 0.01, 0.05) 0.020
Concessionaire
event of default
(0.12, 0.24, 0.50) (0.01, 0.05, 0.29) 0.116
Legal Risks (0.05, 0.10,
0.27)
Approvals and
permits
(0.33, 1.65, 1.89) (0.01, 0.16, 0.51) 0.226
Land acquisition
risks
(0.68, 0.95, 1.08) (0.05, 0.09, 0.18) 0.106
Contractual risks (0.35, 0.36, 0.58) (0.03, 0.03, 0.16) 0.073
Political
Risks
(0.01,0.02, 0.05)
Government’s
reliability
(0.17 ,0.57 ,0.79) (0.00, 0.01, 0.03) 0.013
Change in law (0.06,0.51,0.83) (0.00, 0.01, 0.04) 0.016
Economic
Risks
(0.20,0.26,0.55)
Change in
marketdemands
(0.09, 0.08, 0.32) (0.01, 0.02, 0.17) 0.067
Change in tax
regulation
(0.24, 0.51, 0.73) (0.02, 0.13, 0.40) 0.183
Inflation rate
volatility
(0.02, 0.05, 0.09) (0.00, 0.01, 0.04) 0.016
Interest rate
volatility
(0.08,0.09, 0.20) (0.02, 0.02, 0.11) 0.050
Construction
Risks
(0.08,0.19,0.44)
Constructiontime
delay
(0.32, 1.56, 1.89) (0.02, 0.29, 0.83) 0.380
Construction
cost overruns
(1.00, 1.82, 1.98) (0.08, 0.32, 0.87) 0.423
Design changes (0.52, 0.75, 0.91) (0.04, 0.14, 0.40) 0.193
External
linkages
(0.09, 0.10, 0.14) (0.00, 0.01, 0.06) 0.030
Technology risk (0.08, 0.09, 1.01) (0.00, 0.01, 0.44) 0.150
Operation
Risks
(0.06,0.14,0.31)
Operation cost
overruns
(1.04, 1.16, 1.87) (0.06, 0.16, 0.57) 0.263
Maintenancerisks (0.34, 0.55, 0.67) (0.02, 0.07, 0.20) 0.096
Natura
lRisks
(0.01, 0.02,
0.06)
Force Majeure (0.16, 1.29, 1.55) (0.00, 0.02, 0.09) 0.036
The final weights of the sub risk factors are calculated as the product of FAHP weights and FRPN values. The results
are provided in Table-6.
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072
© 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 347
Table-6: Ranking of Sub Risk Factors
Sub Risk Factors FRPN FAHP
Weight
Final
Weight
Rank
Approvals and permits 64.142 0.401 25.720 1
Construction time delay 69.231 0.356 24.646 2
Availability of finance 71.624 0.264 18.908 3
Construction cost overruns 39.139 0.468 18.317 4
Land acquisition risks 72.560 0.173 12.552 5
Design changes 78.001 0.153 11.934 6
Concessionaire event of default 48.213 0.189 9.112 7
Change in market demands 48.674 0.096 4.672 8
Operation cost overruns 28.462 0.164 4.667 9
Technology risk 26.144 0.178 4.653 10
Contractual risks 53.451 0.054 2.886 11
Revenue risk 54.112 0.042 2.272 12
Force Majeure 32.541 0.068 2.212 13
Change in tax regulation 15.464 0.113 1.747 14
Interest rate volatility 29.108 0.058 1.688 15
Maintenance risks 19.313 0.069 1.332 16
Change in law 36.452 0.014 0.510 17
Government’s reliability 17.251 0.021 0.362 18
External linkages 10.254 0.022 0.225 19
From the fuzzy AHP and fuzzy FMEA analysis, the top risk factors obtained are approvals and permits, construction time
delay, and availability of finance, construction cost overruns and land acquisition risks. These sub risks should be given top
priority while formulating a risk management strategy. Most of the PPP projects are delayed because of delays in getting
timely approvals and permits. The concessionaire will find it difficult to execute the work within the planned schedule and
this may even result in cost overruns. In most cases, it is not within the concessionaire’s powers to avoid such risks.
However, risks such as construction time delays andcostoverruns can be avoided by proper planning for budget
and cost. Risks due to unavailability offinance occur when there is an absence of a well organized financial framework.
There should be provisions for alternate lenders so that there is a continuous flow of finance as and when required. Delays
in obtaining land have created significant problems and even have lead to the discontinuation of many promising PPP
project proposals. In some cases the government free up land before launching a PPP projects or in othercases the private
sector is responsible for land acquisition. The land owners should be fairly compensated so there is no further resource
consuming legal proceedings.
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072
© 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 348
6. RISKS IN CASE STUDY PROJECTS
Three case study projects in Kerala were considered for the validation of the study. The major risks that occurred in
Thiruvananthapuram City Road Improvement Project, Iruttukanam Small Hydro Electric Project and Thavakkara Bus
Terminal Project are compared with the top ranked risks. The major risks that occurred in the above three projects are
compared with the top risks obtained from the present study. Land acquisition is a majorrisk in all three of the projects while
approvals and permits is a major issue in two of the projects. The rest of the top risks namely availability of finance,
construction time delay and construction cost overrun occurs in at least one of the three projects taken. Thus, the major
risks that occurredin the case studyprojects taken correlates with the results obtained from the present study.
7. CONCLUSIONS
The main objective of this study is to identify the significant risks in PPP projects in Kerala and develop a risk allocation
framework. The risk factors in PPP projects are summarized from a comprehensive literature review. A risk break down
structure is formulated consisting of main risks and sub risks. The main risks are divided into cause and effect group by
using fuzzy DEMATEL analysis. Political risks are found to be the major cause group while financial risks and construction
risks are impacted the most due to other risk factors. In addition, financialrisks are found to be the most prominent risk
group closely followed by construction risks.
The key risks which affect the PPP projects are to be given due importance in order to achieve successful completion of
such projects. A quantitative assessment of the risk will help to identify such key risks. The risks are assessed based on a
fuzzy hybrid approach including fuzzy FMEA and fuzzy AHP approach. The obtained resultsrevealed that the top four risk
factors are approvals and permits, construction time delay, availability of finance, construction cost overrun and land
acquisition risks. The results obtained correlates with risks that occurred in case study projects in Kerala.
In recent years the concept of PPP is gaining much more momentum across the country justbecause it has been able to
provide ample solution to the much needed projects which government cannot do on its own. The research findings
presented in this report can contribute to the development and application of PPP in Kerala and enables better
understanding of the risk allocation in PPP projects.
REFERENCES
[1] Public Private Partnership Projects in India: Compendium of Case Studies, PPP Cell, Departmentof Economic Affairs
New Delhi.
[2] Ayhan M. B., A Fuzzy AHP Approach for Supplier Selection Problem: A Case Study in a Gearmotor Company,
International Journal of Managing Value and Supply Chains, 2013, 4 (3), 11-23.
[3] Li, J. and P. X. W. Zou (2011) Fuzzy AHP-Based Risk Assessment Methodology for PPP Projects, Journal of
Construction Engineering and Management, 137 (12), 1205-1209.
[4] Luthra, S., K. Govindan, R. K. Kharb and S. K. Mangla (2016) Evaluating the Enablers in Solar Power
Developments in the Current Scenario Using Fuzzy DEMATEL: an Indian Perspective, Renewable and Sustainable
Energy Reviews, 63, 379-397.
[5] Mohammadi, A. and M. Tavakolan (2013) Construction Project Risk Assessment Using Combined Fuzzy and
FMEA, IEEE, 232-237.
[6] Nazeri, A. and R. Naderikia (2017) A New Fuzzy Approach to Identify the Critical Risk Factors in Maintenance
Management, Intenational Journal of Advances in Manuf acturing and Technology, 92 (9-12), 3749–3783.
[7] Tzeng, G. H., C. H. Chiang and C. W. Li (2007) Evaluating Intertwined Effects in E- Learning Programs: aNovel
Hybrid, MCDM Model Based on Factor Analysis and DEMATEL, Expert Systems with Applications, 32 (4), 1028-1044.

More Related Content

Similar to Risks in Public and Private Partnership Projects –Identification and Prioritization

IRJET- Review on Developing a Model of Risk Allocation and Risk Handling for ...
IRJET- Review on Developing a Model of Risk Allocation and Risk Handling for ...IRJET- Review on Developing a Model of Risk Allocation and Risk Handling for ...
IRJET- Review on Developing a Model of Risk Allocation and Risk Handling for ...IRJET Journal
 
IRJET- Risk Management in Construction: A Literature Review
IRJET- Risk Management in Construction: A Literature ReviewIRJET- Risk Management in Construction: A Literature Review
IRJET- Risk Management in Construction: A Literature ReviewIRJET Journal
 
AN INTEGRATED PROJECT EVALUATION TOOL FOR PFI SEAPORT PROJECTS
AN INTEGRATED PROJECT EVALUATION TOOL FOR PFI SEAPORT PROJECTSAN INTEGRATED PROJECT EVALUATION TOOL FOR PFI SEAPORT PROJECTS
AN INTEGRATED PROJECT EVALUATION TOOL FOR PFI SEAPORT PROJECTSFredy Kurniawan
 
An Integrated Project Evaluation Tool for PFI Seaport Project
An Integrated Project Evaluation Tool for PFI Seaport ProjectAn Integrated Project Evaluation Tool for PFI Seaport Project
An Integrated Project Evaluation Tool for PFI Seaport ProjectFredy Kurniawan
 
IRJET- Risk Management in Residential Project by Primavera Software
IRJET- Risk Management in Residential Project by Primavera SoftwareIRJET- Risk Management in Residential Project by Primavera Software
IRJET- Risk Management in Residential Project by Primavera SoftwareIRJET Journal
 
Critical Success Factors and Strategies for Sub-contractor Management in Infr...
Critical Success Factors and Strategies for Sub-contractor Management in Infr...Critical Success Factors and Strategies for Sub-contractor Management in Infr...
Critical Success Factors and Strategies for Sub-contractor Management in Infr...IRJET Journal
 
IRJET - Risk Allocation in Public Private Partnership Projects in Kerala
IRJET - Risk Allocation in Public Private Partnership Projects in KeralaIRJET - Risk Allocation in Public Private Partnership Projects in Kerala
IRJET - Risk Allocation in Public Private Partnership Projects in KeralaIRJET Journal
 
IRJET- Analysis of Risk Factors Affecting Management and Maintenance of Urban...
IRJET- Analysis of Risk Factors Affecting Management and Maintenance of Urban...IRJET- Analysis of Risk Factors Affecting Management and Maintenance of Urban...
IRJET- Analysis of Risk Factors Affecting Management and Maintenance of Urban...IRJET Journal
 
IRJET- Study and Analysis of Risk Management Strategies in Construction P...
IRJET-  	  Study and Analysis of Risk Management Strategies in Construction P...IRJET-  	  Study and Analysis of Risk Management Strategies in Construction P...
IRJET- Study and Analysis of Risk Management Strategies in Construction P...IRJET Journal
 
IRJET- Risk Management in the Construction Project: Review
IRJET-  	  Risk Management in the Construction Project: ReviewIRJET-  	  Risk Management in the Construction Project: Review
IRJET- Risk Management in the Construction Project: ReviewIRJET Journal
 
Risk Contingency Evaluation in International Construction Projects (Real Case...
Risk Contingency Evaluation in International Construction Projects (Real Case...Risk Contingency Evaluation in International Construction Projects (Real Case...
Risk Contingency Evaluation in International Construction Projects (Real Case...IJLT EMAS
 
Study and Need of Risk Management for Construction Projects
Study and Need of Risk Management for Construction ProjectsStudy and Need of Risk Management for Construction Projects
Study and Need of Risk Management for Construction ProjectsIRJET Journal
 
IRJET- Developing a Model of Risk Allocation and Risk Handling for Effective ...
IRJET- Developing a Model of Risk Allocation and Risk Handling for Effective ...IRJET- Developing a Model of Risk Allocation and Risk Handling for Effective ...
IRJET- Developing a Model of Risk Allocation and Risk Handling for Effective ...IRJET Journal
 
IRJET - A Study on Identification of Risks at Various Phases of Road Construc...
IRJET - A Study on Identification of Risks at Various Phases of Road Construc...IRJET - A Study on Identification of Risks at Various Phases of Road Construc...
IRJET - A Study on Identification of Risks at Various Phases of Road Construc...IRJET Journal
 
IRJET- Fuzzy Logic in Construction Project Scheduling: A Review
IRJET- Fuzzy Logic in Construction Project Scheduling: A ReviewIRJET- Fuzzy Logic in Construction Project Scheduling: A Review
IRJET- Fuzzy Logic in Construction Project Scheduling: A ReviewIRJET Journal
 
IRJET-Qualitative Risk Analysis for Construction Projects
IRJET-Qualitative Risk Analysis for Construction ProjectsIRJET-Qualitative Risk Analysis for Construction Projects
IRJET-Qualitative Risk Analysis for Construction ProjectsIRJET Journal
 
Risk Management In High Rise Construction Projects
Risk Management In High Rise Construction ProjectsRisk Management In High Rise Construction Projects
Risk Management In High Rise Construction ProjectsIRJET Journal
 
IRJET- Influence of Stakeholders on Project Time Overrun
IRJET- Influence of Stakeholders on Project Time OverrunIRJET- Influence of Stakeholders on Project Time Overrun
IRJET- Influence of Stakeholders on Project Time OverrunIRJET Journal
 
Minimization of Risks in Construction projects
Minimization of Risks in Construction projectsMinimization of Risks in Construction projects
Minimization of Risks in Construction projectsIRJET Journal
 

Similar to Risks in Public and Private Partnership Projects –Identification and Prioritization (20)

IRJET- Review on Developing a Model of Risk Allocation and Risk Handling for ...
IRJET- Review on Developing a Model of Risk Allocation and Risk Handling for ...IRJET- Review on Developing a Model of Risk Allocation and Risk Handling for ...
IRJET- Review on Developing a Model of Risk Allocation and Risk Handling for ...
 
IRJET- Risk Management in Construction: A Literature Review
IRJET- Risk Management in Construction: A Literature ReviewIRJET- Risk Management in Construction: A Literature Review
IRJET- Risk Management in Construction: A Literature Review
 
AN INTEGRATED PROJECT EVALUATION TOOL FOR PFI SEAPORT PROJECTS
AN INTEGRATED PROJECT EVALUATION TOOL FOR PFI SEAPORT PROJECTSAN INTEGRATED PROJECT EVALUATION TOOL FOR PFI SEAPORT PROJECTS
AN INTEGRATED PROJECT EVALUATION TOOL FOR PFI SEAPORT PROJECTS
 
An Integrated Project Evaluation Tool for PFI Seaport Project
An Integrated Project Evaluation Tool for PFI Seaport ProjectAn Integrated Project Evaluation Tool for PFI Seaport Project
An Integrated Project Evaluation Tool for PFI Seaport Project
 
IRJET- Risk Management in Residential Project by Primavera Software
IRJET- Risk Management in Residential Project by Primavera SoftwareIRJET- Risk Management in Residential Project by Primavera Software
IRJET- Risk Management in Residential Project by Primavera Software
 
Critical Success Factors and Strategies for Sub-contractor Management in Infr...
Critical Success Factors and Strategies for Sub-contractor Management in Infr...Critical Success Factors and Strategies for Sub-contractor Management in Infr...
Critical Success Factors and Strategies for Sub-contractor Management in Infr...
 
IRJET - Risk Allocation in Public Private Partnership Projects in Kerala
IRJET - Risk Allocation in Public Private Partnership Projects in KeralaIRJET - Risk Allocation in Public Private Partnership Projects in Kerala
IRJET - Risk Allocation in Public Private Partnership Projects in Kerala
 
IRJET- Analysis of Risk Factors Affecting Management and Maintenance of Urban...
IRJET- Analysis of Risk Factors Affecting Management and Maintenance of Urban...IRJET- Analysis of Risk Factors Affecting Management and Maintenance of Urban...
IRJET- Analysis of Risk Factors Affecting Management and Maintenance of Urban...
 
IRJET- Study and Analysis of Risk Management Strategies in Construction P...
IRJET-  	  Study and Analysis of Risk Management Strategies in Construction P...IRJET-  	  Study and Analysis of Risk Management Strategies in Construction P...
IRJET- Study and Analysis of Risk Management Strategies in Construction P...
 
IRJET- Risk Management in the Construction Project: Review
IRJET-  	  Risk Management in the Construction Project: ReviewIRJET-  	  Risk Management in the Construction Project: Review
IRJET- Risk Management in the Construction Project: Review
 
Risk Contingency Evaluation in International Construction Projects (Real Case...
Risk Contingency Evaluation in International Construction Projects (Real Case...Risk Contingency Evaluation in International Construction Projects (Real Case...
Risk Contingency Evaluation in International Construction Projects (Real Case...
 
Study and Need of Risk Management for Construction Projects
Study and Need of Risk Management for Construction ProjectsStudy and Need of Risk Management for Construction Projects
Study and Need of Risk Management for Construction Projects
 
IRJET- Developing a Model of Risk Allocation and Risk Handling for Effective ...
IRJET- Developing a Model of Risk Allocation and Risk Handling for Effective ...IRJET- Developing a Model of Risk Allocation and Risk Handling for Effective ...
IRJET- Developing a Model of Risk Allocation and Risk Handling for Effective ...
 
IRJET - A Study on Identification of Risks at Various Phases of Road Construc...
IRJET - A Study on Identification of Risks at Various Phases of Road Construc...IRJET - A Study on Identification of Risks at Various Phases of Road Construc...
IRJET - A Study on Identification of Risks at Various Phases of Road Construc...
 
project management
project managementproject management
project management
 
IRJET- Fuzzy Logic in Construction Project Scheduling: A Review
IRJET- Fuzzy Logic in Construction Project Scheduling: A ReviewIRJET- Fuzzy Logic in Construction Project Scheduling: A Review
IRJET- Fuzzy Logic in Construction Project Scheduling: A Review
 
IRJET-Qualitative Risk Analysis for Construction Projects
IRJET-Qualitative Risk Analysis for Construction ProjectsIRJET-Qualitative Risk Analysis for Construction Projects
IRJET-Qualitative Risk Analysis for Construction Projects
 
Risk Management In High Rise Construction Projects
Risk Management In High Rise Construction ProjectsRisk Management In High Rise Construction Projects
Risk Management In High Rise Construction Projects
 
IRJET- Influence of Stakeholders on Project Time Overrun
IRJET- Influence of Stakeholders on Project Time OverrunIRJET- Influence of Stakeholders on Project Time Overrun
IRJET- Influence of Stakeholders on Project Time Overrun
 
Minimization of Risks in Construction projects
Minimization of Risks in Construction projectsMinimization of Risks in Construction projects
Minimization of Risks in Construction projects
 

More from IRJET Journal

TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...
TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...
TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...IRJET Journal
 
STUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTURE
STUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTURESTUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTURE
STUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTUREIRJET Journal
 
A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...
A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...
A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...IRJET Journal
 
Effect of Camber and Angles of Attack on Airfoil Characteristics
Effect of Camber and Angles of Attack on Airfoil CharacteristicsEffect of Camber and Angles of Attack on Airfoil Characteristics
Effect of Camber and Angles of Attack on Airfoil CharacteristicsIRJET Journal
 
A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...
A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...
A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...IRJET Journal
 
Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...
Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...
Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...IRJET Journal
 
Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...
Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...
Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...IRJET Journal
 
A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...
A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...
A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...IRJET Journal
 
A REVIEW ON MACHINE LEARNING IN ADAS
A REVIEW ON MACHINE LEARNING IN ADASA REVIEW ON MACHINE LEARNING IN ADAS
A REVIEW ON MACHINE LEARNING IN ADASIRJET Journal
 
Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...
Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...
Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...IRJET Journal
 
P.E.B. Framed Structure Design and Analysis Using STAAD Pro
P.E.B. Framed Structure Design and Analysis Using STAAD ProP.E.B. Framed Structure Design and Analysis Using STAAD Pro
P.E.B. Framed Structure Design and Analysis Using STAAD ProIRJET Journal
 
A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...
A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...
A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...IRJET Journal
 
Survey Paper on Cloud-Based Secured Healthcare System
Survey Paper on Cloud-Based Secured Healthcare SystemSurvey Paper on Cloud-Based Secured Healthcare System
Survey Paper on Cloud-Based Secured Healthcare SystemIRJET Journal
 
Review on studies and research on widening of existing concrete bridges
Review on studies and research on widening of existing concrete bridgesReview on studies and research on widening of existing concrete bridges
Review on studies and research on widening of existing concrete bridgesIRJET Journal
 
React based fullstack edtech web application
React based fullstack edtech web applicationReact based fullstack edtech web application
React based fullstack edtech web applicationIRJET Journal
 
A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...
A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...
A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...IRJET Journal
 
A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.
A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.
A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.IRJET Journal
 
Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...
Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...
Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...IRJET Journal
 
Multistoried and Multi Bay Steel Building Frame by using Seismic Design
Multistoried and Multi Bay Steel Building Frame by using Seismic DesignMultistoried and Multi Bay Steel Building Frame by using Seismic Design
Multistoried and Multi Bay Steel Building Frame by using Seismic DesignIRJET Journal
 
Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...
Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...
Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...IRJET Journal
 

More from IRJET Journal (20)

TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...
TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...
TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...
 
STUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTURE
STUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTURESTUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTURE
STUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTURE
 
A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...
A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...
A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...
 
Effect of Camber and Angles of Attack on Airfoil Characteristics
Effect of Camber and Angles of Attack on Airfoil CharacteristicsEffect of Camber and Angles of Attack on Airfoil Characteristics
Effect of Camber and Angles of Attack on Airfoil Characteristics
 
A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...
A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...
A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...
 
Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...
Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...
Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...
 
Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...
Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...
Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...
 
A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...
A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...
A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...
 
A REVIEW ON MACHINE LEARNING IN ADAS
A REVIEW ON MACHINE LEARNING IN ADASA REVIEW ON MACHINE LEARNING IN ADAS
A REVIEW ON MACHINE LEARNING IN ADAS
 
Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...
Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...
Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...
 
P.E.B. Framed Structure Design and Analysis Using STAAD Pro
P.E.B. Framed Structure Design and Analysis Using STAAD ProP.E.B. Framed Structure Design and Analysis Using STAAD Pro
P.E.B. Framed Structure Design and Analysis Using STAAD Pro
 
A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...
A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...
A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...
 
Survey Paper on Cloud-Based Secured Healthcare System
Survey Paper on Cloud-Based Secured Healthcare SystemSurvey Paper on Cloud-Based Secured Healthcare System
Survey Paper on Cloud-Based Secured Healthcare System
 
Review on studies and research on widening of existing concrete bridges
Review on studies and research on widening of existing concrete bridgesReview on studies and research on widening of existing concrete bridges
Review on studies and research on widening of existing concrete bridges
 
React based fullstack edtech web application
React based fullstack edtech web applicationReact based fullstack edtech web application
React based fullstack edtech web application
 
A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...
A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...
A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...
 
A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.
A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.
A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.
 
Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...
Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...
Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...
 
Multistoried and Multi Bay Steel Building Frame by using Seismic Design
Multistoried and Multi Bay Steel Building Frame by using Seismic DesignMultistoried and Multi Bay Steel Building Frame by using Seismic Design
Multistoried and Multi Bay Steel Building Frame by using Seismic Design
 
Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...
Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...
Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...
 

Recently uploaded

Processing & Properties of Floor and Wall Tiles.pptx
Processing & Properties of Floor and Wall Tiles.pptxProcessing & Properties of Floor and Wall Tiles.pptx
Processing & Properties of Floor and Wall Tiles.pptxpranjaldaimarysona
 
(SHREYA) Chakan Call Girls Just Call 7001035870 [ Cash on Delivery ] Pune Esc...
(SHREYA) Chakan Call Girls Just Call 7001035870 [ Cash on Delivery ] Pune Esc...(SHREYA) Chakan Call Girls Just Call 7001035870 [ Cash on Delivery ] Pune Esc...
(SHREYA) Chakan Call Girls Just Call 7001035870 [ Cash on Delivery ] Pune Esc...ranjana rawat
 
chaitra-1.pptx fake news detection using machine learning
chaitra-1.pptx  fake news detection using machine learningchaitra-1.pptx  fake news detection using machine learning
chaitra-1.pptx fake news detection using machine learningmisbanausheenparvam
 
Decoding Kotlin - Your guide to solving the mysterious in Kotlin.pptx
Decoding Kotlin - Your guide to solving the mysterious in Kotlin.pptxDecoding Kotlin - Your guide to solving the mysterious in Kotlin.pptx
Decoding Kotlin - Your guide to solving the mysterious in Kotlin.pptxJoão Esperancinha
 
APPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICS
APPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICSAPPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICS
APPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICSKurinjimalarL3
 
MANUFACTURING PROCESS-II UNIT-2 LATHE MACHINE
MANUFACTURING PROCESS-II UNIT-2 LATHE MACHINEMANUFACTURING PROCESS-II UNIT-2 LATHE MACHINE
MANUFACTURING PROCESS-II UNIT-2 LATHE MACHINESIVASHANKAR N
 
Microscopic Analysis of Ceramic Materials.pptx
Microscopic Analysis of Ceramic Materials.pptxMicroscopic Analysis of Ceramic Materials.pptx
Microscopic Analysis of Ceramic Materials.pptxpurnimasatapathy1234
 
Call for Papers - African Journal of Biological Sciences, E-ISSN: 2663-2187, ...
Call for Papers - African Journal of Biological Sciences, E-ISSN: 2663-2187, ...Call for Papers - African Journal of Biological Sciences, E-ISSN: 2663-2187, ...
Call for Papers - African Journal of Biological Sciences, E-ISSN: 2663-2187, ...Christo Ananth
 
(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...ranjana rawat
 
(RIA) Call Girls Bhosari ( 7001035870 ) HI-Fi Pune Escorts Service
(RIA) Call Girls Bhosari ( 7001035870 ) HI-Fi Pune Escorts Service(RIA) Call Girls Bhosari ( 7001035870 ) HI-Fi Pune Escorts Service
(RIA) Call Girls Bhosari ( 7001035870 ) HI-Fi Pune Escorts Serviceranjana rawat
 
HARDNESS, FRACTURE TOUGHNESS AND STRENGTH OF CERAMICS
HARDNESS, FRACTURE TOUGHNESS AND STRENGTH OF CERAMICSHARDNESS, FRACTURE TOUGHNESS AND STRENGTH OF CERAMICS
HARDNESS, FRACTURE TOUGHNESS AND STRENGTH OF CERAMICSRajkumarAkumalla
 
High Profile Call Girls Nagpur Meera Call 7001035870 Meet With Nagpur Escorts
High Profile Call Girls Nagpur Meera Call 7001035870 Meet With Nagpur EscortsHigh Profile Call Girls Nagpur Meera Call 7001035870 Meet With Nagpur Escorts
High Profile Call Girls Nagpur Meera Call 7001035870 Meet With Nagpur EscortsCall Girls in Nagpur High Profile
 
(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...ranjana rawat
 
High Profile Call Girls Nagpur Isha Call 7001035870 Meet With Nagpur Escorts
High Profile Call Girls Nagpur Isha Call 7001035870 Meet With Nagpur EscortsHigh Profile Call Girls Nagpur Isha Call 7001035870 Meet With Nagpur Escorts
High Profile Call Girls Nagpur Isha Call 7001035870 Meet With Nagpur Escortsranjana rawat
 
Sheet Pile Wall Design and Construction: A Practical Guide for Civil Engineer...
Sheet Pile Wall Design and Construction: A Practical Guide for Civil Engineer...Sheet Pile Wall Design and Construction: A Practical Guide for Civil Engineer...
Sheet Pile Wall Design and Construction: A Practical Guide for Civil Engineer...Dr.Costas Sachpazis
 

Recently uploaded (20)

★ CALL US 9953330565 ( HOT Young Call Girls In Badarpur delhi NCR
★ CALL US 9953330565 ( HOT Young Call Girls In Badarpur delhi NCR★ CALL US 9953330565 ( HOT Young Call Girls In Badarpur delhi NCR
★ CALL US 9953330565 ( HOT Young Call Girls In Badarpur delhi NCR
 
Processing & Properties of Floor and Wall Tiles.pptx
Processing & Properties of Floor and Wall Tiles.pptxProcessing & Properties of Floor and Wall Tiles.pptx
Processing & Properties of Floor and Wall Tiles.pptx
 
Call Us -/9953056974- Call Girls In Vikaspuri-/- Delhi NCR
Call Us -/9953056974- Call Girls In Vikaspuri-/- Delhi NCRCall Us -/9953056974- Call Girls In Vikaspuri-/- Delhi NCR
Call Us -/9953056974- Call Girls In Vikaspuri-/- Delhi NCR
 
(SHREYA) Chakan Call Girls Just Call 7001035870 [ Cash on Delivery ] Pune Esc...
(SHREYA) Chakan Call Girls Just Call 7001035870 [ Cash on Delivery ] Pune Esc...(SHREYA) Chakan Call Girls Just Call 7001035870 [ Cash on Delivery ] Pune Esc...
(SHREYA) Chakan Call Girls Just Call 7001035870 [ Cash on Delivery ] Pune Esc...
 
9953056974 Call Girls In South Ex, Escorts (Delhi) NCR.pdf
9953056974 Call Girls In South Ex, Escorts (Delhi) NCR.pdf9953056974 Call Girls In South Ex, Escorts (Delhi) NCR.pdf
9953056974 Call Girls In South Ex, Escorts (Delhi) NCR.pdf
 
chaitra-1.pptx fake news detection using machine learning
chaitra-1.pptx  fake news detection using machine learningchaitra-1.pptx  fake news detection using machine learning
chaitra-1.pptx fake news detection using machine learning
 
Decoding Kotlin - Your guide to solving the mysterious in Kotlin.pptx
Decoding Kotlin - Your guide to solving the mysterious in Kotlin.pptxDecoding Kotlin - Your guide to solving the mysterious in Kotlin.pptx
Decoding Kotlin - Your guide to solving the mysterious in Kotlin.pptx
 
APPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICS
APPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICSAPPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICS
APPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICS
 
MANUFACTURING PROCESS-II UNIT-2 LATHE MACHINE
MANUFACTURING PROCESS-II UNIT-2 LATHE MACHINEMANUFACTURING PROCESS-II UNIT-2 LATHE MACHINE
MANUFACTURING PROCESS-II UNIT-2 LATHE MACHINE
 
Microscopic Analysis of Ceramic Materials.pptx
Microscopic Analysis of Ceramic Materials.pptxMicroscopic Analysis of Ceramic Materials.pptx
Microscopic Analysis of Ceramic Materials.pptx
 
Exploring_Network_Security_with_JA3_by_Rakesh Seal.pptx
Exploring_Network_Security_with_JA3_by_Rakesh Seal.pptxExploring_Network_Security_with_JA3_by_Rakesh Seal.pptx
Exploring_Network_Security_with_JA3_by_Rakesh Seal.pptx
 
Call for Papers - African Journal of Biological Sciences, E-ISSN: 2663-2187, ...
Call for Papers - African Journal of Biological Sciences, E-ISSN: 2663-2187, ...Call for Papers - African Journal of Biological Sciences, E-ISSN: 2663-2187, ...
Call for Papers - African Journal of Biological Sciences, E-ISSN: 2663-2187, ...
 
DJARUM4D - SLOT GACOR ONLINE | SLOT DEMO ONLINE
DJARUM4D - SLOT GACOR ONLINE | SLOT DEMO ONLINEDJARUM4D - SLOT GACOR ONLINE | SLOT DEMO ONLINE
DJARUM4D - SLOT GACOR ONLINE | SLOT DEMO ONLINE
 
(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
 
(RIA) Call Girls Bhosari ( 7001035870 ) HI-Fi Pune Escorts Service
(RIA) Call Girls Bhosari ( 7001035870 ) HI-Fi Pune Escorts Service(RIA) Call Girls Bhosari ( 7001035870 ) HI-Fi Pune Escorts Service
(RIA) Call Girls Bhosari ( 7001035870 ) HI-Fi Pune Escorts Service
 
HARDNESS, FRACTURE TOUGHNESS AND STRENGTH OF CERAMICS
HARDNESS, FRACTURE TOUGHNESS AND STRENGTH OF CERAMICSHARDNESS, FRACTURE TOUGHNESS AND STRENGTH OF CERAMICS
HARDNESS, FRACTURE TOUGHNESS AND STRENGTH OF CERAMICS
 
High Profile Call Girls Nagpur Meera Call 7001035870 Meet With Nagpur Escorts
High Profile Call Girls Nagpur Meera Call 7001035870 Meet With Nagpur EscortsHigh Profile Call Girls Nagpur Meera Call 7001035870 Meet With Nagpur Escorts
High Profile Call Girls Nagpur Meera Call 7001035870 Meet With Nagpur Escorts
 
(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
 
High Profile Call Girls Nagpur Isha Call 7001035870 Meet With Nagpur Escorts
High Profile Call Girls Nagpur Isha Call 7001035870 Meet With Nagpur EscortsHigh Profile Call Girls Nagpur Isha Call 7001035870 Meet With Nagpur Escorts
High Profile Call Girls Nagpur Isha Call 7001035870 Meet With Nagpur Escorts
 
Sheet Pile Wall Design and Construction: A Practical Guide for Civil Engineer...
Sheet Pile Wall Design and Construction: A Practical Guide for Civil Engineer...Sheet Pile Wall Design and Construction: A Practical Guide for Civil Engineer...
Sheet Pile Wall Design and Construction: A Practical Guide for Civil Engineer...
 

Risks in Public and Private Partnership Projects –Identification and Prioritization

  • 1. © 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 339 Risks in Public and Private Partnership Projects –Identification and Prioritization Hafeez Ali1, Asha Jose2 1Student: Department of Civil Engineering Indira Gandhi Institute of Engineering and Technology Kothamangalam, Eranakulam-686691 2Assistant Professor: Department of Civil Engineering Indira Gandhi Institute of Engineering and Technology Kothamangalam, Eranakulam-686691 ---------------------------------------------------------------------***--------------------------------------------------------------------- ABSTRACT Infrastructure is an important sector which contributes to the growth of overall development of the nation. Recently, Public Private Partnerships (PPP) has become the key factor to facilitate this development. Due to long concession periods and large investments, the risk management plays a crucial role in these types of projects. This thesis deals with the risk quantification and risk allocation of PPP projects using a fuzzy based questionnaire survey. Fuzzy logic can express and handle vague or imprecise judgments mathematically and therefore can effectively deal with errors due to human subjectivity. 20 risk factors in PPP projects are summarized from a comprehensive literature review. Interdependencies among the main risk factors affecting PPP projects are assessed using fuzzy Decision-Making Trial and Evaluation Laboratory (DEMATEL) approach. Sub risk factors are prioritized using a fuzzy hybrid method involving fuzzy Failure Mode and Effect Analysis (FMEA) and fuzzy Analytic Hierarchy Process (AHP) method. The obtained results have shown that approvals and permits, construction cost overrun, construction time overrun and land acquisition risks are the key risks affecting PPP projects. Key Words: Public Private Partnership Projects; Risk Management; Fuzzy Logic; Failure Mode and Effect Analysis; Decision Making Trial and Evaluation Laboratory; Analytic Network Process. 1. INTRODUCTION PPP is contractual partnership between the public and private sector agencies, specifically targeted towards financing, designing, implementing and operating infrastructure facilities and services. Moreover, PPP contributes to better quality and performance of infrastructure projects. Though PPP projects provide a good return in investment, risk involved in such projects is very significant. The risks need to be thoroughly analyzed, researched and managed to minimize disputes and costs and maximize the value for money. Risk management involves risk planning, risk identification, qualitative risk analysis, quantitative risk analysis, risk response planning, risk monitoring and control. Quantitative analysis of risks in PPP projects provides a very clear picture on the most prominent risk groups. This study uses a fuzzy based risk assessment approach to quantify risks occurring in PPP projects. A questionnaire survey was conducted among professionals working in PPP projects and responses of 24 experts are used for the analysis. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072 When making decisions in a fuzzy environment, the result of decision-making is highly affected by subjective judgments that are vague and imprecise. To solve this kind of imprecision problem, fuzzy set theory was first introduced by L. A. Zadeh (1965) as a mathematical way to represent and handle vagueness in decision-making. The concepts of fuzzy set theory are essential to accounting for the uncertainty and fuzziness of realistic environments. Research subjects are allocated a value between 0 and 1 to indicate their fuzzy degree. People’s subjective judgments are convertedinto numbers In particular, to tackle the ambiguities involved in the process of linguistic estimation, it is a beneficial way to convert these linguistic terms into fuzzy numbers. A linguistic variable is a variable whose values have the form of phrases or sentences in a natural language. Especially, linguistic variables are used as variables whose values are not numbers but linguistic terms. The linguistic term approach is a convenient way for decision makers to express their assessments. For dealing with the ambiguities of human assessments, the linguistic variable ‘‘influence’’ is used with different linguistic terms like very high, high, low etc. each of which are expressed in fuzzy numbers. A fuzzy hybrid method involving fuzzy Failure Mode and
  • 2. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072 © 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 340 Questionnaire survey based on fuzzy DEMATEL process to determine the interdependencies between the main risk factors Questionnaire survey based on fuzzy FMEA and fuzzy AHP methods to rank the sub risks Validation of the results Develop a risk breakdown structure Identify risk factors in PPP projects through literature survey Effect Analysis (FMEA), fuzzy Decision-Making Trial and Evaluation Laboratory (DEMATEL) and fuzzy Analytic Hierarchy Process (AHP) is employed for the purpose. DEMATEL, originally developed by the Science and Human Affairs Program of the Battelle Memorial Institute of Geneva between 1972 and 1976, is used for researching and solving the complicated and intertwined problem group. DEMATEL method allows to explore interrelationships between factors and to develop a cause effect diagram. The main advantage of fuzzy integrated DEMATEL is to consider fuzziness involved in human decision making. Fuzzy DEMATEL is used in this study to find the interdependencies between the main risk groups such as financial risks, legal risks, political risks etc. AHP is a widely used multi-criteria decision-making tool originally developed by Prof. Thomas L. Saaty. AHP uses pair-wise comparisons which allow verbal judgments and enhances the precision of the results. It is suitable to use fuzzy AHP to assess the risks of PPP projects, which will encounter many uncertainties during the long concession contract period and have multiple objectives originating from project stakeholders (Li and Zou, 2011). Failure Mode and Effect Analysis (FMEA) is a tool for identifying potential modes of failure in asystem, evaluating the main causes, determining the impact of failures and formulating preventive measures (Mohammadi and Tavakolan, 2013). In this system, a Risk Priority Number(RPN) for each risk is calculated as the product of the probability of risk occurrence (O), severity (S) and detection (D). In traditional FMEA, the relative importance ofO, S and D is not taken into account and RPN value may not truly represent the actual scenario. Fuzzy FMEA is used to overcome these drawbacks. Results of both fuzzy FMEA and fuzzy AHP technique are taken to rank the risk factors. 2. REASEARCH METHODOLOGY The research methodology adopted is demonstrated in Fig. 1 and is based on a comprehensive literature review, and comprehensive questionnaire survey for data collection. Fig.-1: Research Methodology
  • 3. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072 © 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 341 Force Majeure Natural Mainte - nance risks Operation cost overruns Operation Govern - ment’s reliability Land acquisi -tion risks Interest rate volatility Inflation rate volatility Contractu -al risks Change in tax regulation Change in law Approvals & permits Change in market demand Constru- ction Economic Political Revenue risks Concess- ionaire event of default Availab- ility of finance Legal Financial Technology risk External linkages Design Changes Construction cost overrun Constru- ction time delay Risk factors 3. RISK IDENTIFICATION AND RISK BREAKDOWN STRUCTURE The main risk factors and sub risk factors under each main risk in PPP projects identified were through literature survey Those factors that have been repeatedly identifiedin the literature as critical were only taken up for further analysis. 5 projects are taken to correlate the results of the literature review with the actual scenario in India. The projects were taken from Public Private Partnership Projects in India: Compendium of Case Studies. The case studies provided a representation across various locations and various types of PPP projects. The risk breakdownstructure formed is given in Fig.2. Fig.- 2: Risk Breakdown Structure 4. ANALYSIS OF MAIN RISK FACTORS DEMATEL is applied to determine effect and cause criteria, and to obtain the model in terms of linguistics parameterized with fuzzy numbers. Fuzzy DEMATEL method can be applied to problems that require group decision-making in a fuzzy environment. The procedure for fuzzy DEMATEL analysis to find the cause and effectrelationship between the main factors is given below (Tzeng et al., 2007 and Luthra et al., 2016).
  • 4. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072 © 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 342 Step 1: Respondents are asked to indicate the direct influence that they believe each main risk factor exerts on each of the others according to an integer scale ranging 0 - 4 and then the responses are entered into a matrix asfuzzy numbers. Step 2: Defuzzify the TFNs in the matrices into crisp scores (center of area method) to obtain defuzzified DEMATEL response matrix. Step 3: Compute the average matrix,X from all 24 responses Each element of this average matrix will be in this case the mean of the same elements in the different defuzzified response matrices of the respondents. Step 4: Calculate the initial direct relation matrix. The initial direct relation matrix, N can be obtained by normalizing the average matrix X. The initial influence which an element exerts and receives from another canbe read from matrix N. Matrix N portrays the interrelationships among the elements. Step 5: Calculate the direct/indirect relation matrix T, which is also called the total relation matrix. A continuous decrease of the indirect effects of problems along the powers of the matrix N (N2, N3, . . . , N∞) guarantees convergent solutions to matrix inversion. 𝑇 = lim (𝑁 + 𝑁2 + ⋯ + 𝑁𝑘) = (1 − 𝑁)−1 (1) Step 6: Calculate the sum of the values in each column and each row. This step entails summing the values of each column and row in the total relation matrix, where Di is the sum of the ith row and Rj is the sum of the jth column. Step 7: Let i=j; Di = D and Ri = R. A causal diagram can be acquired by mapping the dataset of (D + R, D - R), where the horizontal axis (D + R) is made by adding D to R, and the vertical axis(D - R) is made by subtracting D from R. In this step, (D + R) is defined as prominence and (D −R) is defined as relation. ‘‘Prominence’’ shows how important the criterion is, whereas ‘‘Relation’’ may divide the criteria into the cause and effect groups. When the value (D-R) is positive, the criterion belongs to the cause group. If the value (D-R) is negative, the criterion belongs to the effect group. Prominence and Relation values are provided in Table 5.7. Table-1: Prominence and Relation Values Factors D R ProminenceD+R RelationD-R Financial Risks 2.356 3.259 5.615 -0.903 Legal Risks 1.879 1.990 3.869 -0.111 Political Risks 3.010 1.646 4.656 1.364 Economic Risks 2.813 1.993 4.806 0.820 Construction Risks 2.139 3.217 5.356 -1.078 Operation Risks 2.053 2.229 4.282 -0.176 Natural Risks 2.357 2.273 4.630 0.084 As we move along the horizontal axis of the cause effect diagram the prominence of the factors increases. From the causal diagram (Fig 5.2), it can be inferred that financial risks are the most prominent risk group closely followed by construction risks. The horizontal axis separates the cause group risks and effect group risks. Fig. 5.2 reveals that political risks, economic risks and natural risks are the cause group risks and financial risks, legal risks, construction risks and operation risks are the effect group risks. The cause group risks trigger the other risks. Political risks are the major cause group risks and hence political risks should be given due considerationsin the risk management process. Construction risks and political risks are easily affected by other risks.
  • 5. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072 © 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 343 SEVERITY Rating Fuzzy Number Extremely significant effect (4, 5, 6) Very significant effect (3, 4, 5) Significant effect (2, 3, 4) Slight effect (1, 2, 3) No effect (1, 1, 2) DETECTION Rating Fuzzy Number Extremely significant effect (4, 5, 6) Very significant effect (3, 4, 5) Significant effect (2, 3, 4) Slight effect (1, 2, 3) No effect (1, 1, 2) OCCURRENCE Rating Fuzzy Number Very high (4, 5, 6) High (3, 4, 5) Medium (2, 3, 4) Low (1, 2, 3) Very low (1, 1, 2) Political Risks Chart 1: Cause Effect Diagram 5. ANALYSIS OF SUB RISK FACTORS Construction Risks Financial Risks A fuzzy hybrid method involving Fuzzy FMEA and Fuzzy AHP (FAHP) methods was adopted to prioritize sub riskfactors in PPP projects. FMEA takes into consideration the severity, frequency of occurrence and likelihood of detection of a particular risk factor while AHP explores the relative importance of the risk factors. The integration of fuzzy theory will help to reduce errors due to human subjectivity. The weights obtained by two method, fuzzyFMEA and FAHP, are multiplied to arrive at a final weight for each risk factor. 5.1 Fuzzy FMEA In Failure Mode and Effect Analysis (FMEA) a Risk Priority Number(RPN) for each risk is calculated as the product of the probability of risk occurrence (O), severity (S) and detection (D). The O rating refers to the frequency of the occurrence of a particular risk factor. The S rating is used to represent the potential effects associated with the occurrence of a risk factor. D rating considers the likelihood of detection of a particular risk factor. The RPN represents the level of a particular risk, i.e. a higher value of RPN means higher level of risk FMEA integrated with fuzzy theory allows risk prioritization to be handled more efficiently. Table 2: Fuzzy linguistic scale (Nazeri and Naderikia, 2017)
  • 6. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072 © 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 344 The Fuzzy FMEA procedure employed for the present study is provided below (Nazeri and Naderikia, 2017). Step 1: A fuzzy linguistic scale is adopted from Nazeri and Naderikia, 2017 and provided in Table-2 is selected, and respondents are asked to rate O, S and D according to it. Step 2: The mean responses are found by taking the average of the fuzzy ratings from the 24 respondents. Step 3: The mean response in TFN form is defuzzified into crisp score by center of area method. Step 4: The Risk Priority Number (RPN) is found by, RPN = O ⊗ S ⊗ D. The RPN gives the FMEA weights ofeach risk. Table 3: Sample FRPN Calculation for Risk Factor “Revenue Risks” Parameter Average response Crisp score FRPN Occurrence (3.13, 4.04, 5.04) 4.07 FRPN=4.07 ×4. 09 ×3.25= 54.100 Severity (3.09, 4.09, 5.09) 4. 09 Detection (2.40, 3.18, 4.18) 3.25 Similarly, FRPN values for all sub risks are calculated and listed in Table 4. Table 4: Fuzzy RPN Values Sub Risk Factors FRPN Sub RiskFactors FRPN Design changes 78.001 Change in law 36.452 Land acquisition risks 72.560 Force Majeure 32.541 Availability of finance 71.624 Interest ratevolatility 29.108 Construction time delay 69.231 Operation costoverruns 28.462 Approvals and permits 64.142 Technologyrisk 26.144 Revenue risk 54.112 Maintenancerisks 19.313 Contractual risks 53.451 Inflation ratevolatility 19.142 Change in market demands 48.674 Government’s reliability 17.251 Concessionaire event of default 48.213 Change in taxregulation 15.464 Construction cost overruns 39.13 Externallinkages 10.254
  • 7. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072 © 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 345 The risks are listed in Table 4 according to their priority order from the FMEA results. Design changes, Land acquisition risks, availability of finance, construction time delay and approvals and permits are the major risk according to the results obtained from fuzzy FMEA analysis. Change in tax regulation and external linkages are the least important ones. The FRPN values are multiplied by FAHP weights to obtain the final weights of each sub factor. 5.2 Fuzzy AHP Developed by T. L. Saaty in 1970, and refined continuously to date, the AHP breaks down the main problem into more comprehensible sub-problems. The AHP model is a tree diagram, which in its simplest form, consists of a goal at the top, a set of alternates for reaching the goal at the lowest level, and a set of criteria connecting the alternates to the goal. For the present study, project success is the goal. The set of risk factors are taken as the set of criteria forming the last level. If uncertainty (fuzziness) of human decision making is not taken into account in an AHP problem, the results can be misleading. FAHP overcomes the inability of AHP to deal with human subjectiveness in the pair wise comparison process. Instead of a single value, the FAHP generates a range of values to incorporate the decision- makers uncertainty. The steps employed to find the FAHP weights of risk factors are found from the procedure described below (Li and Zou, 2011;Ayhan, 2013). Step 1: The results of all the pair wise comparisons are entered into a matrix as fuzzy numbers according to a linguistic scale Step 2: Preferences of each respondent are averaged and is calculated to form a pair wise comparison matrix (which is average of all 24 responses) Step 3: The local weights of sub risk factors are found using Eq. 2. 𝑤𝑆𝑅𝑖 𝑛 𝑖= 1 𝑆𝑅 𝑖𝑗 𝑛 𝑗= 1 𝑛 𝑖= 1 𝑆𝑅 𝑖𝑗 (2) 𝐴 𝑆 is the ith row and jth column fuzzy element of updated sub risk pair wise comparison matrix and 𝑤𝑆𝑅 is the 𝑖𝑗 𝑖 local fuzzy weight of sub risk factor in ith row of sub risk comparison matrix Step 4: The weights of the main risk factors are found by employing Eq. 3. 𝑤𝑀𝑅𝑖 𝑛 𝑖= 1 𝑀𝑅 𝑖𝑗 𝑛 𝑗= 1 𝑛 𝑖= 1 𝑀𝑅 𝑖𝑗 (3) 𝐴 𝑀 is the ith row and jth column fuzzy element of main risk pair wise comparison matrix and 𝑤𝑀𝑅 is the fuzzy 𝑖𝑗 𝑖 weight of main risk factor in ith row of main risk pair wise comparison matrix. The calculations are similar to that of calculations to find the weights of sub risk factors Step 5: The global weights of each sub risk factor is found by the following Eq. 4 𝑊SR𝑖 = 𝑆𝑅𝑖 ⊗ 𝑊 𝑀𝑅𝑖 (4) 𝑊 SR𝑖 is the global fuzzy weight of sub risk factor in ith row of sub risk pair wise comparison matrix. Step 6: 𝑊 𝑆𝑅𝑖 is defuzzified into a crisp score using centre of area method. FAHP weights for the sub risks are provided in Table 5. = ∑ 𝐴 ⊗ ∑ ∑ 𝐴 = ∑ 𝐴 ⊗ ∑ ∑ 𝐴
  • 8. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072 © 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 346 Table-5: FAHP Weights of Sub Risk Factors Main Risk Factors Weights, 𝑾 𝑴𝑹𝒊 Sub Risk Factors Local Weights, 𝒘𝑺𝑹𝒊 Global weights, 𝑾𝑺𝑹𝒊 FAHP Weight Crisp Score Financial Risks (0.10, 0.23, 0.58) Availability of finance (0.36,0.63, 1.17) (0.04, 0.15, 0.67) 0.286 Revenue risk (0.03, 0.05, 0.09) (0.00, 0.01, 0.05) 0.020 Concessionaire event of default (0.12, 0.24, 0.50) (0.01, 0.05, 0.29) 0.116 Legal Risks (0.05, 0.10, 0.27) Approvals and permits (0.33, 1.65, 1.89) (0.01, 0.16, 0.51) 0.226 Land acquisition risks (0.68, 0.95, 1.08) (0.05, 0.09, 0.18) 0.106 Contractual risks (0.35, 0.36, 0.58) (0.03, 0.03, 0.16) 0.073 Political Risks (0.01,0.02, 0.05) Government’s reliability (0.17 ,0.57 ,0.79) (0.00, 0.01, 0.03) 0.013 Change in law (0.06,0.51,0.83) (0.00, 0.01, 0.04) 0.016 Economic Risks (0.20,0.26,0.55) Change in marketdemands (0.09, 0.08, 0.32) (0.01, 0.02, 0.17) 0.067 Change in tax regulation (0.24, 0.51, 0.73) (0.02, 0.13, 0.40) 0.183 Inflation rate volatility (0.02, 0.05, 0.09) (0.00, 0.01, 0.04) 0.016 Interest rate volatility (0.08,0.09, 0.20) (0.02, 0.02, 0.11) 0.050 Construction Risks (0.08,0.19,0.44) Constructiontime delay (0.32, 1.56, 1.89) (0.02, 0.29, 0.83) 0.380 Construction cost overruns (1.00, 1.82, 1.98) (0.08, 0.32, 0.87) 0.423 Design changes (0.52, 0.75, 0.91) (0.04, 0.14, 0.40) 0.193 External linkages (0.09, 0.10, 0.14) (0.00, 0.01, 0.06) 0.030 Technology risk (0.08, 0.09, 1.01) (0.00, 0.01, 0.44) 0.150 Operation Risks (0.06,0.14,0.31) Operation cost overruns (1.04, 1.16, 1.87) (0.06, 0.16, 0.57) 0.263 Maintenancerisks (0.34, 0.55, 0.67) (0.02, 0.07, 0.20) 0.096 Natura lRisks (0.01, 0.02, 0.06) Force Majeure (0.16, 1.29, 1.55) (0.00, 0.02, 0.09) 0.036 The final weights of the sub risk factors are calculated as the product of FAHP weights and FRPN values. The results are provided in Table-6.
  • 9. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072 © 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 347 Table-6: Ranking of Sub Risk Factors Sub Risk Factors FRPN FAHP Weight Final Weight Rank Approvals and permits 64.142 0.401 25.720 1 Construction time delay 69.231 0.356 24.646 2 Availability of finance 71.624 0.264 18.908 3 Construction cost overruns 39.139 0.468 18.317 4 Land acquisition risks 72.560 0.173 12.552 5 Design changes 78.001 0.153 11.934 6 Concessionaire event of default 48.213 0.189 9.112 7 Change in market demands 48.674 0.096 4.672 8 Operation cost overruns 28.462 0.164 4.667 9 Technology risk 26.144 0.178 4.653 10 Contractual risks 53.451 0.054 2.886 11 Revenue risk 54.112 0.042 2.272 12 Force Majeure 32.541 0.068 2.212 13 Change in tax regulation 15.464 0.113 1.747 14 Interest rate volatility 29.108 0.058 1.688 15 Maintenance risks 19.313 0.069 1.332 16 Change in law 36.452 0.014 0.510 17 Government’s reliability 17.251 0.021 0.362 18 External linkages 10.254 0.022 0.225 19 From the fuzzy AHP and fuzzy FMEA analysis, the top risk factors obtained are approvals and permits, construction time delay, and availability of finance, construction cost overruns and land acquisition risks. These sub risks should be given top priority while formulating a risk management strategy. Most of the PPP projects are delayed because of delays in getting timely approvals and permits. The concessionaire will find it difficult to execute the work within the planned schedule and this may even result in cost overruns. In most cases, it is not within the concessionaire’s powers to avoid such risks. However, risks such as construction time delays andcostoverruns can be avoided by proper planning for budget and cost. Risks due to unavailability offinance occur when there is an absence of a well organized financial framework. There should be provisions for alternate lenders so that there is a continuous flow of finance as and when required. Delays in obtaining land have created significant problems and even have lead to the discontinuation of many promising PPP project proposals. In some cases the government free up land before launching a PPP projects or in othercases the private sector is responsible for land acquisition. The land owners should be fairly compensated so there is no further resource consuming legal proceedings.
  • 10. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 09 Issue: 07 | July 2022 www.irjet.net p-ISSN: 2395-0072 © 2022, IRJET | Impact Factor value: 7.529 | ISO 9001:2008 Certified Journal | Page 348 6. RISKS IN CASE STUDY PROJECTS Three case study projects in Kerala were considered for the validation of the study. The major risks that occurred in Thiruvananthapuram City Road Improvement Project, Iruttukanam Small Hydro Electric Project and Thavakkara Bus Terminal Project are compared with the top ranked risks. The major risks that occurred in the above three projects are compared with the top risks obtained from the present study. Land acquisition is a majorrisk in all three of the projects while approvals and permits is a major issue in two of the projects. The rest of the top risks namely availability of finance, construction time delay and construction cost overrun occurs in at least one of the three projects taken. Thus, the major risks that occurredin the case studyprojects taken correlates with the results obtained from the present study. 7. CONCLUSIONS The main objective of this study is to identify the significant risks in PPP projects in Kerala and develop a risk allocation framework. The risk factors in PPP projects are summarized from a comprehensive literature review. A risk break down structure is formulated consisting of main risks and sub risks. The main risks are divided into cause and effect group by using fuzzy DEMATEL analysis. Political risks are found to be the major cause group while financial risks and construction risks are impacted the most due to other risk factors. In addition, financialrisks are found to be the most prominent risk group closely followed by construction risks. The key risks which affect the PPP projects are to be given due importance in order to achieve successful completion of such projects. A quantitative assessment of the risk will help to identify such key risks. The risks are assessed based on a fuzzy hybrid approach including fuzzy FMEA and fuzzy AHP approach. The obtained resultsrevealed that the top four risk factors are approvals and permits, construction time delay, availability of finance, construction cost overrun and land acquisition risks. The results obtained correlates with risks that occurred in case study projects in Kerala. In recent years the concept of PPP is gaining much more momentum across the country justbecause it has been able to provide ample solution to the much needed projects which government cannot do on its own. The research findings presented in this report can contribute to the development and application of PPP in Kerala and enables better understanding of the risk allocation in PPP projects. REFERENCES [1] Public Private Partnership Projects in India: Compendium of Case Studies, PPP Cell, Departmentof Economic Affairs New Delhi. [2] Ayhan M. B., A Fuzzy AHP Approach for Supplier Selection Problem: A Case Study in a Gearmotor Company, International Journal of Managing Value and Supply Chains, 2013, 4 (3), 11-23. [3] Li, J. and P. X. W. Zou (2011) Fuzzy AHP-Based Risk Assessment Methodology for PPP Projects, Journal of Construction Engineering and Management, 137 (12), 1205-1209. [4] Luthra, S., K. Govindan, R. K. Kharb and S. K. Mangla (2016) Evaluating the Enablers in Solar Power Developments in the Current Scenario Using Fuzzy DEMATEL: an Indian Perspective, Renewable and Sustainable Energy Reviews, 63, 379-397. [5] Mohammadi, A. and M. Tavakolan (2013) Construction Project Risk Assessment Using Combined Fuzzy and FMEA, IEEE, 232-237. [6] Nazeri, A. and R. Naderikia (2017) A New Fuzzy Approach to Identify the Critical Risk Factors in Maintenance Management, Intenational Journal of Advances in Manuf acturing and Technology, 92 (9-12), 3749–3783. [7] Tzeng, G. H., C. H. Chiang and C. W. Li (2007) Evaluating Intertwined Effects in E- Learning Programs: aNovel Hybrid, MCDM Model Based on Factor Analysis and DEMATEL, Expert Systems with Applications, 32 (4), 1028-1044.