SlideShare a Scribd company logo
The Architect as Contract Administrator
DAS AZMAN ARCHITECTS SDN BHD
A Legal Perspective
Ar. THURAI DAS THURAISINGHAM
1 2 N o v e m b e r 2 0 1 1
1
An overview The Architect As Contract Administrator ● A Legal Perspective
Contents
● An Overview
● Architect’s Work Scope
● The Building Contract
● Architect – An Independant Certifier
● Specific Contractual Clauses – PAM 2006 Form
● Conclusion
2
An overview The Architect As Contract Administrator ● A Legal Perspective
Sources of Law
● Federal and State Constitutions
● Statutes
eg. - Contracts Act 1950
- Architects Act 1967
- Street, Drainage And Building Act 1974
● Common Law
- Judicial decisions made by the Courts
● Regulations of Administrative Agencies
eg. - Board of Architects
- Architects (Scale of Minimum Fees) Rules 2010.
● Rules of Equity
Classification of Law
Law pertaining to the practice of architecture
Civil Law : Private law dealing with the rights and obligations of individuals and
corporations in their dealing with each other.
eg. Law of Contract
Law of Tort
Administrative Law : Legislation at the federal, state and local levels establishes and enhances
building codes and regulations.
Designed to protect the health, safety and welfare of the public.
3
An overview The Architect As Contract Administrator ● A Legal Perspective
Law of Contract
Concerns the legally binding rights and obligations of parties who have made an agreement for a specific
purpose.
Law of Tort
A tort is a wrong done by one party to another for which a remedy such as compensation or an injunction
may be sought in the courts.
Specific Torts eg. Negligence
Defamation
Trespass.
The Architect’s Liability
The Architect’s legal obligations and responsibilities are owed to a variety of parties, and are governed by
statutes, administrative regulations and common law.
Two areas of specific concern are,
Breach of Contract
Negligence
4
An overview The Architect As Contract Administrator ● A Legal Perspective
Breach of Contract
The Architect enters into a contractual relationship with the client to perform specific services. (architectural
consultancy) There is an implied agreement to carry out the required work to the standard expected of the
profession. Failure to meet these standards, which cause extra expense or delays for the owner, may result
in a claim for damages against the Architect on the grounds of breach of contract.
Negligence
Apart from any contractual obligations which may have been agreed upon, a duty or standard of care
under the law of tort may exist. If a person fails in this duty, a negligence suit could succeed.
5
Architect’s Work Scope The Architect As Contract Administrator ● A Legal Perspective
CLIENT / ARCHITECT AGREEMENT
ARCHITECT’S SCOPE OF WORKS
Schematic Design
Phase
Design
Development
Phase
Tender
Documentation
Phase
Contract
Implementation &
Management
Phase
CONTRACT IMPLEMENTATION AND MANAGEMENT PHASE
ARCHITECT’S PROFESSIONAL DUTIES
CLIENT
CONTRACTOR
&
EMPLOYER
Defined By
CLIENT / ARCHITECT
AGREEMENT
Defined By
BUILDING
CONTRACT
6
The Building Contract The Architect As Contract Administrator ● A Legal Perspective
The Building Contract
The building contract in reference, in this paper, is the PAM 2006 Form – With Quantities edition.
This is a contract for a lump sum which requires the Contractor to complete the work comprised in
it for an ascertained and specified sum, subject to it being increased or diminished, by taking into
consideration the value of variation additions and omissions made in accordance with the contract.
The PAM 2006 Form must be read in conjunction with the general corpus of the law of contract. A
standard form, in itself, will not be self-sufficient nor self-contained, in incorporating all the rights
and obligations of the contracting parties. As such, it must be read and understood in light of the
general law and in particular that part of the law governing contractual relationships.
Article 3 of the Articles of Agreement of the PAM 2006 Form, provides for the designation of an
Architect registered with the Board of Architects Malaysia. Under Article 3, the Employer has a duty
to appoint the Architect. The named Architect, engaged by the Employer is thus entrusted with the
administration and supervision of the building contract.
7
Architect – An Independent Certifier The Architect As Contract Administrator ● A Legal Perspective
Architect – An Independant Certifier
The Architect, engaged by the Employer, acts as his agent for the purpose of securing the
completion of the works, in an economical and timely manner. Under the PAM 2006 Form, the
Architect is the contract administrator, whilst at the same time, under this phase he continues to be
the Employer’s agent.
In his capacity as contract administrator and an agent of the Employer the Architect, amongst
others, provides information to the Contractor to enable him to carry out his contractual works,
issues variation orders which may alter the extent, nature and quantity of the works, nominates
sub-contractors and suppliers on the Employer’s behalf, supervises and approves the works.
In his capacity as contract administrator and independent certifier, it is the Architects’ duty to issue
certifications on all payments due under the contract and to certify acceptance of completed works
in conformity to contract specifications and accepted standards.
The contract administrator must act with independence, impartiality and fairness. The professional
obligation to act fairly extends to such of his duties as require him to use his professional skill and
judgement in forming an opinion or making a decision where he is holding the balance between his
Client and the Contractor.
8
Architect – An Independent Certifier The Architect As Contract Administrator ● A Legal Perspective
Architect – An Independant Certifier
Continuation
The Architect is duty bound to serve the Employer faithfully as his agent. The Employer would
reasonably expect that the Architect possesses the requisite ability and skill, and the latter, by
holding himself out as an Architect, impliedly warrants that he possesses such attributes. An
Architect would be liable to the Employer if he had been professionally negligent.
Breach of a professional persons obligations to his Client is generally referred to as professional
negligence. For liability to be established it must be proven that the Architect had failed to exercise
the standard of care required and that the negligence alleged is a matter of substance.
Not every careless act or fault of an Architect gives rise to liability in negligence, even where
damage is sustained by another as a result.
In order to establish a claim in negligence, the law makes it necessary for a claimant to satisfy the
following requirements :-
o The existence in law of a duty of care.
o Professional conduct that falls below the standard of care imposed by law.
o A causal connection between the defendant’s conduct and the damage.
o Damage falling within the scope of the duty.
9
Architect – An Independent Certifier The Architect As Contract Administrator ● A Legal Perspective
Architect – An Independant Certifier
Continuation
In a situation where special skill or competence is involved, then the test as to whether there has
been negligence or not, is measured against the standard of the ordinary skilled man exercising
and professing to have that skill. The normal measure of an Architect’s skill is that of ordinary
skilled Architects. An error of judgement may or may not amount to negligence. A good defence
against a negligence complaint is one where the Architect can show that he acted in accord with
general and approved practice.
The seminal English case of Sutcliff v Thackrah (1974) AC 727 deemed that the Architect is liable
in damages if he causes loss to his Employer by failure to take due care or to exercise reasonable
professional skill in carrying out his duties.
It would be a reasonable expectation on the Client’s part, that the Architect will perform his duties
under the contract, in such a manner as to safeguard his interests and that he will do all that is
reasonably within his power to ensure that the work is satisfactorily and expeditiously undertaken,
so as to achieve the objective as contemplated by the contract. It naturally flows from this
expectation that the Architect will administer the contract and supervise the work, so as to ensure,
as far as is reasonably possible, that the quality of work, is as specified in the contract.
The Architect must provide reasonable supervision to the works, not only in compliance with
statutory provisions, but also to enable him to issue certifications under the contract that the work
has been satisfactorily carried out in accordance with contract drawings and specifications. He is
not required personally to measure or check every detail, but should check substantial and critical
aspects of the work. It is altogether imperative that qualified supervisory personnel are stationed at
the construction site, to assist the Architect in his supervision of the works.
10
Architect – An Independent Certifier The Architect As Contract Administrator ● A Legal Perspective
Architect – An Independant Certifier
Continuation
In the administration of the building contract, the importance of the Architect’s impartiality in his role
as an independent certifier, cannot be over – emphasised. The basic premise underpinning the
system of payment arrangements in construction contracts is the integrity of the certification
machinery. The Architect must exercise his function as the certifier in good faith and to the best of
his uninfluenced professional judgement, eventhough he is appointed by the Employer.
It is settled law that an Architect, in exercising his function as a certifier under a building contract
has to act fairly and independently and should not be subject to the directions or instructions of
either the Employer nor the Contractor. Needless to say, an Architect should never allow the
Employer improperly to influence his decisions nor should the Employer prevent the independent
exercise of the Architect’s authority as certifier.
The Architects decisions and certificates bind both the Employer and the Contractor. Improper or
negligent certification may result in the Contractor suffering financial losses. This could arise where
the Architect under – certifies the Interim Payment Certificates and Final Certificates, certifies late
or fails to certify them at all, or when he does not certify the Certificate of Practical Completion or
Certificate of Making Good Defects, or certifies them late, or he issues the Certificate of Non-
Completion erroneously causing the Employer to deduct monies from sums otherwise due to the
Contractor.
The Contractor’s contractual remedy in such situations is by way of reference to arbitration, as
provided for under Clause 34.0 of the PAM 2006 Form.
There have been cases where an aggrieved Contractor has sued the Architect in tort for negligent
certification. The question here is whether an Architect owed a duty of care to the Contractor in the
issuance of certificates under the building contract. Based on recent case law, it would seem
unlikely that a contractor, under a building contract which provides for arbitration, could
successfully bring a claim in tort against the Architect for negligent certification.
11
Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective
THE PAM 2006 FORM – With Quantities Edition
CLAUSE 15.0 PRACTICAL COMPLETION AND DEFECTS LIABILITY
Clause 15.1 Practical Completion
Clause 15.2 Certificate of Practical Completion
Clause 15.3 Contractor’s failure to comply with undertaking
Clause 15.4 Schedule of Defects
Clause 15.5 Instruction to make good Defects
Clause 15.6 Certificate of Making Good Defects
12
Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective
PAM 2006 Form : Clause 15.0 A Commentary
The term ‘practical completion’ is not explicitly defined in Clause 15.1 of the conditions of contract.
It is stipulated amongst others, that for the issuance of the Certificate of Practical Completion, in
the opinion of the Architect, the Employer can have full use of the Works for their intended
purposes, notwithstanding that there may be works and defects of a minor nature still to be
executed.
There have been conflicting court decisions, as can be seen in the English cases of Westminster
City Council v Jarvis & Sons Ltd (1970) 7 BLR 64 and P&M Kaye LTD v Hosier & Dickinson Ltd
(1972) 1 WLR 146, as to what constitutes practical completion in the context of the JCT 1963
Form.
The latter case takes a rather expedient view that it would be unrealistic to take practical
completion to mean completion down to the last detail. This could be interpreted to mean that if the
Works reach a state of readiness for use or occupation by the employer, then they would be
considered to be practically complete.
The earlier case of Westminster City Council v Jarvis & Sons Ltd (1970) 7 BLR 64 takes a strict
view that all patent defects are to be remedied before the issuance of the CPC. Practical
completion is construed to be completion for all practical purposes when the contractor has
performed all the contractual works except for very minor ‘de minimis’ work and there are no patent
defects in the Works.
In the case of HW Nevill (Sunblest) Ltd v William Press & Son Ltd (1981) 20 BLR 78 it was held
that the Architect would have a discretion to certify practical completion when very minor ‘de
minimis’ works had not been carried out, but if there are any patent defects then the architect
cannot issue a certificate of practical completion.
13
Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective
PAM 2006 Form : Clause 15.0 A Commentary
Continuation
To state the obvious, the Certificate of Practical Completion is a highly significant document with
major contractual implications. The Architect in the administration of the contract is here called
upon to exercise his professional judgement on whether the Works are practically complete or
otherwise. The exercise of judgement should be done in a responsible, prudent and impartial
manner. Specifically, the architect is to determine whether the very minor works left incomplete or
that which needs to be remedied is to be deemed as ‘de minimis’ in which case he would issue the
Certificate of Practical Completion.
Based on the stipulations in the PAM 2006 Form it would be reasonable to issue the Certificate of
Practical Completion only when all contractual works have been completed in accordance with
contract drawings and specifications. The only exception to this condition would be incomplete or
remedial works of a very minor nature and defects which are not apparent at the date of practical
completion. The Architect should not issue a Certificate of Practical Completion if there are patent
defects which are not minor in nature.
Clause 15.6 is a contract condition which provides for the Architect to issue the Certificate of
Making Good Defects when the instruction contained in the schedule of defects or given under
Clause 15.5 has been complied with.
The issuance of this certificate is a pre-requisite for the release of the second moiety of the
retention sum. This certification is also one of the events which must have occurred for the
commencement of the period within which the Final Certificate is to be issued.
14
Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective
THE PAM 2006 FORM – With Quantities Edition
CLAUSE 22.0 DAMAGES FOR NON-COMPLETION
Clause 22.1 Liquidated Damages and Certificate of Non-Completion
Clause 22.2 Agreed Liquidated Damages amount
Clause 22.3 Certificate of Non-Completion revoked by subsequent
Certificate of Extension of Time
15
Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective
PAM 2006 Form : Clause 22.0 A Commentary
In almost all construction contracts, time is of the essence. The failure by the Contractor to
complete in time invariably results in the Employer sustaining financial losses including exposure to
claims by third parties like purchases.
Late completion by a Contractor is a breach of contract and damages are the Employer’s remedy.
Damages in the legal lexicon is described as a quantum of money awarded as compensation for a
breach of contract or a tort. Liquidated damages are fixed in advance of the breach and can be
recovered without proof of loss; however the sum fixed ought to be a fair pre-estimate of the likely
consequence of a breach. Liquidated damages may be distinguished from unliquidated or general
damages which are assessed only after the breach and can only be recovered upon proof of
losses.
There are sound commercial reasons for using liquidated damages in construction contracts.
Firstly, because of the certainty they bring to the consequences of breach; and secondly, because
they avoid the expense and dispute involved in proving loss.
Clause 22.0 provides a mechanism whereby the contracting parties can agree in advance as to the
damages payable by the Contractor and recoverable by the Employer if the former fails to
complete the Works by the Date of Completion stated in the Appendix or within any extended
period certified by the Architect under Clause 23.0 – Extension of Time.
The insertion of a specific Date of Completion is a pre-requisite for liquidated damages to be
effected. Utmost care must be exercised in completing the Appendix of the contract and the
English case of Temloc Ltd v Erril Properties Ltd (1987) 39 BLR 30 is an example of the
complications arising from not doing so.
In that case ‘NIL’ was inserted in the Appendix entry for the amount of liquidated damages and the
period over which payment was to be made was left blank. The courts held that this constituted an
agreement that no damages would be payable by the Contractor for late completion and it was not
open to the Employer to claim general damages.
16
Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective
PAM 2006 Form : Clause 22.0 A Commentary
Continuation
However, it would be reasonable to presume that under the PAM 2006 Form, if the Date of
Completion is not inserted in the Appendix, the Employer would be able to recover general
damages by legal action on the basis of his actual proven loss, provided for in common law.
In order for liquidated damages to be effected, there must be failure by the Contractor to achieve
practical completion by the contractual Date for Completion. The damages are computed at the
rate stated in the Appendix and based on the duration from the date of the Certificate of Non-
Completion till the date of the Certificate of Practical Completion.
It is imperative that the Architect perform his duties judiciously, in regard to any warranted
extension of time under Clause 23.0 of the contract provisions. Failure by a Contractor to achieve
practical completion by the Date for Completion, whether it be the original date or one which has
been revised due to time extension being granted, will cause the Architect to issue the Certificate
of Non-Completion.
The Certificate of Non-Completion is a statement of fact by the Architect. He certifies objectively in
writing that in his opinion the Works ought reasonably to have been completed by the Date of
Completion and that the contractor has failed to complete the said Works.
Court decisions are unequivocal in that the Certificate on Non-Completion is a condition precedent
to the deduction of the liquidated damages. Without the said certificate, any deduction by the
Employer will amount to a repudiation of the contract.
17
Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective
THE PAM 2006 FORM – With Quantities Edition
CLAUSE 23.0 EXTENSION OF TIME
Clause 23.1 Submission of notice and particulars for extension of time
Clause 23.2 Delay by Nominated Sub-Contractor
Clause 23.3 Insufficient information
Clause 23.4 Certificate of Extension of Time
Clause 23.5 Other consideration for extension of time
Clause 23.6 Contractor to prevent delay
Clause 23.7 Notification to Nominated Sub-Contractors
Clause 23.8 Relevant Events
Clause 23.9 Extension of time after the issuance of Certificate of Non-
Completion
Clause 23.10 Architect’s review of extension of time after Practical
Completion
18
Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective
PAM 2006 Form : Clause 23.0 A Commentary
Generally, delaying circumstances in the context of a building construction contract can be of three
types. Firstly, delays caused by the Contractor, secondly delays caused by the Employer or his
agents and thirdly delays caused by neutral events.
Clause 23.0 of the PAM 2006 Form allocates these risks of non-completion between the parties. It
reduces the Contractor’s risk in relation to work delays by entitling him to an extension of time on
account of delay based on various specific circumstances.
It is the main provision under which any alteration to the Date of Completion can be made and
refers to an extension of time meaning a lengthening of the period within which the Works have to
be completed.
Clause 23.0 provides for the mechanism for notification of delay by the Contractor and the grant of
extension of time by the Architect on specified grounds. An extension of time is grantable only on
those grounds stipulated under this clause.
The operation of Clause 23.0 modifies the obligation of the Contractor to complete the Works by
the Date for Completion specified in the Appendix and his liability to pay liquidated damages for
late completion. It imposes a duty on the Architect to grant a fair and reasonable extension of time
for completion of the Works, under specified circumstances. In law, the word ‘reasonable’ implies
an objective and careful decision by the Architect. He is required to exercise reasonable skill and
care in arriving at an impartial decision, independently. Neither the Employer nor the Contractor
should interfere or influence the Architect’s decision.
Failure by the architect to judiciously exercise the authority to grant time extension, where any
delay to completion is caused by the Employer or those for whom he is responsible in law, relieves
the Contractor from his liability to pay liquidated damages. Consequently, the time for completion
may becomes ‘at large’ and the Contractor’s contractual obligation would then be to complete the
Works ‘within a reasonable time’.
19
Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective
PAM 2006 Form : Clause 23.0 A Commentary
Continuation
Under the provisions in Clause 23.0 the Contractor is obligated to notify the Architect of events
causing delay. He is required to identity the relevant causes causing the delay, giving particulars of
the expected effect and an estimate of the extension of time required. The notice shall contain
sufficient information and reasons why delay to completion will result. It is an express provision in
the contract that the Contractor substantiate his claims for time extension. The notification of delay
to the Architect, by the Contractor, is a condition precedent to the performance by the Architect of
his duties under the clause.
Upon receipt of the Contractor’s notice, the Architect is to consider granting an extension of time
independantly, based on his knowledge of the progress of the Works and other matters which may
affect or likely to affect its progress.
The Architect should approach his assessment of the Contractor’s time extension claim in a
prudent and methodical manner so as to arrive at a fair and reasonable extension, if so warranted.
Clause 23.6 stipulates that the Contractor shall constantly use his best endeavours to prevent
delay in the progress of the works. Failure of the Contractor to do so is a breach of contract. The
Contractor should take positive steps in order not to breach this term of the contract, which may
include rescheduling the works, revising his methods of working or identifying ways to reduce the
delay.
The cause or causes of delay must fall under the relevant events listed in Clause 23.8, if they are
to qualify for an extension of time. The relevant delaying event is deemed to be outside the
Contractor’s control and which, if it causes delay to completion excuses the Contractor from liability
to liquidated damages.
20
Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective
PAM 2006 Form : Clause 23.0 A Commentary
Continuation
Where the Architect decides that time extension is warranted he must then by written notice to the
Contractor give a fair and reasonable extension of time, by fixing such a later date as the Date for
Completion. The Architect is required to deal comprehensively with extensions of time within the
stipulated time upon receipt of the Contractor’s notice and particulars and fix a new Date for
Completion. The Architect subject to contractual provisions is obliged to give an extension of time
prospectively.
The contract places the onus on the Architect to grant a justifiable extension of time to the
Contractor in a timely manner. The Contractor would need to incorporate the additional time into
his progress schedule and coordinate the remainder of the work. His failure to do so may cause the
Employer to lose the right to extend time, thus putting time ‘at large’ with a consequent loss of the
right to deduct liquidated and ascertained damages.
It should be noted that under Clause 23.10, the Architect has the discretion to fix a new Date for
Completion retrospectively.
21
Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective
THE PAM 2006 FORM – With Quantities Edition
CLAUSE 24.0 LOSS AND/OR EXPENSE CAUSED BY MATTERS
AFFECTING THE REGULAR PROGRESS OF THE
WORKS
Clause 24.1 Loss and/or expense caused by matters affecting the
regular progress of the Works
Clause 24.2 Access to Contractor’s books and documents
Clause 24.3 Matters materially affecting the regular progress of the
Works
Clause 24.4 Loss and/or expense to be included in certificate
22
Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective
PAM 2006 Form : Clause 24.0 A Commentary
It is not uncommon for a Contractor to suffer disturbance in the regular progress of the works due
to causes within the Employer’s or Architect’s control. The main purpose of this contractual clause
is to reimburse the Contractor for any loss and/or expense which he has suffered or incurred as a
direct result of certain specified events.
A claim would be considered valid under this provision, only if regular progress of the works had
been materially affected, as a direct consequence, by one or more of the specified events. A
written application to the Architect by the Contractor, at the relevant time, is a condition precedent
to a successful claim under Clause 24.0.
The Architect may delegate the duty of ascertaining the quantum of loss and/or expense to the
quantity surveyor and in practice this is most often the case. Upon receipt of reasonably sufficient
information pertaining to the claim, from the Contractor, the Architect must undertake the task
within a reasonable time frame. Should the Architect fail to ascertain or instruct the quantity
surveyor to ascertain the amount of loss and/or expense, there would be a breach of contract for
which the Employer may be liable in damages.
Clause 24.0 also stipulates that any amount ascertained under this provision, should be added to
the contract sum and included in the following Interim Certificate.
23
Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective
THE PAM 2006 FORM – With Quantities Edition
CLAUSE 30.0 CERTIFICATES AND PAYMENT
Clause 30.1 Payment application and issuance of Architect’s certificate
Clause 30.2 Amount due in Architect’s certificate
Clause 30.3 Errors in payment certificate
Clause 30.4 Set-off by Employer
Clause 30.5 Retention Fund
Clause 30.6 Rules regarding Retention Fund
Clause 30.7 Suspension of Works for non-payment
Clause 30.8 Compulsory suspension of Works
Clause 30.9 Cessation insurance resulting from suspension of the Works
Clause 30.10 Final Account
Clause 30.11 Items in Final Account
Clause 30.12 Conclusiveness of the Final Account
Clause 30.13 Issuance of Penultimate Certificate
Clause 30.14 Issuance of Final Certificate
Clause 30.15 Final Certificate
Clause 30.16 Final Certificate not conclusive
Clause 30.17 Interest
24
Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective
PAM 2006 Form : Clause 30.0 A Commentary
This contractual clause pertains to all payment certifications under the contract and regulates the
payment mechanism. The issuance of certificates under Clause 30.0 by the Architect is to record
when the Contractor has met a contractual obligation and also imposes contractual obligations in
relation to the transfer or entitlement of monies between the Employer and the Contractor.
The scheme of payment is for Interim Certificates to be issued at regular intervals as stated in the
Appendix; monthly certification is common. The Architect issues the certificates to the Contractor
with a copy to the Employer.
The Architect is permitted to correct any error or discrepancy, or modify any previous certificate
except the Certificate of Practical Completion or the Final Certificate. This is limited to genuine
errors and discrepancies in preparing the certificates and ought not to extend to the Architect’s
change of mind on matters that he has already decided upon.
An eminent English judge, Lord Denning MR in Dawney Ltd v FG Minter Ltd and Others (1971) 1
BLR 16 had stated that there must be cashflow in the building industry and that it is the very
lifeblood of the enterprise and as such an interim payment mechanism should be viewed as of
benefit to both the Contractor and Employer, in reducing the overall risk factor.
The Contractor is required to submit his claim with details and particulars for payment, for the
Architect to certify interim payments. However, even in the absence of a payment claim from the
Contractor, the Architect can certify interim payments.
The Employer has to act, on the copy of the payment certificate, sent to him by the Architect, and
effect payment, on or before the due date. The Contractor’s entitlement to payment is subject to
the Employer’s contractual rights of deduction, for example, liquidated damages under Clause
22.0. Failure to pay by the Employer is a breach of contract.
25
Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective
PAM 2006 Form : Clause 30.0 A Commentary
Continuation
The primary purpose of the issue of Interim Certificates is to ensure that the Contractor receives
regular payments as the work progresses. Interim Certificates are only an approximate valuation of
the work done and the amount in any Interim Certificate is subject to adjustment in subsequent
certificates. The Architects opinion on the state of the works, only becomes conclusive, on the
issuance of the Final Certificate.
The contract provides for the retention of a percentage of the total value of the work, materials and
goods valued. The primary purpose of the retention fund is to afford protection to the Employer, as
a safeguard against defective work.
A time schedule is provided for in the contract with regards to the issuance of the Final Certificate.
The issue of the Final Certificate is mandatory. Failure to issue it within the time and in the manner
specified is a breach of contract for which the Employer, would be liable. On the issuance of the
Final Certificate, the Architect becomes functus officio, that is, his authority under the contract
comes to an end.
The Architect should exercise a high degree of competence and carry out his role as certifier under
Clause 30.0 of the contract in an independent, impartial and fair manner.
26
Conclusion The Architect As Contract Administrator ● A Legal Perspective
Conclusion
The Architect’s professional duties and responsibilities as a contract administrator, are without
doubt onerous in nature. This responsibility must be borne, in order for the Architect to realize the
satisfactory culmination of his architectural designs.
The obligations imposed on the Architect require him to be technically competent in his specialised
field of work and equally importantly, to be of unquestionable rectitude. These attributes will serve
the Architect well and certainly minimise the prospect of professional liability disputes with either of
the contracting parties.
Prudence would dictate that Architects in private practice are covered by professional indemnity
insurance against legal liability for negligent acts, omissions and errors. However, insurance should
not be seen as a universal panacea for protecting the Architect against claims. The adoption and
disciplined adherence to best practices in the Architect’s office would undoubtedly distance its
practitioners from professional liability.
Ar Thurai Das Thuraisingham ■ Das Azman Architects Sdn Bhd
This paper was presented at the Malaysian Institute of Architects, Northern Chapter on 12 Nov 2011

More Related Content

What's hot

Professional practice 2
Professional practice 2Professional practice 2
Professional practice 2
ahmong4
 
Assignment - Tender Documentation (Presentation Slide)
Assignment - Tender Documentation (Presentation Slide)Assignment - Tender Documentation (Presentation Slide)
Assignment - Tender Documentation (Presentation Slide)
Kai Yun Pang
 
Construction lawprint-final-update-21112017
Construction lawprint-final-update-21112017Construction lawprint-final-update-21112017
Construction lawprint-final-update-21112017
DarrenTofu
 
Professional practice 2
Professional practice 2Professional practice 2
Professional practice 2
Shze Hwa Lee
 
Assignment - Final Account
Assignment - Final AccountAssignment - Final Account
Assignment - Final Account
Kai Yun Pang
 
Lecture 4 - selection of contract forms
Lecture 4 - selection of contract formsLecture 4 - selection of contract forms
Lecture 4 - selection of contract forms
kohwenqi
 
Assignment - FIDIC Contract
Assignment - FIDIC ContractAssignment - FIDIC Contract
Assignment - FIDIC Contract
Kai Yun Pang
 
Pp2 p5
Pp2   p5Pp2   p5
Pp2 p5
Shze Hwa Lee
 
Construction contracts docuements_08092008
Construction contracts docuements_08092008Construction contracts docuements_08092008
Construction contracts docuements_08092008
AYM1979
 
Professional Practice 1
Professional Practice 1Professional Practice 1
Professional Practice 1
Lee Pei Gie
 
07 cl-assignment-syafiq-qy-macy-huiyong-deric
07 cl-assignment-syafiq-qy-macy-huiyong-deric07 cl-assignment-syafiq-qy-macy-huiyong-deric
07 cl-assignment-syafiq-qy-macy-huiyong-deric
Syafiq Zariful
 
CL Final Report
CL Final ReportCL Final Report
CL Final Report
Melvin Lim
 
PP1 assignment
PP1 assignment PP1 assignment
PP1 assignment
Enoch Wong
 
Construction Contract in Malaysia
Construction Contract in MalaysiaConstruction Contract in Malaysia
Construction Contract in Malaysia
Dayat Mohamad
 
Pp1 group assignment
Pp1 group assignmentPp1 group assignment
Pp1 group assignment
Pui Chun Shian
 
Professional Practice 1 Assignment
Professional Practice 1 AssignmentProfessional Practice 1 Assignment
Professional Practice 1 Assignment
Melvin Lim
 
Building economics final assignment report
Building economics final assignment reportBuilding economics final assignment report
Building economics final assignment report
lucaschinsheng
 
Fidic comparison red yellow - silver book
Fidic comparison red   yellow - silver bookFidic comparison red   yellow - silver book
Fidic comparison red yellow - silver book
Hani Saad
 

What's hot (20)

Professional practice 2
Professional practice 2Professional practice 2
Professional practice 2
 
Site Possession
Site PossessionSite Possession
Site Possession
 
Assignment - Tender Documentation (Presentation Slide)
Assignment - Tender Documentation (Presentation Slide)Assignment - Tender Documentation (Presentation Slide)
Assignment - Tender Documentation (Presentation Slide)
 
Construction lawprint-final-update-21112017
Construction lawprint-final-update-21112017Construction lawprint-final-update-21112017
Construction lawprint-final-update-21112017
 
Professional practice 2
Professional practice 2Professional practice 2
Professional practice 2
 
Assignment - Final Account
Assignment - Final AccountAssignment - Final Account
Assignment - Final Account
 
Lecture 4 - selection of contract forms
Lecture 4 - selection of contract formsLecture 4 - selection of contract forms
Lecture 4 - selection of contract forms
 
Assignment - FIDIC Contract
Assignment - FIDIC ContractAssignment - FIDIC Contract
Assignment - FIDIC Contract
 
Pp2 p5
Pp2   p5Pp2   p5
Pp2 p5
 
Construction contracts docuements_08092008
Construction contracts docuements_08092008Construction contracts docuements_08092008
Construction contracts docuements_08092008
 
Professional Practice 1
Professional Practice 1Professional Practice 1
Professional Practice 1
 
07 cl-assignment-syafiq-qy-macy-huiyong-deric
07 cl-assignment-syafiq-qy-macy-huiyong-deric07 cl-assignment-syafiq-qy-macy-huiyong-deric
07 cl-assignment-syafiq-qy-macy-huiyong-deric
 
CL Final Report
CL Final ReportCL Final Report
CL Final Report
 
PP1 assignment
PP1 assignment PP1 assignment
PP1 assignment
 
Construction Contract in Malaysia
Construction Contract in MalaysiaConstruction Contract in Malaysia
Construction Contract in Malaysia
 
Defects liability
Defects liabilityDefects liability
Defects liability
 
Pp1 group assignment
Pp1 group assignmentPp1 group assignment
Pp1 group assignment
 
Professional Practice 1 Assignment
Professional Practice 1 AssignmentProfessional Practice 1 Assignment
Professional Practice 1 Assignment
 
Building economics final assignment report
Building economics final assignment reportBuilding economics final assignment report
Building economics final assignment report
 
Fidic comparison red yellow - silver book
Fidic comparison red   yellow - silver bookFidic comparison red   yellow - silver book
Fidic comparison red yellow - silver book
 

Similar to The architect as contract administrator a legal perspective - presentation paper

05 Contract Management.pptx . DEFINITION
05 Contract Management.pptx . DEFINITION05 Contract Management.pptx . DEFINITION
05 Contract Management.pptx . DEFINITION
ByishimoBTCChef
 
Guide for Construction Contract Administrators
Guide for Construction Contract AdministratorsGuide for Construction Contract Administrators
Guide for Construction Contract Administrators
Sarah Fox
 
LEC - 1.ppt most important lecture note and best
LEC - 1.ppt most important lecture note and bestLEC - 1.ppt most important lecture note and best
LEC - 1.ppt most important lecture note and best
2cd
 
Contract
Contract Contract
Contract
Simran Aggarwal
 
Administer Legal Obligations of Construction Contract.docx
Administer Legal Obligations of Construction Contract.docxAdminister Legal Obligations of Construction Contract.docx
Administer Legal Obligations of Construction Contract.docx
Dereje Jima
 
Seminar Presentation Slides (Chapter 2)
Seminar Presentation Slides (Chapter 2)Seminar Presentation Slides (Chapter 2)
Seminar Presentation Slides (Chapter 2)
Melvin Lim
 
Consultant Agreements and the Role of the Consultant
Consultant Agreements and the Role of the ConsultantConsultant Agreements and the Role of the Consultant
Consultant Agreements and the Role of the Consultant
Samantha Ip
 
Construction Contracts Common Interest Developments
Construction Contracts Common Interest DevelopmentsConstruction Contracts Common Interest Developments
Construction Contracts Common Interest DevelopmentsConstruction Cicerone
 
Chapter 5.1 Contracts Management - Contract Administration-owners perspective...
Chapter 5.1 Contracts Management - Contract Administration-owners perspective...Chapter 5.1 Contracts Management - Contract Administration-owners perspective...
Chapter 5.1 Contracts Management - Contract Administration-owners perspective...
ChandanLawrence
 
ARCHITECT Vs ARCHITECT Relations.pptx
ARCHITECT Vs ARCHITECT Relations.pptxARCHITECT Vs ARCHITECT Relations.pptx
ARCHITECT Vs ARCHITECT Relations.pptx
yeabsiramuluken
 
Managing Contractors Effectively 2011
Managing Contractors Effectively 2011Managing Contractors Effectively 2011
Managing Contractors Effectively 2011
Stephen Findlay
 
Understanding The role of The Consultant
Understanding The role of The ConsultantUnderstanding The role of The Consultant
Understanding The role of The Consultant
Harry Gusti Nugroho
 
Construction Law Presentation
Construction Law PresentationConstruction Law Presentation
Construction Law Presentation
elliotfus
 
Architects professional liability
Architects professional liabilityArchitects professional liability
Architects professional liability
Aditi Garg
 
Surety Bonds
Surety BondsSurety Bonds
Surety Bonds
Yajush Sonar
 
The crucial decision of Homebuyers for successful execution of there dream pr...
The crucial decision of Homebuyers for successful execution of there dream pr...The crucial decision of Homebuyers for successful execution of there dream pr...
The crucial decision of Homebuyers for successful execution of there dream pr...
CA. (Dr.) Rajkumar Adukia
 
Effective contract administration may 2014
Effective contract administration may 2014Effective contract administration may 2014
Effective contract administration may 2014
SHKLaw
 
Lecture4construction contract.ppt
Lecture4construction contract.pptLecture4construction contract.ppt
Lecture4construction contract.ppt
IrynaRudnieva
 
Jbcc - out with the old
Jbcc - out with the oldJbcc - out with the old
Jbcc - out with the old
Werksmans Attorneys
 
Professional Practice for Architecture II
Professional Practice for Architecture IIProfessional Practice for Architecture II
Professional Practice for Architecture II
Ar. Mukunda K.S
 

Similar to The architect as contract administrator a legal perspective - presentation paper (20)

05 Contract Management.pptx . DEFINITION
05 Contract Management.pptx . DEFINITION05 Contract Management.pptx . DEFINITION
05 Contract Management.pptx . DEFINITION
 
Guide for Construction Contract Administrators
Guide for Construction Contract AdministratorsGuide for Construction Contract Administrators
Guide for Construction Contract Administrators
 
LEC - 1.ppt most important lecture note and best
LEC - 1.ppt most important lecture note and bestLEC - 1.ppt most important lecture note and best
LEC - 1.ppt most important lecture note and best
 
Contract
Contract Contract
Contract
 
Administer Legal Obligations of Construction Contract.docx
Administer Legal Obligations of Construction Contract.docxAdminister Legal Obligations of Construction Contract.docx
Administer Legal Obligations of Construction Contract.docx
 
Seminar Presentation Slides (Chapter 2)
Seminar Presentation Slides (Chapter 2)Seminar Presentation Slides (Chapter 2)
Seminar Presentation Slides (Chapter 2)
 
Consultant Agreements and the Role of the Consultant
Consultant Agreements and the Role of the ConsultantConsultant Agreements and the Role of the Consultant
Consultant Agreements and the Role of the Consultant
 
Construction Contracts Common Interest Developments
Construction Contracts Common Interest DevelopmentsConstruction Contracts Common Interest Developments
Construction Contracts Common Interest Developments
 
Chapter 5.1 Contracts Management - Contract Administration-owners perspective...
Chapter 5.1 Contracts Management - Contract Administration-owners perspective...Chapter 5.1 Contracts Management - Contract Administration-owners perspective...
Chapter 5.1 Contracts Management - Contract Administration-owners perspective...
 
ARCHITECT Vs ARCHITECT Relations.pptx
ARCHITECT Vs ARCHITECT Relations.pptxARCHITECT Vs ARCHITECT Relations.pptx
ARCHITECT Vs ARCHITECT Relations.pptx
 
Managing Contractors Effectively 2011
Managing Contractors Effectively 2011Managing Contractors Effectively 2011
Managing Contractors Effectively 2011
 
Understanding The role of The Consultant
Understanding The role of The ConsultantUnderstanding The role of The Consultant
Understanding The role of The Consultant
 
Construction Law Presentation
Construction Law PresentationConstruction Law Presentation
Construction Law Presentation
 
Architects professional liability
Architects professional liabilityArchitects professional liability
Architects professional liability
 
Surety Bonds
Surety BondsSurety Bonds
Surety Bonds
 
The crucial decision of Homebuyers for successful execution of there dream pr...
The crucial decision of Homebuyers for successful execution of there dream pr...The crucial decision of Homebuyers for successful execution of there dream pr...
The crucial decision of Homebuyers for successful execution of there dream pr...
 
Effective contract administration may 2014
Effective contract administration may 2014Effective contract administration may 2014
Effective contract administration may 2014
 
Lecture4construction contract.ppt
Lecture4construction contract.pptLecture4construction contract.ppt
Lecture4construction contract.ppt
 
Jbcc - out with the old
Jbcc - out with the oldJbcc - out with the old
Jbcc - out with the old
 
Professional Practice for Architecture II
Professional Practice for Architecture IIProfessional Practice for Architecture II
Professional Practice for Architecture II
 

Recently uploaded

Memorandum Of Association Constitution of Company.ppt
Memorandum Of Association Constitution of Company.pptMemorandum Of Association Constitution of Company.ppt
Memorandum Of Association Constitution of Company.ppt
seri bangash
 
RMD24 | Debunking the non-endemic revenue myth Marvin Vacquier Droop | First ...
RMD24 | Debunking the non-endemic revenue myth Marvin Vacquier Droop | First ...RMD24 | Debunking the non-endemic revenue myth Marvin Vacquier Droop | First ...
RMD24 | Debunking the non-endemic revenue myth Marvin Vacquier Droop | First ...
BBPMedia1
 
Kseniya Leshchenko: Shared development support service model as the way to ma...
Kseniya Leshchenko: Shared development support service model as the way to ma...Kseniya Leshchenko: Shared development support service model as the way to ma...
Kseniya Leshchenko: Shared development support service model as the way to ma...
Lviv Startup Club
 
Cracking the Workplace Discipline Code Main.pptx
Cracking the Workplace Discipline Code Main.pptxCracking the Workplace Discipline Code Main.pptx
Cracking the Workplace Discipline Code Main.pptx
Workforce Group
 
VAT Registration Outlined In UAE: Benefits and Requirements
VAT Registration Outlined In UAE: Benefits and RequirementsVAT Registration Outlined In UAE: Benefits and Requirements
VAT Registration Outlined In UAE: Benefits and Requirements
uae taxgpt
 
BeMetals Presentation_May_22_2024 .pdf
BeMetals Presentation_May_22_2024   .pdfBeMetals Presentation_May_22_2024   .pdf
BeMetals Presentation_May_22_2024 .pdf
DerekIwanaka1
 
Search Disrupted Google’s Leaked Documents Rock the SEO World.pdf
Search Disrupted Google’s Leaked Documents Rock the SEO World.pdfSearch Disrupted Google’s Leaked Documents Rock the SEO World.pdf
Search Disrupted Google’s Leaked Documents Rock the SEO World.pdf
Arihant Webtech Pvt. Ltd
 
ModelingMarketingStrategiesMKS.CollumbiaUniversitypdf
ModelingMarketingStrategiesMKS.CollumbiaUniversitypdfModelingMarketingStrategiesMKS.CollumbiaUniversitypdf
ModelingMarketingStrategiesMKS.CollumbiaUniversitypdf
fisherameliaisabella
 
The-McKinsey-7S-Framework. strategic management
The-McKinsey-7S-Framework. strategic managementThe-McKinsey-7S-Framework. strategic management
The-McKinsey-7S-Framework. strategic management
Bojamma2
 
Unveiling the Secrets How Does Generative AI Work.pdf
Unveiling the Secrets How Does Generative AI Work.pdfUnveiling the Secrets How Does Generative AI Work.pdf
Unveiling the Secrets How Does Generative AI Work.pdf
Sam H
 
Putting the SPARK into Virtual Training.pptx
Putting the SPARK into Virtual Training.pptxPutting the SPARK into Virtual Training.pptx
Putting the SPARK into Virtual Training.pptx
Cynthia Clay
 
The Influence of Marketing Strategy and Market Competition on Business Perfor...
The Influence of Marketing Strategy and Market Competition on Business Perfor...The Influence of Marketing Strategy and Market Competition on Business Perfor...
The Influence of Marketing Strategy and Market Competition on Business Perfor...
Adam Smith
 
ENTREPRENEURSHIP TRAINING.ppt for graduating class (1).ppt
ENTREPRENEURSHIP TRAINING.ppt for graduating class (1).pptENTREPRENEURSHIP TRAINING.ppt for graduating class (1).ppt
ENTREPRENEURSHIP TRAINING.ppt for graduating class (1).ppt
zechu97
 
Tata Group Dials Taiwan for Its Chipmaking Ambition in Gujarat’s Dholera
Tata Group Dials Taiwan for Its Chipmaking Ambition in Gujarat’s DholeraTata Group Dials Taiwan for Its Chipmaking Ambition in Gujarat’s Dholera
Tata Group Dials Taiwan for Its Chipmaking Ambition in Gujarat’s Dholera
Avirahi City Dholera
 
April 2024 Nostalgia Products Newsletter
April 2024 Nostalgia Products NewsletterApril 2024 Nostalgia Products Newsletter
April 2024 Nostalgia Products Newsletter
NathanBaughman3
 
LA HUG - Video Testimonials with Chynna Morgan - June 2024
LA HUG - Video Testimonials with Chynna Morgan - June 2024LA HUG - Video Testimonials with Chynna Morgan - June 2024
LA HUG - Video Testimonials with Chynna Morgan - June 2024
Lital Barkan
 
CADAVER AS OUR FIRST TEACHER anatomt in your.pptx
CADAVER AS OUR FIRST TEACHER anatomt in your.pptxCADAVER AS OUR FIRST TEACHER anatomt in your.pptx
CADAVER AS OUR FIRST TEACHER anatomt in your.pptx
fakeloginn69
 
Affordable Stationery Printing Services in Jaipur | Navpack n Print
Affordable Stationery Printing Services in Jaipur | Navpack n PrintAffordable Stationery Printing Services in Jaipur | Navpack n Print
Affordable Stationery Printing Services in Jaipur | Navpack n Print
Navpack & Print
 
Maksym Vyshnivetskyi: PMO Quality Management (UA)
Maksym Vyshnivetskyi: PMO Quality Management (UA)Maksym Vyshnivetskyi: PMO Quality Management (UA)
Maksym Vyshnivetskyi: PMO Quality Management (UA)
Lviv Startup Club
 
Business Valuation Principles for Entrepreneurs
Business Valuation Principles for EntrepreneursBusiness Valuation Principles for Entrepreneurs
Business Valuation Principles for Entrepreneurs
Ben Wann
 

Recently uploaded (20)

Memorandum Of Association Constitution of Company.ppt
Memorandum Of Association Constitution of Company.pptMemorandum Of Association Constitution of Company.ppt
Memorandum Of Association Constitution of Company.ppt
 
RMD24 | Debunking the non-endemic revenue myth Marvin Vacquier Droop | First ...
RMD24 | Debunking the non-endemic revenue myth Marvin Vacquier Droop | First ...RMD24 | Debunking the non-endemic revenue myth Marvin Vacquier Droop | First ...
RMD24 | Debunking the non-endemic revenue myth Marvin Vacquier Droop | First ...
 
Kseniya Leshchenko: Shared development support service model as the way to ma...
Kseniya Leshchenko: Shared development support service model as the way to ma...Kseniya Leshchenko: Shared development support service model as the way to ma...
Kseniya Leshchenko: Shared development support service model as the way to ma...
 
Cracking the Workplace Discipline Code Main.pptx
Cracking the Workplace Discipline Code Main.pptxCracking the Workplace Discipline Code Main.pptx
Cracking the Workplace Discipline Code Main.pptx
 
VAT Registration Outlined In UAE: Benefits and Requirements
VAT Registration Outlined In UAE: Benefits and RequirementsVAT Registration Outlined In UAE: Benefits and Requirements
VAT Registration Outlined In UAE: Benefits and Requirements
 
BeMetals Presentation_May_22_2024 .pdf
BeMetals Presentation_May_22_2024   .pdfBeMetals Presentation_May_22_2024   .pdf
BeMetals Presentation_May_22_2024 .pdf
 
Search Disrupted Google’s Leaked Documents Rock the SEO World.pdf
Search Disrupted Google’s Leaked Documents Rock the SEO World.pdfSearch Disrupted Google’s Leaked Documents Rock the SEO World.pdf
Search Disrupted Google’s Leaked Documents Rock the SEO World.pdf
 
ModelingMarketingStrategiesMKS.CollumbiaUniversitypdf
ModelingMarketingStrategiesMKS.CollumbiaUniversitypdfModelingMarketingStrategiesMKS.CollumbiaUniversitypdf
ModelingMarketingStrategiesMKS.CollumbiaUniversitypdf
 
The-McKinsey-7S-Framework. strategic management
The-McKinsey-7S-Framework. strategic managementThe-McKinsey-7S-Framework. strategic management
The-McKinsey-7S-Framework. strategic management
 
Unveiling the Secrets How Does Generative AI Work.pdf
Unveiling the Secrets How Does Generative AI Work.pdfUnveiling the Secrets How Does Generative AI Work.pdf
Unveiling the Secrets How Does Generative AI Work.pdf
 
Putting the SPARK into Virtual Training.pptx
Putting the SPARK into Virtual Training.pptxPutting the SPARK into Virtual Training.pptx
Putting the SPARK into Virtual Training.pptx
 
The Influence of Marketing Strategy and Market Competition on Business Perfor...
The Influence of Marketing Strategy and Market Competition on Business Perfor...The Influence of Marketing Strategy and Market Competition on Business Perfor...
The Influence of Marketing Strategy and Market Competition on Business Perfor...
 
ENTREPRENEURSHIP TRAINING.ppt for graduating class (1).ppt
ENTREPRENEURSHIP TRAINING.ppt for graduating class (1).pptENTREPRENEURSHIP TRAINING.ppt for graduating class (1).ppt
ENTREPRENEURSHIP TRAINING.ppt for graduating class (1).ppt
 
Tata Group Dials Taiwan for Its Chipmaking Ambition in Gujarat’s Dholera
Tata Group Dials Taiwan for Its Chipmaking Ambition in Gujarat’s DholeraTata Group Dials Taiwan for Its Chipmaking Ambition in Gujarat’s Dholera
Tata Group Dials Taiwan for Its Chipmaking Ambition in Gujarat’s Dholera
 
April 2024 Nostalgia Products Newsletter
April 2024 Nostalgia Products NewsletterApril 2024 Nostalgia Products Newsletter
April 2024 Nostalgia Products Newsletter
 
LA HUG - Video Testimonials with Chynna Morgan - June 2024
LA HUG - Video Testimonials with Chynna Morgan - June 2024LA HUG - Video Testimonials with Chynna Morgan - June 2024
LA HUG - Video Testimonials with Chynna Morgan - June 2024
 
CADAVER AS OUR FIRST TEACHER anatomt in your.pptx
CADAVER AS OUR FIRST TEACHER anatomt in your.pptxCADAVER AS OUR FIRST TEACHER anatomt in your.pptx
CADAVER AS OUR FIRST TEACHER anatomt in your.pptx
 
Affordable Stationery Printing Services in Jaipur | Navpack n Print
Affordable Stationery Printing Services in Jaipur | Navpack n PrintAffordable Stationery Printing Services in Jaipur | Navpack n Print
Affordable Stationery Printing Services in Jaipur | Navpack n Print
 
Maksym Vyshnivetskyi: PMO Quality Management (UA)
Maksym Vyshnivetskyi: PMO Quality Management (UA)Maksym Vyshnivetskyi: PMO Quality Management (UA)
Maksym Vyshnivetskyi: PMO Quality Management (UA)
 
Business Valuation Principles for Entrepreneurs
Business Valuation Principles for EntrepreneursBusiness Valuation Principles for Entrepreneurs
Business Valuation Principles for Entrepreneurs
 

The architect as contract administrator a legal perspective - presentation paper

  • 1. The Architect as Contract Administrator DAS AZMAN ARCHITECTS SDN BHD A Legal Perspective Ar. THURAI DAS THURAISINGHAM 1 2 N o v e m b e r 2 0 1 1
  • 2. 1 An overview The Architect As Contract Administrator ● A Legal Perspective Contents ● An Overview ● Architect’s Work Scope ● The Building Contract ● Architect – An Independant Certifier ● Specific Contractual Clauses – PAM 2006 Form ● Conclusion
  • 3. 2 An overview The Architect As Contract Administrator ● A Legal Perspective Sources of Law ● Federal and State Constitutions ● Statutes eg. - Contracts Act 1950 - Architects Act 1967 - Street, Drainage And Building Act 1974 ● Common Law - Judicial decisions made by the Courts ● Regulations of Administrative Agencies eg. - Board of Architects - Architects (Scale of Minimum Fees) Rules 2010. ● Rules of Equity Classification of Law Law pertaining to the practice of architecture Civil Law : Private law dealing with the rights and obligations of individuals and corporations in their dealing with each other. eg. Law of Contract Law of Tort Administrative Law : Legislation at the federal, state and local levels establishes and enhances building codes and regulations. Designed to protect the health, safety and welfare of the public.
  • 4. 3 An overview The Architect As Contract Administrator ● A Legal Perspective Law of Contract Concerns the legally binding rights and obligations of parties who have made an agreement for a specific purpose. Law of Tort A tort is a wrong done by one party to another for which a remedy such as compensation or an injunction may be sought in the courts. Specific Torts eg. Negligence Defamation Trespass. The Architect’s Liability The Architect’s legal obligations and responsibilities are owed to a variety of parties, and are governed by statutes, administrative regulations and common law. Two areas of specific concern are, Breach of Contract Negligence
  • 5. 4 An overview The Architect As Contract Administrator ● A Legal Perspective Breach of Contract The Architect enters into a contractual relationship with the client to perform specific services. (architectural consultancy) There is an implied agreement to carry out the required work to the standard expected of the profession. Failure to meet these standards, which cause extra expense or delays for the owner, may result in a claim for damages against the Architect on the grounds of breach of contract. Negligence Apart from any contractual obligations which may have been agreed upon, a duty or standard of care under the law of tort may exist. If a person fails in this duty, a negligence suit could succeed.
  • 6. 5 Architect’s Work Scope The Architect As Contract Administrator ● A Legal Perspective CLIENT / ARCHITECT AGREEMENT ARCHITECT’S SCOPE OF WORKS Schematic Design Phase Design Development Phase Tender Documentation Phase Contract Implementation & Management Phase CONTRACT IMPLEMENTATION AND MANAGEMENT PHASE ARCHITECT’S PROFESSIONAL DUTIES CLIENT CONTRACTOR & EMPLOYER Defined By CLIENT / ARCHITECT AGREEMENT Defined By BUILDING CONTRACT
  • 7. 6 The Building Contract The Architect As Contract Administrator ● A Legal Perspective The Building Contract The building contract in reference, in this paper, is the PAM 2006 Form – With Quantities edition. This is a contract for a lump sum which requires the Contractor to complete the work comprised in it for an ascertained and specified sum, subject to it being increased or diminished, by taking into consideration the value of variation additions and omissions made in accordance with the contract. The PAM 2006 Form must be read in conjunction with the general corpus of the law of contract. A standard form, in itself, will not be self-sufficient nor self-contained, in incorporating all the rights and obligations of the contracting parties. As such, it must be read and understood in light of the general law and in particular that part of the law governing contractual relationships. Article 3 of the Articles of Agreement of the PAM 2006 Form, provides for the designation of an Architect registered with the Board of Architects Malaysia. Under Article 3, the Employer has a duty to appoint the Architect. The named Architect, engaged by the Employer is thus entrusted with the administration and supervision of the building contract.
  • 8. 7 Architect – An Independent Certifier The Architect As Contract Administrator ● A Legal Perspective Architect – An Independant Certifier The Architect, engaged by the Employer, acts as his agent for the purpose of securing the completion of the works, in an economical and timely manner. Under the PAM 2006 Form, the Architect is the contract administrator, whilst at the same time, under this phase he continues to be the Employer’s agent. In his capacity as contract administrator and an agent of the Employer the Architect, amongst others, provides information to the Contractor to enable him to carry out his contractual works, issues variation orders which may alter the extent, nature and quantity of the works, nominates sub-contractors and suppliers on the Employer’s behalf, supervises and approves the works. In his capacity as contract administrator and independent certifier, it is the Architects’ duty to issue certifications on all payments due under the contract and to certify acceptance of completed works in conformity to contract specifications and accepted standards. The contract administrator must act with independence, impartiality and fairness. The professional obligation to act fairly extends to such of his duties as require him to use his professional skill and judgement in forming an opinion or making a decision where he is holding the balance between his Client and the Contractor.
  • 9. 8 Architect – An Independent Certifier The Architect As Contract Administrator ● A Legal Perspective Architect – An Independant Certifier Continuation The Architect is duty bound to serve the Employer faithfully as his agent. The Employer would reasonably expect that the Architect possesses the requisite ability and skill, and the latter, by holding himself out as an Architect, impliedly warrants that he possesses such attributes. An Architect would be liable to the Employer if he had been professionally negligent. Breach of a professional persons obligations to his Client is generally referred to as professional negligence. For liability to be established it must be proven that the Architect had failed to exercise the standard of care required and that the negligence alleged is a matter of substance. Not every careless act or fault of an Architect gives rise to liability in negligence, even where damage is sustained by another as a result. In order to establish a claim in negligence, the law makes it necessary for a claimant to satisfy the following requirements :- o The existence in law of a duty of care. o Professional conduct that falls below the standard of care imposed by law. o A causal connection between the defendant’s conduct and the damage. o Damage falling within the scope of the duty.
  • 10. 9 Architect – An Independent Certifier The Architect As Contract Administrator ● A Legal Perspective Architect – An Independant Certifier Continuation In a situation where special skill or competence is involved, then the test as to whether there has been negligence or not, is measured against the standard of the ordinary skilled man exercising and professing to have that skill. The normal measure of an Architect’s skill is that of ordinary skilled Architects. An error of judgement may or may not amount to negligence. A good defence against a negligence complaint is one where the Architect can show that he acted in accord with general and approved practice. The seminal English case of Sutcliff v Thackrah (1974) AC 727 deemed that the Architect is liable in damages if he causes loss to his Employer by failure to take due care or to exercise reasonable professional skill in carrying out his duties. It would be a reasonable expectation on the Client’s part, that the Architect will perform his duties under the contract, in such a manner as to safeguard his interests and that he will do all that is reasonably within his power to ensure that the work is satisfactorily and expeditiously undertaken, so as to achieve the objective as contemplated by the contract. It naturally flows from this expectation that the Architect will administer the contract and supervise the work, so as to ensure, as far as is reasonably possible, that the quality of work, is as specified in the contract. The Architect must provide reasonable supervision to the works, not only in compliance with statutory provisions, but also to enable him to issue certifications under the contract that the work has been satisfactorily carried out in accordance with contract drawings and specifications. He is not required personally to measure or check every detail, but should check substantial and critical aspects of the work. It is altogether imperative that qualified supervisory personnel are stationed at the construction site, to assist the Architect in his supervision of the works.
  • 11. 10 Architect – An Independent Certifier The Architect As Contract Administrator ● A Legal Perspective Architect – An Independant Certifier Continuation In the administration of the building contract, the importance of the Architect’s impartiality in his role as an independent certifier, cannot be over – emphasised. The basic premise underpinning the system of payment arrangements in construction contracts is the integrity of the certification machinery. The Architect must exercise his function as the certifier in good faith and to the best of his uninfluenced professional judgement, eventhough he is appointed by the Employer. It is settled law that an Architect, in exercising his function as a certifier under a building contract has to act fairly and independently and should not be subject to the directions or instructions of either the Employer nor the Contractor. Needless to say, an Architect should never allow the Employer improperly to influence his decisions nor should the Employer prevent the independent exercise of the Architect’s authority as certifier. The Architects decisions and certificates bind both the Employer and the Contractor. Improper or negligent certification may result in the Contractor suffering financial losses. This could arise where the Architect under – certifies the Interim Payment Certificates and Final Certificates, certifies late or fails to certify them at all, or when he does not certify the Certificate of Practical Completion or Certificate of Making Good Defects, or certifies them late, or he issues the Certificate of Non- Completion erroneously causing the Employer to deduct monies from sums otherwise due to the Contractor. The Contractor’s contractual remedy in such situations is by way of reference to arbitration, as provided for under Clause 34.0 of the PAM 2006 Form. There have been cases where an aggrieved Contractor has sued the Architect in tort for negligent certification. The question here is whether an Architect owed a duty of care to the Contractor in the issuance of certificates under the building contract. Based on recent case law, it would seem unlikely that a contractor, under a building contract which provides for arbitration, could successfully bring a claim in tort against the Architect for negligent certification.
  • 12. 11 Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective THE PAM 2006 FORM – With Quantities Edition CLAUSE 15.0 PRACTICAL COMPLETION AND DEFECTS LIABILITY Clause 15.1 Practical Completion Clause 15.2 Certificate of Practical Completion Clause 15.3 Contractor’s failure to comply with undertaking Clause 15.4 Schedule of Defects Clause 15.5 Instruction to make good Defects Clause 15.6 Certificate of Making Good Defects
  • 13. 12 Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective PAM 2006 Form : Clause 15.0 A Commentary The term ‘practical completion’ is not explicitly defined in Clause 15.1 of the conditions of contract. It is stipulated amongst others, that for the issuance of the Certificate of Practical Completion, in the opinion of the Architect, the Employer can have full use of the Works for their intended purposes, notwithstanding that there may be works and defects of a minor nature still to be executed. There have been conflicting court decisions, as can be seen in the English cases of Westminster City Council v Jarvis & Sons Ltd (1970) 7 BLR 64 and P&M Kaye LTD v Hosier & Dickinson Ltd (1972) 1 WLR 146, as to what constitutes practical completion in the context of the JCT 1963 Form. The latter case takes a rather expedient view that it would be unrealistic to take practical completion to mean completion down to the last detail. This could be interpreted to mean that if the Works reach a state of readiness for use or occupation by the employer, then they would be considered to be practically complete. The earlier case of Westminster City Council v Jarvis & Sons Ltd (1970) 7 BLR 64 takes a strict view that all patent defects are to be remedied before the issuance of the CPC. Practical completion is construed to be completion for all practical purposes when the contractor has performed all the contractual works except for very minor ‘de minimis’ work and there are no patent defects in the Works. In the case of HW Nevill (Sunblest) Ltd v William Press & Son Ltd (1981) 20 BLR 78 it was held that the Architect would have a discretion to certify practical completion when very minor ‘de minimis’ works had not been carried out, but if there are any patent defects then the architect cannot issue a certificate of practical completion.
  • 14. 13 Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective PAM 2006 Form : Clause 15.0 A Commentary Continuation To state the obvious, the Certificate of Practical Completion is a highly significant document with major contractual implications. The Architect in the administration of the contract is here called upon to exercise his professional judgement on whether the Works are practically complete or otherwise. The exercise of judgement should be done in a responsible, prudent and impartial manner. Specifically, the architect is to determine whether the very minor works left incomplete or that which needs to be remedied is to be deemed as ‘de minimis’ in which case he would issue the Certificate of Practical Completion. Based on the stipulations in the PAM 2006 Form it would be reasonable to issue the Certificate of Practical Completion only when all contractual works have been completed in accordance with contract drawings and specifications. The only exception to this condition would be incomplete or remedial works of a very minor nature and defects which are not apparent at the date of practical completion. The Architect should not issue a Certificate of Practical Completion if there are patent defects which are not minor in nature. Clause 15.6 is a contract condition which provides for the Architect to issue the Certificate of Making Good Defects when the instruction contained in the schedule of defects or given under Clause 15.5 has been complied with. The issuance of this certificate is a pre-requisite for the release of the second moiety of the retention sum. This certification is also one of the events which must have occurred for the commencement of the period within which the Final Certificate is to be issued.
  • 15. 14 Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective THE PAM 2006 FORM – With Quantities Edition CLAUSE 22.0 DAMAGES FOR NON-COMPLETION Clause 22.1 Liquidated Damages and Certificate of Non-Completion Clause 22.2 Agreed Liquidated Damages amount Clause 22.3 Certificate of Non-Completion revoked by subsequent Certificate of Extension of Time
  • 16. 15 Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective PAM 2006 Form : Clause 22.0 A Commentary In almost all construction contracts, time is of the essence. The failure by the Contractor to complete in time invariably results in the Employer sustaining financial losses including exposure to claims by third parties like purchases. Late completion by a Contractor is a breach of contract and damages are the Employer’s remedy. Damages in the legal lexicon is described as a quantum of money awarded as compensation for a breach of contract or a tort. Liquidated damages are fixed in advance of the breach and can be recovered without proof of loss; however the sum fixed ought to be a fair pre-estimate of the likely consequence of a breach. Liquidated damages may be distinguished from unliquidated or general damages which are assessed only after the breach and can only be recovered upon proof of losses. There are sound commercial reasons for using liquidated damages in construction contracts. Firstly, because of the certainty they bring to the consequences of breach; and secondly, because they avoid the expense and dispute involved in proving loss. Clause 22.0 provides a mechanism whereby the contracting parties can agree in advance as to the damages payable by the Contractor and recoverable by the Employer if the former fails to complete the Works by the Date of Completion stated in the Appendix or within any extended period certified by the Architect under Clause 23.0 – Extension of Time. The insertion of a specific Date of Completion is a pre-requisite for liquidated damages to be effected. Utmost care must be exercised in completing the Appendix of the contract and the English case of Temloc Ltd v Erril Properties Ltd (1987) 39 BLR 30 is an example of the complications arising from not doing so. In that case ‘NIL’ was inserted in the Appendix entry for the amount of liquidated damages and the period over which payment was to be made was left blank. The courts held that this constituted an agreement that no damages would be payable by the Contractor for late completion and it was not open to the Employer to claim general damages.
  • 17. 16 Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective PAM 2006 Form : Clause 22.0 A Commentary Continuation However, it would be reasonable to presume that under the PAM 2006 Form, if the Date of Completion is not inserted in the Appendix, the Employer would be able to recover general damages by legal action on the basis of his actual proven loss, provided for in common law. In order for liquidated damages to be effected, there must be failure by the Contractor to achieve practical completion by the contractual Date for Completion. The damages are computed at the rate stated in the Appendix and based on the duration from the date of the Certificate of Non- Completion till the date of the Certificate of Practical Completion. It is imperative that the Architect perform his duties judiciously, in regard to any warranted extension of time under Clause 23.0 of the contract provisions. Failure by a Contractor to achieve practical completion by the Date for Completion, whether it be the original date or one which has been revised due to time extension being granted, will cause the Architect to issue the Certificate of Non-Completion. The Certificate of Non-Completion is a statement of fact by the Architect. He certifies objectively in writing that in his opinion the Works ought reasonably to have been completed by the Date of Completion and that the contractor has failed to complete the said Works. Court decisions are unequivocal in that the Certificate on Non-Completion is a condition precedent to the deduction of the liquidated damages. Without the said certificate, any deduction by the Employer will amount to a repudiation of the contract.
  • 18. 17 Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective THE PAM 2006 FORM – With Quantities Edition CLAUSE 23.0 EXTENSION OF TIME Clause 23.1 Submission of notice and particulars for extension of time Clause 23.2 Delay by Nominated Sub-Contractor Clause 23.3 Insufficient information Clause 23.4 Certificate of Extension of Time Clause 23.5 Other consideration for extension of time Clause 23.6 Contractor to prevent delay Clause 23.7 Notification to Nominated Sub-Contractors Clause 23.8 Relevant Events Clause 23.9 Extension of time after the issuance of Certificate of Non- Completion Clause 23.10 Architect’s review of extension of time after Practical Completion
  • 19. 18 Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective PAM 2006 Form : Clause 23.0 A Commentary Generally, delaying circumstances in the context of a building construction contract can be of three types. Firstly, delays caused by the Contractor, secondly delays caused by the Employer or his agents and thirdly delays caused by neutral events. Clause 23.0 of the PAM 2006 Form allocates these risks of non-completion between the parties. It reduces the Contractor’s risk in relation to work delays by entitling him to an extension of time on account of delay based on various specific circumstances. It is the main provision under which any alteration to the Date of Completion can be made and refers to an extension of time meaning a lengthening of the period within which the Works have to be completed. Clause 23.0 provides for the mechanism for notification of delay by the Contractor and the grant of extension of time by the Architect on specified grounds. An extension of time is grantable only on those grounds stipulated under this clause. The operation of Clause 23.0 modifies the obligation of the Contractor to complete the Works by the Date for Completion specified in the Appendix and his liability to pay liquidated damages for late completion. It imposes a duty on the Architect to grant a fair and reasonable extension of time for completion of the Works, under specified circumstances. In law, the word ‘reasonable’ implies an objective and careful decision by the Architect. He is required to exercise reasonable skill and care in arriving at an impartial decision, independently. Neither the Employer nor the Contractor should interfere or influence the Architect’s decision. Failure by the architect to judiciously exercise the authority to grant time extension, where any delay to completion is caused by the Employer or those for whom he is responsible in law, relieves the Contractor from his liability to pay liquidated damages. Consequently, the time for completion may becomes ‘at large’ and the Contractor’s contractual obligation would then be to complete the Works ‘within a reasonable time’.
  • 20. 19 Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective PAM 2006 Form : Clause 23.0 A Commentary Continuation Under the provisions in Clause 23.0 the Contractor is obligated to notify the Architect of events causing delay. He is required to identity the relevant causes causing the delay, giving particulars of the expected effect and an estimate of the extension of time required. The notice shall contain sufficient information and reasons why delay to completion will result. It is an express provision in the contract that the Contractor substantiate his claims for time extension. The notification of delay to the Architect, by the Contractor, is a condition precedent to the performance by the Architect of his duties under the clause. Upon receipt of the Contractor’s notice, the Architect is to consider granting an extension of time independantly, based on his knowledge of the progress of the Works and other matters which may affect or likely to affect its progress. The Architect should approach his assessment of the Contractor’s time extension claim in a prudent and methodical manner so as to arrive at a fair and reasonable extension, if so warranted. Clause 23.6 stipulates that the Contractor shall constantly use his best endeavours to prevent delay in the progress of the works. Failure of the Contractor to do so is a breach of contract. The Contractor should take positive steps in order not to breach this term of the contract, which may include rescheduling the works, revising his methods of working or identifying ways to reduce the delay. The cause or causes of delay must fall under the relevant events listed in Clause 23.8, if they are to qualify for an extension of time. The relevant delaying event is deemed to be outside the Contractor’s control and which, if it causes delay to completion excuses the Contractor from liability to liquidated damages.
  • 21. 20 Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective PAM 2006 Form : Clause 23.0 A Commentary Continuation Where the Architect decides that time extension is warranted he must then by written notice to the Contractor give a fair and reasonable extension of time, by fixing such a later date as the Date for Completion. The Architect is required to deal comprehensively with extensions of time within the stipulated time upon receipt of the Contractor’s notice and particulars and fix a new Date for Completion. The Architect subject to contractual provisions is obliged to give an extension of time prospectively. The contract places the onus on the Architect to grant a justifiable extension of time to the Contractor in a timely manner. The Contractor would need to incorporate the additional time into his progress schedule and coordinate the remainder of the work. His failure to do so may cause the Employer to lose the right to extend time, thus putting time ‘at large’ with a consequent loss of the right to deduct liquidated and ascertained damages. It should be noted that under Clause 23.10, the Architect has the discretion to fix a new Date for Completion retrospectively.
  • 22. 21 Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective THE PAM 2006 FORM – With Quantities Edition CLAUSE 24.0 LOSS AND/OR EXPENSE CAUSED BY MATTERS AFFECTING THE REGULAR PROGRESS OF THE WORKS Clause 24.1 Loss and/or expense caused by matters affecting the regular progress of the Works Clause 24.2 Access to Contractor’s books and documents Clause 24.3 Matters materially affecting the regular progress of the Works Clause 24.4 Loss and/or expense to be included in certificate
  • 23. 22 Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective PAM 2006 Form : Clause 24.0 A Commentary It is not uncommon for a Contractor to suffer disturbance in the regular progress of the works due to causes within the Employer’s or Architect’s control. The main purpose of this contractual clause is to reimburse the Contractor for any loss and/or expense which he has suffered or incurred as a direct result of certain specified events. A claim would be considered valid under this provision, only if regular progress of the works had been materially affected, as a direct consequence, by one or more of the specified events. A written application to the Architect by the Contractor, at the relevant time, is a condition precedent to a successful claim under Clause 24.0. The Architect may delegate the duty of ascertaining the quantum of loss and/or expense to the quantity surveyor and in practice this is most often the case. Upon receipt of reasonably sufficient information pertaining to the claim, from the Contractor, the Architect must undertake the task within a reasonable time frame. Should the Architect fail to ascertain or instruct the quantity surveyor to ascertain the amount of loss and/or expense, there would be a breach of contract for which the Employer may be liable in damages. Clause 24.0 also stipulates that any amount ascertained under this provision, should be added to the contract sum and included in the following Interim Certificate.
  • 24. 23 Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective THE PAM 2006 FORM – With Quantities Edition CLAUSE 30.0 CERTIFICATES AND PAYMENT Clause 30.1 Payment application and issuance of Architect’s certificate Clause 30.2 Amount due in Architect’s certificate Clause 30.3 Errors in payment certificate Clause 30.4 Set-off by Employer Clause 30.5 Retention Fund Clause 30.6 Rules regarding Retention Fund Clause 30.7 Suspension of Works for non-payment Clause 30.8 Compulsory suspension of Works Clause 30.9 Cessation insurance resulting from suspension of the Works Clause 30.10 Final Account Clause 30.11 Items in Final Account Clause 30.12 Conclusiveness of the Final Account Clause 30.13 Issuance of Penultimate Certificate Clause 30.14 Issuance of Final Certificate Clause 30.15 Final Certificate Clause 30.16 Final Certificate not conclusive Clause 30.17 Interest
  • 25. 24 Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective PAM 2006 Form : Clause 30.0 A Commentary This contractual clause pertains to all payment certifications under the contract and regulates the payment mechanism. The issuance of certificates under Clause 30.0 by the Architect is to record when the Contractor has met a contractual obligation and also imposes contractual obligations in relation to the transfer or entitlement of monies between the Employer and the Contractor. The scheme of payment is for Interim Certificates to be issued at regular intervals as stated in the Appendix; monthly certification is common. The Architect issues the certificates to the Contractor with a copy to the Employer. The Architect is permitted to correct any error or discrepancy, or modify any previous certificate except the Certificate of Practical Completion or the Final Certificate. This is limited to genuine errors and discrepancies in preparing the certificates and ought not to extend to the Architect’s change of mind on matters that he has already decided upon. An eminent English judge, Lord Denning MR in Dawney Ltd v FG Minter Ltd and Others (1971) 1 BLR 16 had stated that there must be cashflow in the building industry and that it is the very lifeblood of the enterprise and as such an interim payment mechanism should be viewed as of benefit to both the Contractor and Employer, in reducing the overall risk factor. The Contractor is required to submit his claim with details and particulars for payment, for the Architect to certify interim payments. However, even in the absence of a payment claim from the Contractor, the Architect can certify interim payments. The Employer has to act, on the copy of the payment certificate, sent to him by the Architect, and effect payment, on or before the due date. The Contractor’s entitlement to payment is subject to the Employer’s contractual rights of deduction, for example, liquidated damages under Clause 22.0. Failure to pay by the Employer is a breach of contract.
  • 26. 25 Specific Contractual Clauses – PAM 2006 Form The Architect As Contract Administrator ● A Legal Perspective PAM 2006 Form : Clause 30.0 A Commentary Continuation The primary purpose of the issue of Interim Certificates is to ensure that the Contractor receives regular payments as the work progresses. Interim Certificates are only an approximate valuation of the work done and the amount in any Interim Certificate is subject to adjustment in subsequent certificates. The Architects opinion on the state of the works, only becomes conclusive, on the issuance of the Final Certificate. The contract provides for the retention of a percentage of the total value of the work, materials and goods valued. The primary purpose of the retention fund is to afford protection to the Employer, as a safeguard against defective work. A time schedule is provided for in the contract with regards to the issuance of the Final Certificate. The issue of the Final Certificate is mandatory. Failure to issue it within the time and in the manner specified is a breach of contract for which the Employer, would be liable. On the issuance of the Final Certificate, the Architect becomes functus officio, that is, his authority under the contract comes to an end. The Architect should exercise a high degree of competence and carry out his role as certifier under Clause 30.0 of the contract in an independent, impartial and fair manner.
  • 27. 26 Conclusion The Architect As Contract Administrator ● A Legal Perspective Conclusion The Architect’s professional duties and responsibilities as a contract administrator, are without doubt onerous in nature. This responsibility must be borne, in order for the Architect to realize the satisfactory culmination of his architectural designs. The obligations imposed on the Architect require him to be technically competent in his specialised field of work and equally importantly, to be of unquestionable rectitude. These attributes will serve the Architect well and certainly minimise the prospect of professional liability disputes with either of the contracting parties. Prudence would dictate that Architects in private practice are covered by professional indemnity insurance against legal liability for negligent acts, omissions and errors. However, insurance should not be seen as a universal panacea for protecting the Architect against claims. The adoption and disciplined adherence to best practices in the Architect’s office would undoubtedly distance its practitioners from professional liability. Ar Thurai Das Thuraisingham ■ Das Azman Architects Sdn Bhd This paper was presented at the Malaysian Institute of Architects, Northern Chapter on 12 Nov 2011