This document discusses construction delays and extensions of time under standard construction contracts. It defines different categories of delays including those caused by the contractor, employer, and third parties. For contractor-caused delays, the contractor is not entitled to an extension of time or reimbursement for losses. For employer-caused delays, the contractor can claim an extension of time and reimbursement for losses. The document outlines the procedure for applying for an extension of time and the principles for granting one. It also discusses implications of granting or not granting extensions of time, such as liquidated damages and time becoming at large.
A review of the concept of extension of time for construction contracts, including why it is beneficial for employers to grant extensions. Includes a look at alternatives to extension, by way of acceleration of works.
A review of the concept of extension of time for construction contracts, including why it is beneficial for employers to grant extensions. Includes a look at alternatives to extension, by way of acceleration of works.
This seminar was part of the Bar Council practical construction law series presented by the Construction Law Committee to practitioners. It covers the topic of payments and common issues arising in the construction industry.
•What is Contract?
•What is Construction Contract?
•Purpose of Construction Contract
•Contract for Bid and Procurement
•Contract for Pricing Arrangement
•Construction Contract Component
•Contract Document List
•Standard Form of Contract in Malaysia
This seminar was part of the Bar Council practical construction law series presented by the Construction Law Committee to practitioners. It covers the topic of payments and common issues arising in the construction industry.
•What is Contract?
•What is Construction Contract?
•Purpose of Construction Contract
•Contract for Bid and Procurement
•Contract for Pricing Arrangement
•Construction Contract Component
•Contract Document List
•Standard Form of Contract in Malaysia
Tips for effective administration of a construction contract and for reducing the risk of delay and change orders. Interplay between the contractors, the consultant and an owner.
Contractor’s ability to mitigate damages can be limited if coupled with uncertainty of the duration of the delay. HOOH is recoverable in certain prolonged delay situations and has been granted by courts and amicable settlements for more than half a century. The Contractor may recover the return that he would have achieved on other work had his resources not been detained on the Works due to the delay. The presentation highlights the different formulae used in the calculations and conditions precedent to do so.
A thorough analysis of FIDIC and it implication on COnstruction industry explained in this presentation for the beginners. It has been broken down to simplified version
The French Revolution, which began in 1789, was a period of radical social and political upheaval in France. It marked the decline of absolute monarchies, the rise of secular and democratic republics, and the eventual rise of Napoleon Bonaparte. This revolutionary period is crucial in understanding the transition from feudalism to modernity in Europe.
For more information, visit-www.vavaclasses.com
Operation “Blue Star” is the only event in the history of Independent India where the state went into war with its own people. Even after about 40 years it is not clear if it was culmination of states anger over people of the region, a political game of power or start of dictatorial chapter in the democratic setup.
The people of Punjab felt alienated from main stream due to denial of their just demands during a long democratic struggle since independence. As it happen all over the word, it led to militant struggle with great loss of lives of military, police and civilian personnel. Killing of Indira Gandhi and massacre of innocent Sikhs in Delhi and other India cities was also associated with this movement.
The Indian economy is classified into different sectors to simplify the analysis and understanding of economic activities. For Class 10, it's essential to grasp the sectors of the Indian economy, understand their characteristics, and recognize their importance. This guide will provide detailed notes on the Sectors of the Indian Economy Class 10, using specific long-tail keywords to enhance comprehension.
For more information, visit-www.vavaclasses.com
This is a presentation by Dada Robert in a Your Skill Boost masterclass organised by the Excellence Foundation for South Sudan (EFSS) on Saturday, the 25th and Sunday, the 26th of May 2024.
He discussed the concept of quality improvement, emphasizing its applicability to various aspects of life, including personal, project, and program improvements. He defined quality as doing the right thing at the right time in the right way to achieve the best possible results and discussed the concept of the "gap" between what we know and what we do, and how this gap represents the areas we need to improve. He explained the scientific approach to quality improvement, which involves systematic performance analysis, testing and learning, and implementing change ideas. He also highlighted the importance of client focus and a team approach to quality improvement.
How to Make a Field invisible in Odoo 17Celine George
It is possible to hide or invisible some fields in odoo. Commonly using “invisible” attribute in the field definition to invisible the fields. This slide will show how to make a field invisible in odoo 17.
The Art Pastor's Guide to Sabbath | Steve ThomasonSteve Thomason
What is the purpose of the Sabbath Law in the Torah. It is interesting to compare how the context of the law shifts from Exodus to Deuteronomy. Who gets to rest, and why?
Synthetic Fiber Construction in lab .pptxPavel ( NSTU)
Synthetic fiber production is a fascinating and complex field that blends chemistry, engineering, and environmental science. By understanding these aspects, students can gain a comprehensive view of synthetic fiber production, its impact on society and the environment, and the potential for future innovations. Synthetic fibers play a crucial role in modern society, impacting various aspects of daily life, industry, and the environment. ynthetic fibers are integral to modern life, offering a range of benefits from cost-effectiveness and versatility to innovative applications and performance characteristics. While they pose environmental challenges, ongoing research and development aim to create more sustainable and eco-friendly alternatives. Understanding the importance of synthetic fibers helps in appreciating their role in the economy, industry, and daily life, while also emphasizing the need for sustainable practices and innovation.
Unit 8 - Information and Communication Technology (Paper I).pdfThiyagu K
This slides describes the basic concepts of ICT, basics of Email, Emerging Technology and Digital Initiatives in Education. This presentations aligns with the UGC Paper I syllabus.
We all have good and bad thoughts from time to time and situation to situation. We are bombarded daily with spiraling thoughts(both negative and positive) creating all-consuming feel , making us difficult to manage with associated suffering. Good thoughts are like our Mob Signal (Positive thought) amidst noise(negative thought) in the atmosphere. Negative thoughts like noise outweigh positive thoughts. These thoughts often create unwanted confusion, trouble, stress and frustration in our mind as well as chaos in our physical world. Negative thoughts are also known as “distorted thinking”.
How to Split Bills in the Odoo 17 POS ModuleCeline George
Bills have a main role in point of sale procedure. It will help to track sales, handling payments and giving receipts to customers. Bill splitting also has an important role in POS. For example, If some friends come together for dinner and if they want to divide the bill then it is possible by POS bill splitting. This slide will show how to split bills in odoo 17 POS.
4. DELAYS
Categories of delays : -
➢ Delay caused by Contractor (Clause 21.1)
➢ Delay caused by Employer (Clause 23.8) - 15 relevant events
➢ Delay caused by Third Parties ( Neutral Event) (Clause 23.8) - 9 relevant events
5. DELAY BY CONTRACTOR
Reasons :
● Not having sufficient labour force or plant on site
● Not having necessary materials when needed
● Poor site management/co-ordination/experience
● Failure to pay workers or sub-contractors
Contractual Effects :
● Not entitle to claim for EOT
● No reimbursement for loss and expense
● Employer can be compensated by the way of LD
● Employer may terminate the contractor’s employment if delay is too long
6. DELAY BY EMPLOYER
15 Relevant Events under clause 23.8
Contractual Effects :
● Contractor entitlement to claim for EOT
● Contractor entitle to claim for loss and expense
● Employer cannot impose LD because is own fault
● If delay is serious, contractor can terminate his employment
7. DELAY BY THIRD PARTIES (NEUTRAL EVENTS)
● Weather, Act of God, Natural Justices
● 9 Relevant Events
● Not the fault of contractor or employer
● They have to bare with their own responsibilities
Contractual Effects :
● Contractor entitled to EOT
● Contractor not entitled to lose and expense
● Employer cannot imposed LD
● Contractor and employer should share the burden of delay
8. EXTENSION OF TIME
Procedure of EOT
STEP 1 : Giving of notice
- Must give a written notice of intention to claim for EOT. It is a condition precedent to
any EOT.
STEP 2 : Official Application
- Must submit official application within 28 days after the end of the event.
9. EXTENSION OF TIME
1. Decision to claim for EOT ( is up to the contractor )
2. Failure to submit claim application
3. Written notice shall be a condition precedent to an entitlement of EOT
Case Study 1: Syarikat Tan Lim Bent & Rakan-Rakan v Pulai Jaya S/B (1992)
It was held that this is an expressed condition, contractor must comply. Contractor may lose the case because he failed to submit
written notice.
Case Study 2 : Turner Corporation Ltd v Austotel Pty Ltd (1997)
It was held contractor cannot rely on acts of prevention by employer for not giving written notice. He must give notice which would
have negated the effect of that preventing conduct.
10. Principles for Granting EOT (Architect have to make decision)
1. Before granting EOT, architect have to consider certain items
- In writing - Have materially disrupted the regular progress of works
- Fall within clause 23.8 - Nett effective delay must be assessed based on approved
- Prevent further losses or delays work programme
2. Issue of the certificate of EOT (Architect have to make 2 decision)
- Reject totally with reasons
- Grant an appropriate EOT and issue certificate of EOT
11. 3. Timing of Issue
- Within 6 weeks from the contractor's application, architect must decide an
issue
4. Delay by NSC
5. Obligations of Architect
- To assess the length of EOT, architect must act reasonably, fairly and
impartially
- Failure to assess application and issue EOT is a breach
12. 6. Consequences of Not Granting Contractor’s Application
● If architect default in granting EOT
● Employer will loses the rights to impose liquidated damages
● It is a breach of contract
● Architect liable to the employer in tort (negligence) / for breach of contract (services)
For contractor, initial course of action : i) Make a fresh application
ii) Appeal to employer
iii) Contractor can refer the dispute to Arbitration
13. Can EOT be granted Prospectively or Retrospectively?
1. Clause 23.4
- Architect may issue the written notice of rejection or the certification of EOT before / after
the Completion Date
- Architect can make & approve EOT backward / forward
2. Situations can arise
- Contractor’s submission of his particulars under clauses 23 very near to the completion date
3. Retrospectively
- Contractor submit one week before the completion date
- Architect will assess EOT after completion date
14. EOT After The Issuance Of Certificate of Non-Completion(CNC)
1. If contractor doesn’t complete, architect must issue CNC to contractor. If not employer cannot
impose liquidated damages
2. When clause 23.9 is read together with clause 22.3 the granting of subsequent EOT will
revoke the CNC
3. When CNC is cancelled, employer have to return the surplus liquidated damages.
4. If contractor again fails to complete by the new completion date, a new CNC will be issued by
architect.
15. EOT PROVISIONS
● Employer cannot set new completion date
● Contractor have to complete within a
reasonable time
● Time become at large
● Employer loses the rights to impose
liquidated damages
EOT PROVISIONS
● Completion date can be extended,
if there is a delay
● Employer can set new completion date
● Preserves employer’s contractual rights to
impose liquidated damages
● Prevents time become at large
16. Implications Of Time For Completion Being At Large
1. Original completion date no longer apply
2. there is no definite completion date to work towards
3. Contractor have to complete within a reasonable time
4. Employer loses his right to imposes liquidated damages
5. Contractor’s liability is limited to general damages
17. LIQUIDATED DAMAGES
In order to a successful claim for liquidated damages, Employer have to comply with the
following pre-conditions :
➢ Contract contains express clause enabling the deduction of the liquidated damages
➢ The liquidated clause must be valid and enforceable
➢ Details of liquidated damages must be clearly indicated
➢ Specific contractual procedure must be strictly complied
➢ Must be definite date fixed in contract from which damages can run
➢ Employer has not waived his right to deduct the liquidated damages
Amount of damages that need to be paid to the injured party to collect as compensation upon a specific
breach in a contract.
18. CASE STUDY
Case 1
➢ Selva Kumar a/l Murugiah v. Thiagarajah a/l Retnasamy [1995] 2 MLJ 817
Case 2
➢ Johor Coastal Development Sdn Bhd v. Constrajaya Sdn Bhd [2009] 4 CLJ 569
19. Question 1: As a Consultant assessing an extension of time
application by the Contractor, what are the initial checklist
and the principles to be applied?
20. ● The application must be in writing
● Causes of delay must be under Clause 23.8
● Contractor must have taken all practical steps to mitigate
● Delays must be ‘materially’ disrupted the regular progress of the works, resulting in the
completion date being breached
● The ‘nett effective’ delay must be assessed based on approved work programme under
Clause 3.5
21. Question 2: What are the purpose of an extension of time clauses in
most standard contract and its implications? What is the implication
of a Certificate of Non-Completion? What is the difference between
general damages and liquidated damages?
22. Purpose of EOT
Employer entitled to impose liquidated damages due to the delay caused by contractor.
Contractor in will be granted EOT due to delays caused by employer. (Clause 23.8)
If there is no EOT provision, the contractor’s liability will be limited to general damages not liquidated
damages.
Implication of EOT
If there is EOT provision, completion date can be extended and new completion date can be set. It preserves
the employer’s contractual right to impose liquidated damages to the contractor. It also prevent the completion
time to be ‘at large’.
If there is no EOT provision, time will be ‘at large’, contractor will have to complete the project at a
reasonable time.
23. Implication of certificate of Non completion ( 22.3 & 23.9)
A formal return notice for the contractor, it gives the employer the right to impose liquidated damage to
the contractor.
If EOT is issued after issuance of CNC, employer shall return the surplus amount of liquidated damages
imposed to the contractor.
General damages Liquidated Damages
No EOT provision With EOT provision
Hard to prove (no basis to follow) Easier to prove ( master programme as basis)
No fixed amount Fixed amount
Differences between General damages & Liquidated damages
24. Question 3: What are concurrent delays? Is the Contractor
entitled to extension of time and loss and expense if there
are concurrent delays by Employer and Contractor?
25. Concurrent Delays
● Simultaneous delays caused by the contractor and employer
● Two or more delay events occurring within the same time period
● Affecting the project schedule and project completion date
● but not all of those events enable to claim an extension of time or loss and expense
Contractor entitled to extension of time and loss and expense if
● Have the valid reason and certify by Architect and consultant Quantity Surveyor.
26. QUESTIONS
Q1 : What are the effects of construction projects delay?
Q2 : What are the examples of grounds for challenging extension of time certificate ?
(In what event can the contractor challenge the EOT certificate that is issued by the
Architect?)
Q3 : If Nominated Sub-Contractor goes bankrupt, can the contractor claim for EoT? If
yes what is the relevant clause?
27. ANSWER FOR Q1
➢ Cost overrun
- Contractor extend insurance policies (claimable)
- Contractor’s fault, employer has the rights to impose liquidated damages
➢ Time overrun
- Contractor claims for EOT
- New completion date
➢ Dispute (Arbitration)
28. ANSWER FOR Q2
➢ Certificate not given time
➢ Certificate no in the correct format
➢ Certificate issued by unauthorised person
➢ Addressee of certificate not named
➢ Decision to extend time improperly delegated
➢ Certificate not given fairly
➢ Contractual procedures not followed
Delays of a project can be categorised into 3 categories which are delays caused by contractor, employer and third parties which is the neutral event
The common delay caused by the contractor are not having sufficient labour force or plant on site, not having necessary materials when needed (not enough materials which caused work cannot be done until the next delivery of materials), poor site management/co-ordination/ lack of experience( do not know how to plan properly), and lastly failure to pay workers or sub-contractors.
If a delays is caused by contractor, contractor have to compesate employer by the way of LD. Contractor is not entitled to claim for EOT, no reimbursement for loss and expenss, employer can be compesated by the way of LD, and employer may terminate the contractor ‘s employment if delay is too long.
. For the delay caused by employer is listed under clause 23.8 If the causes of delay are fall under this clause, the contractor is entitle to claim for EOT. If delay is caused by employer, contractor entitle to claim for EOT, contractor get monetary compesation by way of lose and expense, employer cannot impose LD because is his own fault,and if the delay is so serious, the contractor may want to terminate the employment.
For the delay caused by neutral events which are the weather,act of god and the natural justices. There are 9 relevant events in the PAM Contract. Neutral events is not the fault of the contractor and employer as well. They have to bare with their own responsibilities. The contractor is entitled to claim for EOT but will not be compensated with money because not employer’s fault, employer cannot imposed LD as it is not the contractor fault, contractor and employer should share the burden of delay since nobody fault.
Case 1: employer was ask by the federal court to prove the actual damage even though under clause 22.2 reads that both party is agreed with the amount stated in the contract.
Case 2: Employer still have to prove the actual damage. Court had made decision where there will be some case that damage can be easily calculated that will have to prove and some case that calculation is complex does not need to prove. The decision is still up to the court decision whether it is a complex or non complex case.
JKR (diff)
JKR- no notice required to apply for EOT
As a consultant assessing an extension of time application by contractor, the initial checklist and the principles to be applied are the consultants have to check whether the application is in writing form.
The causes of delay must be fall within Clause 23.8. If it is not under this clause then it will be rejected.
Contractor must have taken all practical steps to mitigate the delay which to prevent further losses or prevent further delay.
The delays must be materially disrupted the completion date or the progress of the works, if it does not affect then cannot claim for EOT.
The nett effective delay must be assessed based on approved work programme.The approved work programme is the basis of the EOT. EOT cannot be claimed without work programme. Clause 3.5 mentioned that master programme must submit within 2 weeks from the date of letter of award for approval.
PURPOSE
It gives the benefits to the employer to impose liquidated damages to the contractor if its contractor’s default in causing the delays.
It gives benefits to the contractor to have extended time in completing the project due to the delays caused by employer under clause 23.8 relevant event.
In the event if there is no EOT provision, the contractor’s liability will be limited to general damages not liquidated damages.
IMPLICATION
If its contractor default in delaying the works, it gives the right to the employer impose liquidated damages to the contractor.
If it's employer default, the contractor will be granted for EOT contractor will (avoid the liability to pay to pay liquidated damages).
If there is no EOT provision, time will be at large, contractor will have to complete the project at a reasonable time.
This certificate gives the formal return notice for the contractor to inform the contractor that they have failed to complete their works on time agreed in the contract and it gives the employer the right to impose liquidated damage to the contractor.
In the event if EOT is issued after issuance of CNC, employer is to return the surplus amount of liquidated damages to the contractor.
General damages is only exist if there is no EOT provision in the contract while LD is an agreed amount stated in the contract by both parties in the event if any party breach the contract.