On 23 May 2012, McLachlan Lister's Anamaria Popescu made a presentation on "Extensions of Time - Avoiding the Traps or Taking Advantage of Them" in conjunction with well-known Australian law firm Holding Redlich
Quantify Construction Damages related to Delay, disruption, and inefficienciesMichael Pink
Learn how to quantify damages related to delay, disruption and inefficiencies on Construction projects. Convert your delays and impacts into cost claims with this proven process.
Construction Delay Analysis, SimplifiedMichael Pink
Learn how to perform a delay analysis in the construction industry. Capture and study your impacts to determine why a project was late. Use this proven method to ensure that you get paid for delays caused by others.
Project Controls Expo 09 Nov 2011, London - DELAY AND FORENSIC ANALYSIS By Ro...Project Controls Expo
Delay in Construction Contracts: • On-going phenomenon
• Introduction of Critical Path Method (‘CPM’) • Prospective or retrospective analysis
• Observational or modelled
• Dynamic or Static
• Common Methodologies
Quantify Construction Damages related to Delay, disruption, and inefficienciesMichael Pink
Learn how to quantify damages related to delay, disruption and inefficiencies on Construction projects. Convert your delays and impacts into cost claims with this proven process.
Construction Delay Analysis, SimplifiedMichael Pink
Learn how to perform a delay analysis in the construction industry. Capture and study your impacts to determine why a project was late. Use this proven method to ensure that you get paid for delays caused by others.
Project Controls Expo 09 Nov 2011, London - DELAY AND FORENSIC ANALYSIS By Ro...Project Controls Expo
Delay in Construction Contracts: • On-going phenomenon
• Introduction of Critical Path Method (‘CPM’) • Prospective or retrospective analysis
• Observational or modelled
• Dynamic or Static
• Common Methodologies
إدارة القيمة المكتسبة مفيدة ومخادعة في التحكم في المشروعات
فيديو دورة الأساسيات: http://prof.planner.teachable.com/p/evm-basics/
دورة المستوى المتقدم: http://www.slideshare.net/MohamedMaged8/contracts-classification
للمزيد: https://www.facebook.com/groups/prof.cost.engineers/
Earned schedule role in performance reporting and other important delay indicators.
Video: https://www.youtube.com/watch?v=FbA6RWB1gDM&feature=youtu.be
The full course: https://www.luqmanacademy.com/course?course=project-control-using-evm_399sl6015424f8aba9
Video: https://twitter.com/magedkom/status/1354678096683618305?s=20
EXTENSION OF TIME CLAIMS IN OIL AND GAS CONSTRUCTION PROJECTSHossamNegidaPMPRMPPS
This document is dedicated to projects especially in Oil and Gas field wherein, in light of rapid and continuous development of the construction process and under intense competition in order to acquire reasonable profits, they are facing naturally lot of delays and disruptions which lead to exert huge efforts for proving these delays.
Favorite Delay Analysis Methodologies Town Hall SEIChris Carson
Presentation from a Town Hall session to discuss favorite forensic schedule analysis methodologies, based on the Forensic Analysis Recommended Practice from AACE International. The Best Practices and Guidelines for Schedule Impact Analysis project is discussing methods.
McLachlan Lister provides a range of management consulting and project management services. These are offered either discretely or as an integrated service - you control the depth of our relationship:
A case study of Delay Analysis of construction project: Al Kut Olympic Stadiu...Gaurav Verma
These slides present a case study of Delay Analysis in Construction of "AL KUT OLYMPIC STADIUM". After going through these slides you will gotta know the following things:
1. What are construction delays?
2. Types of Construction Delays.
3. Effects of Construction Delays.
4. Location of "Al Kut Olympic Stadium".
5. Scope of study.
6. Objectives of study.
7. Research Methodology.
8. Result Analysis.
Introduction to Cost Management and Professional Certificates
محتوى المحاضرة:
●عناصر التكلفة الرئيسية للمشاريع.
●طرق ومستويات تقدير التكاليف.
●القيمة المكتسبة والتحكم في التكاليف.
●المؤثرات المختلفة على التكاليف.
●أهم الشهادات الاحترافية في إدارة التكاليف.
●فكرة عن شهادة CCP وكيفية الحصول عليها.
APM webinar hosted by the Greater Bay Area Branch on 21 June 2023.
Speakers: Dennis Wong and Anel Idriz
The Greater Area Bay Branch invited Dennis Wong and Anel Idriz to share their professional project management experience on this Webinar- “Delay Analysis from a technical and legal perspective” on 21 June 2023.
Dennis has a wide experience of various forms of commercial dispute resolution including mediation, arbitration, litigation, and adjudication. In particular, he specialises in resolving complex contractual and construction disputes. Anel's experience is diverse across the construction industry including private residential buildings, leisure, commercial office, large mixed‐use developments, hospitals, education, casinos, heavy civil engineering, highways, and railways.
The webinar targeted to price an Insight into delay analysis and provide a legal update on extension of time/ liquidate damages. The speakers has covered:
Introduction to Planning and Programming
The Role of a Programming and Delay Expert
Understanding Delay Analysis
Accepted Methods of Delay Analysis
Selecting a Method for the Analysis
What Records are important to be maintained for a robust Analysis
Latest cases on the extension of time / liquidated damages
https://youtu.be/l1ChOBpoLwk
https://www.apm.org.uk/news/delay-analysis-from-a-technical-and-legal-perspective-webinar/
إدارة القيمة المكتسبة مفيدة ومخادعة في التحكم في المشروعات
فيديو دورة الأساسيات: http://prof.planner.teachable.com/p/evm-basics/
دورة المستوى المتقدم: http://www.slideshare.net/MohamedMaged8/contracts-classification
للمزيد: https://www.facebook.com/groups/prof.cost.engineers/
Earned schedule role in performance reporting and other important delay indicators.
Video: https://www.youtube.com/watch?v=FbA6RWB1gDM&feature=youtu.be
The full course: https://www.luqmanacademy.com/course?course=project-control-using-evm_399sl6015424f8aba9
Video: https://twitter.com/magedkom/status/1354678096683618305?s=20
EXTENSION OF TIME CLAIMS IN OIL AND GAS CONSTRUCTION PROJECTSHossamNegidaPMPRMPPS
This document is dedicated to projects especially in Oil and Gas field wherein, in light of rapid and continuous development of the construction process and under intense competition in order to acquire reasonable profits, they are facing naturally lot of delays and disruptions which lead to exert huge efforts for proving these delays.
Favorite Delay Analysis Methodologies Town Hall SEIChris Carson
Presentation from a Town Hall session to discuss favorite forensic schedule analysis methodologies, based on the Forensic Analysis Recommended Practice from AACE International. The Best Practices and Guidelines for Schedule Impact Analysis project is discussing methods.
McLachlan Lister provides a range of management consulting and project management services. These are offered either discretely or as an integrated service - you control the depth of our relationship:
A case study of Delay Analysis of construction project: Al Kut Olympic Stadiu...Gaurav Verma
These slides present a case study of Delay Analysis in Construction of "AL KUT OLYMPIC STADIUM". After going through these slides you will gotta know the following things:
1. What are construction delays?
2. Types of Construction Delays.
3. Effects of Construction Delays.
4. Location of "Al Kut Olympic Stadium".
5. Scope of study.
6. Objectives of study.
7. Research Methodology.
8. Result Analysis.
Introduction to Cost Management and Professional Certificates
محتوى المحاضرة:
●عناصر التكلفة الرئيسية للمشاريع.
●طرق ومستويات تقدير التكاليف.
●القيمة المكتسبة والتحكم في التكاليف.
●المؤثرات المختلفة على التكاليف.
●أهم الشهادات الاحترافية في إدارة التكاليف.
●فكرة عن شهادة CCP وكيفية الحصول عليها.
APM webinar hosted by the Greater Bay Area Branch on 21 June 2023.
Speakers: Dennis Wong and Anel Idriz
The Greater Area Bay Branch invited Dennis Wong and Anel Idriz to share their professional project management experience on this Webinar- “Delay Analysis from a technical and legal perspective” on 21 June 2023.
Dennis has a wide experience of various forms of commercial dispute resolution including mediation, arbitration, litigation, and adjudication. In particular, he specialises in resolving complex contractual and construction disputes. Anel's experience is diverse across the construction industry including private residential buildings, leisure, commercial office, large mixed‐use developments, hospitals, education, casinos, heavy civil engineering, highways, and railways.
The webinar targeted to price an Insight into delay analysis and provide a legal update on extension of time/ liquidate damages. The speakers has covered:
Introduction to Planning and Programming
The Role of a Programming and Delay Expert
Understanding Delay Analysis
Accepted Methods of Delay Analysis
Selecting a Method for the Analysis
What Records are important to be maintained for a robust Analysis
Latest cases on the extension of time / liquidated damages
https://youtu.be/l1ChOBpoLwk
https://www.apm.org.uk/news/delay-analysis-from-a-technical-and-legal-perspective-webinar/
Program Management 2.0: Schedule Prediction AccuracyJohn Carter
From a course titled Program Management 2.0, this presentation pulls together a suite of tools for using a simple and yet very powerful tool for tracking progress AND projecting the likely release date.
Program Management 2.0: Monitoring PerformanceJohn Carter
From a course titled Program Management 2.0, this presentation pulls together a suite of tools for planning work, assessing & monitoring risk, monitoring program progress, clarifying roles, and making decisions.
Kristina Robinson [InfluxData] | Understand and Visualize Your Data with Infl...InfluxData
Learn how you as a developer can use our InfluxDB Cloud web interface to ingest, explore, analyze, and understand your data. We’ll highlight new capabilities and show you some tips and tricks to get the most out of the InfluxDB Cloud Platform.
From Factories To Flow: Streamlining Software Delivery at Cubic CorporationTasktop
Cubic Corporation is a technology-driven, market-leading solutions provider that has been innovating in the public transportation and defense industry for nearly seven decades – having revolutionized elevators, global positioning, public transit fare payments and military training. With a strong foundation of software delivery through solutions such as the “Top Gun” air combat training system as well as the fare payment systems for public transportation platforms in many US and European cities, Cubic set out on a journey to double down on software innovation. A key to that transformation was shifting to a product mindset to accelerate delivery through its highly complex value streams.
During this webinar, Tasktop CEO and founder, Dr. Mik Kersten interviews Jim Colson, CTO of Cubic Corporation on how their transformation is unfolding and lessons learned along the way. We cover Cubic’s use of the Flow Framework®, SAFe® and other industry standards and view some of the flow diagnostics identified by Tasktop Viz, where Cubic was able to accelerate the pace and velocity of delivery.
RMD24 | Debunking the non-endemic revenue myth Marvin Vacquier Droop | First ...BBPMedia1
Marvin neemt je in deze presentatie mee in de voordelen van non-endemic advertising op retail media netwerken. Hij brengt ook de uitdagingen in beeld die de markt op dit moment heeft op het gebied van retail media voor niet-leveranciers.
Retail media wordt gezien als het nieuwe advertising-medium en ook mediabureaus richten massaal retail media-afdelingen op. Merken die niet in de betreffende winkel liggen staan ook nog niet in de rij om op de retail media netwerken te adverteren. Marvin belicht de uitdagingen die er zijn om echt aansluiting te vinden op die markt van non-endemic advertising.
Cracking the Workplace Discipline Code Main.pptxWorkforce Group
Cultivating and maintaining discipline within teams is a critical differentiator for successful organisations.
Forward-thinking leaders and business managers understand the impact that discipline has on organisational success. A disciplined workforce operates with clarity, focus, and a shared understanding of expectations, ultimately driving better results, optimising productivity, and facilitating seamless collaboration.
Although discipline is not a one-size-fits-all approach, it can help create a work environment that encourages personal growth and accountability rather than solely relying on punitive measures.
In this deck, you will learn the significance of workplace discipline for organisational success. You’ll also learn
• Four (4) workplace discipline methods you should consider
• The best and most practical approach to implementing workplace discipline.
• Three (3) key tips to maintain a disciplined workplace.
Personal Brand Statement:
As an Army veteran dedicated to lifelong learning, I bring a disciplined, strategic mindset to my pursuits. I am constantly expanding my knowledge to innovate and lead effectively. My journey is driven by a commitment to excellence, and to make a meaningful impact in the world.
Buy Verified PayPal Account | Buy Google 5 Star Reviewsusawebmarket
Buy Verified PayPal Account
Looking to buy verified PayPal accounts? Discover 7 expert tips for safely purchasing a verified PayPal account in 2024. Ensure security and reliability for your transactions.
PayPal Services Features-
🟢 Email Access
🟢 Bank Added
🟢 Card Verified
🟢 Full SSN Provided
🟢 Phone Number Access
🟢 Driving License Copy
🟢 Fasted Delivery
Client Satisfaction is Our First priority. Our services is very appropriate to buy. We assume that the first-rate way to purchase our offerings is to order on the website. If you have any worry in our cooperation usually You can order us on Skype or Telegram.
24/7 Hours Reply/Please Contact
usawebmarketEmail: support@usawebmarket.com
Skype: usawebmarket
Telegram: @usawebmarket
WhatsApp: +1(218) 203-5951
USA WEB MARKET is the Best Verified PayPal, Payoneer, Cash App, Skrill, Neteller, Stripe Account and SEO, SMM Service provider.100%Satisfection granted.100% replacement Granted.
Premium MEAN Stack Development Solutions for Modern BusinessesSynapseIndia
Stay ahead of the curve with our premium MEAN Stack Development Solutions. Our expert developers utilize MongoDB, Express.js, AngularJS, and Node.js to create modern and responsive web applications. Trust us for cutting-edge solutions that drive your business growth and success.
Know more: https://www.synapseindia.com/technology/mean-stack-development-company.html
[Note: This is a partial preview. To download this presentation, visit:
https://www.oeconsulting.com.sg/training-presentations]
Sustainability has become an increasingly critical topic as the world recognizes the need to protect our planet and its resources for future generations. Sustainability means meeting our current needs without compromising the ability of future generations to meet theirs. It involves long-term planning and consideration of the consequences of our actions. The goal is to create strategies that ensure the long-term viability of People, Planet, and Profit.
Leading companies such as Nike, Toyota, and Siemens are prioritizing sustainable innovation in their business models, setting an example for others to follow. In this Sustainability training presentation, you will learn key concepts, principles, and practices of sustainability applicable across industries. This training aims to create awareness and educate employees, senior executives, consultants, and other key stakeholders, including investors, policymakers, and supply chain partners, on the importance and implementation of sustainability.
LEARNING OBJECTIVES
1. Develop a comprehensive understanding of the fundamental principles and concepts that form the foundation of sustainability within corporate environments.
2. Explore the sustainability implementation model, focusing on effective measures and reporting strategies to track and communicate sustainability efforts.
3. Identify and define best practices and critical success factors essential for achieving sustainability goals within organizations.
CONTENTS
1. Introduction and Key Concepts of Sustainability
2. Principles and Practices of Sustainability
3. Measures and Reporting in Sustainability
4. Sustainability Implementation & Best Practices
To download the complete presentation, visit: https://www.oeconsulting.com.sg/training-presentations
RMD24 | Retail media: hoe zet je dit in als je geen AH of Unilever bent? Heid...BBPMedia1
Grote partijen zijn al een tijdje onderweg met retail media. Ondertussen worden in dit domein ook de kansen zichtbaar voor andere spelers in de markt. Maar met die kansen ontstaan ook vragen: Zelf retail media worden of erop adverteren? In welke fase van de funnel past het en hoe integreer je het in een mediaplan? Wat is nu precies het verschil met marketplaces en Programmatic ads? In dit half uur beslechten we de dilemma's en krijg je antwoorden op wanneer het voor jou tijd is om de volgende stap te zetten.
What are the main advantages of using HR recruiter services.pdfHumanResourceDimensi1
HR recruiter services offer top talents to companies according to their specific needs. They handle all recruitment tasks from job posting to onboarding and help companies concentrate on their business growth. With their expertise and years of experience, they streamline the hiring process and save time and resources for the company.
Memorandum Of Association Constitution of Company.pptseri bangash
www.seribangash.com
A Memorandum of Association (MOA) is a legal document that outlines the fundamental principles and objectives upon which a company operates. It serves as the company's charter or constitution and defines the scope of its activities. Here's a detailed note on the MOA:
Contents of Memorandum of Association:
Name Clause: This clause states the name of the company, which should end with words like "Limited" or "Ltd." for a public limited company and "Private Limited" or "Pvt. Ltd." for a private limited company.
https://seribangash.com/article-of-association-is-legal-doc-of-company/
Registered Office Clause: It specifies the location where the company's registered office is situated. This office is where all official communications and notices are sent.
Objective Clause: This clause delineates the main objectives for which the company is formed. It's important to define these objectives clearly, as the company cannot undertake activities beyond those mentioned in this clause.
www.seribangash.com
Liability Clause: It outlines the extent of liability of the company's members. In the case of companies limited by shares, the liability of members is limited to the amount unpaid on their shares. For companies limited by guarantee, members' liability is limited to the amount they undertake to contribute if the company is wound up.
https://seribangash.com/promotors-is-person-conceived-formation-company/
Capital Clause: This clause specifies the authorized capital of the company, i.e., the maximum amount of share capital the company is authorized to issue. It also mentions the division of this capital into shares and their respective nominal value.
Association Clause: It simply states that the subscribers wish to form a company and agree to become members of it, in accordance with the terms of the MOA.
Importance of Memorandum of Association:
Legal Requirement: The MOA is a legal requirement for the formation of a company. It must be filed with the Registrar of Companies during the incorporation process.
Constitutional Document: It serves as the company's constitutional document, defining its scope, powers, and limitations.
Protection of Members: It protects the interests of the company's members by clearly defining the objectives and limiting their liability.
External Communication: It provides clarity to external parties, such as investors, creditors, and regulatory authorities, regarding the company's objectives and powers.
https://seribangash.com/difference-public-and-private-company-law/
Binding Authority: The company and its members are bound by the provisions of the MOA. Any action taken beyond its scope may be considered ultra vires (beyond the powers) of the company and therefore void.
Amendment of MOA:
While the MOA lays down the company's fundamental principles, it is not entirely immutable. It can be amended, but only under specific circumstances and in compliance with legal procedures. Amendments typically require shareholder
Skye Residences | Extended Stay Residences Near Toronto Airportmarketingjdass
Experience unparalleled EXTENDED STAY and comfort at Skye Residences located just minutes from Toronto Airport. Discover sophisticated accommodations tailored for discerning travelers.
Website Link :
https://skyeresidences.com/
https://skyeresidences.com/about-us/
https://skyeresidences.com/gallery/
https://skyeresidences.com/rooms/
https://skyeresidences.com/near-by-attractions/
https://skyeresidences.com/commute/
https://skyeresidences.com/contact/
https://skyeresidences.com/queen-suite-with-sofa-bed/
https://skyeresidences.com/queen-suite-with-sofa-bed-and-balcony/
https://skyeresidences.com/queen-suite-with-sofa-bed-accessible/
https://skyeresidences.com/2-bedroom-deluxe-queen-suite-with-sofa-bed/
https://skyeresidences.com/2-bedroom-deluxe-king-queen-suite-with-sofa-bed/
https://skyeresidences.com/2-bedroom-deluxe-queen-suite-with-sofa-bed-accessible/
#Skye Residences Etobicoke, #Skye Residences Near Toronto Airport, #Skye Residences Toronto, #Skye Hotel Toronto, #Skye Hotel Near Toronto Airport, #Hotel Near Toronto Airport, #Near Toronto Airport Accommodation, #Suites Near Toronto Airport, #Etobicoke Suites Near Airport, #Hotel Near Toronto Pearson International Airport, #Toronto Airport Suite Rentals, #Pearson Airport Hotel Suites
3.0 Project 2_ Developing My Brand Identity Kit.pptxtanyjahb
A personal brand exploration presentation summarizes an individual's unique qualities and goals, covering strengths, values, passions, and target audience. It helps individuals understand what makes them stand out, their desired image, and how they aim to achieve it.
What is the TDS Return Filing Due Date for FY 2024-25.pdfseoforlegalpillers
It is crucial for the taxpayers to understand about the TDS Return Filing Due Date, so that they can fulfill your TDS obligations efficiently. Taxpayers can avoid penalties by sticking to the deadlines and by accurate filing of TDS. Timely filing of TDS will make sure about the availability of tax credits. You can also seek the professional guidance of experts like Legal Pillers for timely filing of the TDS Return.
Discover the innovative and creative projects that highlight my journey throu...dylandmeas
Discover the innovative and creative projects that highlight my journey through Full Sail University. Below, you’ll find a collection of my work showcasing my skills and expertise in digital marketing, event planning, and media production.
3. EOT Triggers
1. An Event Occurred or Will Occur that Causes Delay
2. 3 Possible EOT Event Types:
– Owner driven events – O‟s risk (Time & money)
– Neutral events – risk shared (Time only)
– Concurrent events-risk allocated (Time only)
3. Causes Delay to the Critical Path
….But, Critical Path to What?
4. Contractual Completion Date(s)
Dealt with in Contract 2 ways:
– By stating a date
– By stating a works period
Types of Contractual Completion Dates:
– „Practical Completion‟ Date
– „Substantial Completion‟ Date
– „Mechanical Completion‟ Date
– „Handover‟ Date
– „Separable Portion‟ Date
May apply to a Section, or the Entire Project
– Each Section is treated separately
– Multiple EOT Claims and LD Assessments May Apply
6. Schedule Integrity: What is It?
No Open Ends
Limited Constraints
All Scope Captured
Majority of Tie Types: FS
No Large Lags: “Float Hoarding”
No Redundant Logic Ties
Critical Path Makes Sense
Critical Path is Continuous
“Longest Path” Filter Confirmation
7. Schedule Integrity
Obligation of Both the Owner and Contractor
Contract Must State Schedule Requirements
Diligence Must not Stop after Baseline is Accepted
Schedule Updates Are Contractual Too!
Key Tools to EOTs
8. Schedule Integrity: How do you Know?
Ask for the Electronic Version (Not a PDF)
Run a Schedule Diagnostic on Baseline & Updates
Primavera: “Schedule Log” and “Claim Digger”
Others: Acumen “Fuse”, “Schedule Analyser Pro”
Also look for..
– Added and/or Deleted Activities
– Increase or Decrease in OD
– Calendar Changes
– Schedule Calculation Changes
– Etc…
12. Documentation of Causation
The need for evidence: “He who Asserts Must Prove”
1st: Demonstrate Cause (Documentation)
2nd: Demonstrate Effect (Schedule Analysis)
The 3 „R‟s – Records, Records, and Records
Record Type Important but Record Content Key!
13. Documentation of Causation: Record Types
Letters and Emails
RFI‟s
Hold Registers
Transmittal Logs
Progress photographs
Variation Notices
Daily Field Reports
Weekly Progress Reports
Meeting Minutes
Drawing Revision Logs
14. Documentation of Causation: Record Content
Instructions given & received
Conflicts in plans/specifications
Weather conditions: Not Just Rain
Work Stoppage: Time Stopped and Why
Number of Workers/Trade Type
Subcontractors
Equipment Type Utilised and Number
Daily Activity of Crews
Specific Location: Station Number, Area
Delays Encountered: Specific Activity
Material Shortages
Create a Standardised Daily Report Form
20. Concurrent Delay - Requirements
Two or more delays during the “same” time
There can only be one unit of delay during the same
unit of time, regardless of the number of delaying
events
Delays unrelated and independent
Must delay the critical path
Responsibility of different parties
Each party bears its own expenses for that delay
Involuntary (i.e., not “pacing”)
Substantial and not easily curable
22. Literal vs. Functional Concurrency
Literal Concurrency
– Delays have to be literally concurrent
in time, as in “happening at the same
time”
Functional Concurrency
– Delays need only occur in the same
analysis period or window
24. As-Planned vs. As-Built
Comparison of start/finish dates between two schedule updates
Purely mathematical-Variance between dates
25. As-Planned vs. As-Built
Delayed Completion
1 Early Start
2 Overall Delay
3
4
As-Planned
As-Built
1 Delayed Start
2 Early Completion
3
26. As-Planned vs. As-Built
When should it be used?
Limited time and money
No electronic schedules
Inadequate schedule logic
Quick and dirty 1st pass
What does the Schedule Analysis Method Best
Prove?
Excusable non-compensable delay
27. As-Planned vs. As-Built
Not Good For:
– Concurrent delays or acceleration
– Critical path changes between updates
– Multiple critical or near-critical paths per update
– Recovering extended overhead costs
– Arbitration or Litigation
Pros:
– Easy to understand, explain, and graphically depict
– Technically simple to perform
Data Required:
– Baseline schedule
– As-built schedule
28. Windows Analysis
Quantify loss or gain of time along a float path
Loss and gains tallied by window
A “window” is the time period framed between two
revisions:
• The as-planned schedule for the beginning of the
window
• The as-built schedule for the end of the window
As-
Planned As-
Built
29. Windows Analysis: Example
Jan 2006
ID Task Name Dur
9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27
1 Excavate 2d
Ì Gain = +
2 1d
Delay = --
3 Form / Rebar 3d
¬¬ Planned
4 4d
5 Concrete 3d
As-Built
Ì Ì ¬¬
6 4d
7 Strip Forms 1d
¬¬ ¬¬
8 1d
9 Inspect 1d
10 1d
¬¬ ¬¬ ¬¬ ¬¬
Gain 1 1 2
Null 0 0
Delay -1 -1 -1 -1 -1 -1 -1 -7
Net 1 1 -1 -1 -1 -1 -1 -1 -1 -5
30. Windows Analysis
When Should the Schedule Analysis Method be
Used?
– Complex schedules with large critical paths
– Very high delay damages
– Concurrent delays
– Client has the time and budget
– Need graphical depiction of concurrency
What does the Schedule Analysis Method Best
Prove?
– Excusable non-compensable delay
– Excusable compensable delay
– Concurrent delay: Literal Concurrency
– Non-excusable delay
31. Impacted As-Planned (A.K.A TIA)
Insertion of impact activities into a baseline or
update schedule
Integrated into the network logic before, in-
between, or after the activity it affected
Additive model that simulates the possible effect
of actual delay events to the schedule
completion date
Comparison of IAP schedule and succeeding
update to determine possible acceleration or
non-excusable delays
Comparison of IAP schedule and planned
schedule to determine time extension
34. Impacted As-Planned
When Should the Schedule Analysis Method be
Used?
– Indemnification of liquidated damages
– For preliminary negotiations between owner and
contractor
– While the Job is Ongoing
What does the Schedule Analysis Method Best
Prove?
– Requests for Time Extension or LD Waivers
– Acceleration Claims
35. Presentation
1. Attach Source Documentation
2. Graphical Representation
• Schedule Updates: Prior to Impact and After Impact
• Critical Path in Gantt Chart Format with Logic
• Concurrency
3. Write Up
• Keep it Short and Sweet
• Explanation of Impact Event: Timing,Activities,Duration
4. Cost Impact
• Stand-By Costs of Equipment and Crews Affected
• Don‟t Claim Costs on Crews That Were Working!
5. Executive Summary at the Beginning
6. Submit Once Impact Event Is Known
7. Submit Again Once Full Impact Understood
36. Recap
• Documentation is Key: Content Must be Consistent
• Schedules Must Be Sound and Accurate
• Don‟t Ignore Updates
• Choose Your Technique Wisely
• Consider Concurrency
• Present Claim as a Concise Package
• Don‟t Throw the Kitchen Sink into the Claim
• Resolution Inversely Proportional to Submittal Time
37. Contact Information
Brisbane Office
2/19 Musgrave Street
West End, QLD, 4101
Email: anamariap@mclachlanlister.com
Phone: 61 07 3255 0223
Sydney Office Perth Office
Level 1, 1 Hickson Road 189 Colin Place
Phone: 61 02 9241 7328 Phone: 61 08 9480 0647