This document discusses proposed measures to eliminate delays in land acquisition for highway projects in India. It analyzes reasons for delays such as high compensation rates, many arbitration cases, and issues with land records. It outlines the land acquisition process and provides data on acquisition status for ongoing projects. Recommendations include amending the National Highways Act, strengthening resources for land acquisition, and expediting forest and environmental clearances. Regular monitoring meetings and decentralizing approval powers are also proposed to speed up the land acquisition process.
Land Acquisition, Rehabilitation and Resettlement Act, 2013 (also Land Acquisition Act, 2013) is an Act of Indian Parliament that regulates land acquisition and lays down the procedure and rules for granting compensation, rehabilitation and resettlement to the affected
Planning Laws - Its Implications for Urban Development JIT KUMAR GUPTA
Paper tries to analyse the role and importance of legal framework in the context of urban development and the need to make urban laws more rational, simple and supportive of the urban development.
THE REAL ESTATE (REGULATION AND DEVELOPMENT) ACT, 2016Narmdeshwar Singh
This is a presentation on the new Real Estate Act, 2016 which after a long 9 years came into force. It is considered to be consumer concentric Act enabling the consumers to enforce their rights smoothly under the law.
A webinar conducted for the students and professionals who were interested in learning about Town Planning Scheme model of land management - self-sufficient tool famous with Gujarat State urban centres.
Land Acquisition, Rehabilitation and Resettlement Act, 2013 (also Land Acquisition Act, 2013) is an Act of Indian Parliament that regulates land acquisition and lays down the procedure and rules for granting compensation, rehabilitation and resettlement to the affected
Planning Laws - Its Implications for Urban Development JIT KUMAR GUPTA
Paper tries to analyse the role and importance of legal framework in the context of urban development and the need to make urban laws more rational, simple and supportive of the urban development.
THE REAL ESTATE (REGULATION AND DEVELOPMENT) ACT, 2016Narmdeshwar Singh
This is a presentation on the new Real Estate Act, 2016 which after a long 9 years came into force. It is considered to be consumer concentric Act enabling the consumers to enforce their rights smoothly under the law.
A webinar conducted for the students and professionals who were interested in learning about Town Planning Scheme model of land management - self-sufficient tool famous with Gujarat State urban centres.
Area Appreciation Studio - 2021 - SPAD M.PlanLakshman R
SEE THIS PPT IN SLIDESHOW MODE
About project
This project was an individual studio project named Area Appreciaton.
The main objective was to learn how to look and evaluate an area from a planners perspective.
So we were asked to select an area of about 1 Sqkm near our place of stay and appreciate several aspects related to spatial planning, quality of life etc.
I have selected Shakarpur and a part of Laxmi Nagar. Had a very hectic time but it was all fun and worth it!
TDR - CASE STUDIES OF MUMBAI CHENNAI BANGALORE
TRANSFERABLE DEVELOPMENT RIGHTS
Transferable Development Rights or TDR can be considered as an important raw material in the real estate industry as it allows the developer to build over and above the permissible Floor Space Index (FSI) under the prevalent rules of the respective locations.
Public private partnerships are becoming increasing important as governments harness the expertise and flexibility of the private sector to make investments they could not otherwise afford. The long-term nature of these partnerships makes them different from conventional procurements or privatisation. Both partners, government and private business, must learn new methods to maximize the value for investors and taxpayers.
Presentation is trying to define the intent , content, methods and scope of arbitration and tendering and its implications for the architectural practice.
Uttar Pradesh Urban Planning and Development Act- 1973Ar Vikram Singh
all about the Uttar Pradesh Urban Planning and Development Act- 1973, in a form of questions and answers
after going through this you will get the detail knowledge of this act.
Area Appreciation Studio - 2021 - SPAD M.PlanLakshman R
SEE THIS PPT IN SLIDESHOW MODE
About project
This project was an individual studio project named Area Appreciaton.
The main objective was to learn how to look and evaluate an area from a planners perspective.
So we were asked to select an area of about 1 Sqkm near our place of stay and appreciate several aspects related to spatial planning, quality of life etc.
I have selected Shakarpur and a part of Laxmi Nagar. Had a very hectic time but it was all fun and worth it!
TDR - CASE STUDIES OF MUMBAI CHENNAI BANGALORE
TRANSFERABLE DEVELOPMENT RIGHTS
Transferable Development Rights or TDR can be considered as an important raw material in the real estate industry as it allows the developer to build over and above the permissible Floor Space Index (FSI) under the prevalent rules of the respective locations.
Public private partnerships are becoming increasing important as governments harness the expertise and flexibility of the private sector to make investments they could not otherwise afford. The long-term nature of these partnerships makes them different from conventional procurements or privatisation. Both partners, government and private business, must learn new methods to maximize the value for investors and taxpayers.
Presentation is trying to define the intent , content, methods and scope of arbitration and tendering and its implications for the architectural practice.
Uttar Pradesh Urban Planning and Development Act- 1973Ar Vikram Singh
all about the Uttar Pradesh Urban Planning and Development Act- 1973, in a form of questions and answers
after going through this you will get the detail knowledge of this act.
By Léna Chiaravalli
In India, the Land Acquisition Act, 1894 gives the right for Government authorities to acquire parcels of land for the implementation of development projects.. In the context of a rapid growth of cities, the process of urbanisation shall accompany the needs of increasing populations. Thus, the Government tends to make use of his eminent domain power –the right to acquire land for a public purpose- very regularly. However, in practice, this process can imply the displacement of the affected landowners, whom are sometimes forced to give away their property in exchange of compensations. These events contributed to feed people’s bitterness for this practice, and the proposed Reforms of the Land Acquisition Act got stalled. Moreover, land acquisition can be extremely costly, and this can compromise the well implementation of related development projects.
A beautiful power point presentation on land acquisition act- 1894 and the acquisition procedure in Kerala..Highly useful for revenue officers in KERALA.
a beautiful my sandesham presentation on land acquisition procedure in Kerala.....enjoy the power point presentation, prepared by t.j joseph adhikarathil,deputy tahsildar, kottayam-mob.9447464502 Solve your land problems in Kerala - we provide Legal support, assistance and monitoring of your complaints in Bhoomi tharam mattom, nilam , purayidom , thottam ,michabhoomi issues, pattayam , thandapper , pokkuvaravu , land tax , building tax , digital survey , resurvey ,klc , puramboke , pathway disputes, fair value , data bank , issues . James Joseph Adhikarathil , Former Deputy collector Alappuzha 9447464502. Service available all over Kerala
Our November planning and development club covered the following topics;
• selling developments to investors; points to note - Kassra Powles
• working with the public sector - Alex Kynoch
• planning update - Dmitrije Sirovica
For further advice and training visit our webpage - https://www.brownejacobson.com/
What Happened for Solar During the 2013 Texas Legislative Session? Rick Borry
Russel Smith is the co-founder and executive director of Texas Renewable Energy Industries Association (TREIA).
Hear Russel review and interpret the 2013 Texas Legislative Session and its impact on the solar energy market. Be sure to join this LIVE webinar to find out how the legislature's actions will affect you and your business during the question-and-answer segment following Russel's presentation.
Presented by Rural Advancement Foundation International (RAFI-USA) Research & Policy Associate James Robinson. August 8, 2013.
Contact James Robinson with any questions: james@rafiusa.org
919-542-1396 ext. 209
For more information about forced pooling and landowner rights visit: http://rafiusa.org/issues/landowner-rights-and-fracking/
Webinar presentation for the Counselors of Real Estate and Owners Counsel of America, focusing on the impact of Kelo v. New London on property rights 10 years later.
Securing your Kubernetes cluster_ a step-by-step guide to success !KatiaHIMEUR1
Today, after several years of existence, an extremely active community and an ultra-dynamic ecosystem, Kubernetes has established itself as the de facto standard in container orchestration. Thanks to a wide range of managed services, it has never been so easy to set up a ready-to-use Kubernetes cluster.
However, this ease of use means that the subject of security in Kubernetes is often left for later, or even neglected. This exposes companies to significant risks.
In this talk, I'll show you step-by-step how to secure your Kubernetes cluster for greater peace of mind and reliability.
The Art of the Pitch: WordPress Relationships and SalesLaura Byrne
Clients don’t know what they don’t know. What web solutions are right for them? How does WordPress come into the picture? How do you make sure you understand scope and timeline? What do you do if sometime changes?
All these questions and more will be explored as we talk about matching clients’ needs with what your agency offers without pulling teeth or pulling your hair out. Practical tips, and strategies for successful relationship building that leads to closing the deal.
Elevating Tactical DDD Patterns Through Object CalisthenicsDorra BARTAGUIZ
After immersing yourself in the blue book and its red counterpart, attending DDD-focused conferences, and applying tactical patterns, you're left with a crucial question: How do I ensure my design is effective? Tactical patterns within Domain-Driven Design (DDD) serve as guiding principles for creating clear and manageable domain models. However, achieving success with these patterns requires additional guidance. Interestingly, we've observed that a set of constraints initially designed for training purposes remarkably aligns with effective pattern implementation, offering a more ‘mechanical’ approach. Let's explore together how Object Calisthenics can elevate the design of your tactical DDD patterns, offering concrete help for those venturing into DDD for the first time!
Neuro-symbolic is not enough, we need neuro-*semantic*Frank van Harmelen
Neuro-symbolic (NeSy) AI is on the rise. However, simply machine learning on just any symbolic structure is not sufficient to really harvest the gains of NeSy. These will only be gained when the symbolic structures have an actual semantics. I give an operational definition of semantics as “predictable inference”.
All of this illustrated with link prediction over knowledge graphs, but the argument is general.
Generating a custom Ruby SDK for your web service or Rails API using Smithyg2nightmarescribd
Have you ever wanted a Ruby client API to communicate with your web service? Smithy is a protocol-agnostic language for defining services and SDKs. Smithy Ruby is an implementation of Smithy that generates a Ruby SDK using a Smithy model. In this talk, we will explore Smithy and Smithy Ruby to learn how to generate custom feature-rich SDKs that can communicate with any web service, such as a Rails JSON API.
Encryption in Microsoft 365 - ExpertsLive Netherlands 2024Albert Hoitingh
In this session I delve into the encryption technology used in Microsoft 365 and Microsoft Purview. Including the concepts of Customer Key and Double Key Encryption.
UiPath Test Automation using UiPath Test Suite series, part 3DianaGray10
Welcome to UiPath Test Automation using UiPath Test Suite series part 3. In this session, we will cover desktop automation along with UI automation.
Topics covered:
UI automation Introduction,
UI automation Sample
Desktop automation flow
Pradeep Chinnala, Senior Consultant Automation Developer @WonderBotz and UiPath MVP
Deepak Rai, Automation Practice Lead, Boundaryless Group and UiPath MVP
GDG Cloud Southlake #33: Boule & Rebala: Effective AppSec in SDLC using Deplo...James Anderson
Effective Application Security in Software Delivery lifecycle using Deployment Firewall and DBOM
The modern software delivery process (or the CI/CD process) includes many tools, distributed teams, open-source code, and cloud platforms. Constant focus on speed to release software to market, along with the traditional slow and manual security checks has caused gaps in continuous security as an important piece in the software supply chain. Today organizations feel more susceptible to external and internal cyber threats due to the vast attack surface in their applications supply chain and the lack of end-to-end governance and risk management.
The software team must secure its software delivery process to avoid vulnerability and security breaches. This needs to be achieved with existing tool chains and without extensive rework of the delivery processes. This talk will present strategies and techniques for providing visibility into the true risk of the existing vulnerabilities, preventing the introduction of security issues in the software, resolving vulnerabilities in production environments quickly, and capturing the deployment bill of materials (DBOM).
Speakers:
Bob Boule
Robert Boule is a technology enthusiast with PASSION for technology and making things work along with a knack for helping others understand how things work. He comes with around 20 years of solution engineering experience in application security, software continuous delivery, and SaaS platforms. He is known for his dynamic presentations in CI/CD and application security integrated in software delivery lifecycle.
Gopinath Rebala
Gopinath Rebala is the CTO of OpsMx, where he has overall responsibility for the machine learning and data processing architectures for Secure Software Delivery. Gopi also has a strong connection with our customers, leading design and architecture for strategic implementations. Gopi is a frequent speaker and well-known leader in continuous delivery and integrating security into software delivery.
2. The National Highways Act 1956
U/s 3(a) – Appointment of Competent Authority.
U/s 3(A) – Declaration of Intention to Acquire Land Essentials
U/s 3(C) – Hearing of Objections
U/s 3(D) – Declaration of Land Acquisition
U/s 3(E) – Power to take possession
U/s 3(G) – Determination of compensation -
3. The Process of LA Under NH Act
Identifying LA
Requirement by
Feasibility Study
Notification for
Appointment of CALA
Proposal for 3A
Notification by CALA
with Details of Land
intended for Acquisition
3A Notification
Invitation of Objection
by CALA giving 21 days
time. Disposing the
Objections Received.
Proposal for 3D
Notification by CALA
with Details of land to be
Acquired
3D Notification
Determination of
Compensation by CALA
and Publication of 3G
Award
Examination of 3G
Award by RO and
release of fund
Upto 25 Crores by RO
>25 Crores by NHAI HQ
Payment of
Compensation to Land
Owners by CALA and
60 days Notice for
eviction
Arbitration Process in
case of Compensation
amount fixed by CALA
not Acceptable
Physical Possession of
Land to NHAI
7. Broad Reasons For Delay-State wise
•J&K, Punjab, UP
& Haryana
•Karnataka & UP
• Assam, UP, West
Bengal, Tamil
Nadu, Maharashtra
& Orissa
• Kerala, Goa
, Himachal
& Partly AP
Alignment
Issues &
Resistance
by Public
Slow
Progress in
LA
High Rate of
Compensation
High Number
of Arbitration
Cases
Delay in
Appointment
of CALA
8. Broad Reasons For Delay-State wise
• West
Bengal &
Jharkhand
• Bihar &
UP
•Tamil
Nadu, MP, UP &
Rajashthan
• MP, Assam,
Uttarakhand
UP, Orrisa, J
harkhand &
Goa Forest
Related
Issues
High
Quantum
of Land
Acquisition
Poor Land
Records
Delay in
Eviction of
Encroachm
ent
Defence
Land
M.P.
9. LA: Issues
• Policy Issues
No time limit for award of compensation
No provision for de-notification of excess land
No provision of time limit for filing the cases for arbitration
Methodology of Market value not provided
10. Issues…..
• Institutional/Implementation Issue
Poor Quality of manpower with DPR consultants at field level
Shortage of manpower with CALA
Delays due to changes in alignments
• Alignments of highways frequently altered.
• Preparation of faulty draft notification by DPR consultants mismatching with
the alignment-missing plots etc.
Time lost in arbitration
11. Issues…….
Inherent delays in legal formalities
Competent Authority assigns low priority to land
acquisition for NHAI
Payments which are not due under NH Act are
included in the estimates
Erroneous/outdated revenue records leading to
issue of incomplete/faulty notifications
12. LINKING LAND ACQUISITION WITH PROJECT
ACTIVITIES
Project Activities Time Period Land Activities
Award of Feasibility Studies 0 month Establishment of PIU with
manpower resources
Completion of Feasibility
Studies
4-6 Months Appointment of Competent
Authority
Invitation of RFQ 3 Months Notification under 3A
Invitation of RFP 3 Months Notification under 3D
Issue of LOA 2 Months Compensation Award
Declaration
Signing of Concession
Agreement
1-1/2 Months Disbursement of Compensation
Financial Close 6 Months Land in Possession
13. LA Status of Ongoing Projects
(Started Before Jan 2009)
All figures are in Hectare
15. LA Status of Ongoing Projects
(LOA Issued between Jan 2009-March 2011)
All figures are in Hectare
16. Measures Adopted for LA
•Setting up of Special Land Acquisition Units (SLAUs)
•Strengthening the Manpower/physical resources
with field units/State authorities
•De-centralization of powers:
• Sanction of Compensation award up to 25 Crores by RO
•Setting up of Regional Offices
17. Measures to speed up LA
Regular Meetings of High Powered Committee under Chief Secretary
preferably -once in two months
Formal public consultations by DPR Consultant at the time of project
preparation-To minimize mid course change in scope
Monthly meetings of ROs and PDs with the District Authorities and
Nodal Officers of the State Government
Member(A) to hold meeting with nodal officers of 2 states every
month. CGM(LA) to cover 2 other states every month.
State Support Agreement with the remaining State Govts to provide
support to concessionaire/contractors. (Gujarat, Bihar, Kerala & UP)
18. Proposed Measures
• Amendment of NH Act in the emerging scenario by:
Provision of solatium and interest at par with LA Act
Prescribing time limit for awarding the compensation
Provision of withdrawal for the land which has been
acquired in excess
Prescribing time limit for filing the arbitration cases
19. Proposed Measures: Forest/Environment
clearance
• De-Linking Forest Clearance from Environment Clearance
• Requirement of consent of Gram Sabhas of under Forest Rights Act
for Forest Clearance needs review for non tribal areas
• Laying Standard Conditions for clearance for all Highway Projects
• Resurfacing, Strengthening and Widening be allowed on the
existing roads where no Wild Life diversion is involved.
20. Recent Achievements in Land-Acquisition
2007-08 2008-09 2009-10 2010-11 2011-12
Upto Jul 2011
3A 6000 6000 23359 8533 4450
3D 4000 4000 6190 14100 5155
Possession 3684 3120 6244 8577 3731
All figures are in Hectare
21. Likely Scenario in Land Acquisition
•Increase in Compensation rates: LA component of
Project may rise from 12 % to 30% of the Total Project
Cost
•Element of Annuity to the land owners may be
introduced
•Ban on acquisition of irrigated land may be imposed
•To impact financing plan of NHAI
•Rising expectations of Farmers may delay LA
activities