SlideShare a Scribd company logo
1 of 11
Download to read offline
IOSR Journal of Mechanical and Civil Engineering (IOSR-JMCE)
e-ISSN: 2278-1684,p-ISSN: 2320-334X, Volume 12, Issue 6 Ver. IV (Nov. - Dec. 2015), PP 61-71
www.iosrjournals.org
DOI: 10.9790/1684-12646171 www.iosrjournals.org 61 | Page
Delay Analysis of Projects and Effects of Delays in the
Mining/Manufacturing Industries
Prakash Kumar1
, Piush Raj2
1
, Assistant Professor , Production Engineering Department, B. I. T. Sindri, Dhanbad Jharkhand
2
, Junior Manager, Project, HEC, Ranchi, Jharkhand, India
Abstract: Delays are unique and one of the largest issues mining/manufacturing companies is facing today.
Delays in mining/manufacturing projects have become a major concern across all parts of the world.
Substantial value is destroyed and companies face significant corporate risk if these delays occur during project
execution. However, despite the concern regarding the project delays, there has been very limited research
conducted in this area.
Delay in the completion of a project can be a major problem for contractor companies leading to
costly disputes and adverse relationships amongst project participants. Projects can be delayed for a large
number of reasons. The reasons are related to the various types of uncertainty associated with activities during
the mining/manufacturing processes. The most common factor of delay are natural disaster like flood,
earthquake etc. and some others like financial and payment problems, improper planning, poor site
management, insufficient experience, shortage of materials and equipment etc. Delays will also result in several
negative effects like lawsuits between house owners and contractors, exaggerated prices, loss of productivity
and revenue, and contract termination. So, comprehensive study on these delays is important.
Present study works on identification of causes of delay in mining/manufacturing projects in Indian
context. An approach is suggested to carry out ranking of these causes by two different techniques: Relative
importance index and Importance index based on degree of severity and degree of frequency.
In most of the cases schedule delays also appear in these projects and result in delay claim
progressively. Several studies have proposed various schedule delay analysis methodologies; however, most of
the studies focus on the analysis of surface data (as-planned and as-built schedules), few of them on evaluating
the effect of root causes, such as the problem of lost productivity. Lost productivity, one essential delay cause, is
usually experienced by a contractor while accomplishing its works less than planned rate of production. We
analyze the situations of schedule impacts caused by loss of productivity through the case study. In this study, it
has been proposed to calculate the schedule impact from lost productivity. The study results will be a basis for
developing comprehensive delay analysis methodologies for different mining/manufacturing Projects. It is
hoped that the findings of the paper will help the stakeholders to act on critical causes and further try to reduce
delay of their projects.
Keywords: Mining delays, Effects of delays, Cost overruns, Mining/Manufacturing project, Relative
importance index, Importance index, Delay analysis, Loss of productivity.
I. Overview
Infrastructure projects in India are infamous for delays and cost overruns. Recently commissioned,
Bandra-Worli Sea Link amply demonstrates the state of project delivery system in the country. The original cost
estimate of the project, to be completed by 2004, was Rs. 300 crore. But due to delay in completion of the
project by five years, the final cost of the project stood at Rs. 1600 crore. Indeed, very few projects get
delivered in time and on cost. The delays and cost overruns have become hallmark of infrastructure projects in
India. The quarterly reports of the Ministry of Statistics and Program Implementation (MOSPI) stand testimony
to a saga of unfettered delays and cost overruns. Yet, the extents and the causes behind the time and the cost
overruns have remained understudied. As a result, the types of the policy interventions required to rectify the
malady have also remained unidentified. Delays and cost overruns have significant implications from economic
as well as political point of view. Due to delays in project implementation, the people and the economy have to
wait for the provisions of public goods and services longer than is necessary. Thus, delays limit the growth
potential of the economy. Similarly, cost overruns reduce competitiveness of the economy. Services provided by
infrastructure projects serve as input for other sectors of the economy. Cost overruns in these projects lead to an
increase in the capital-output-ratio for the entire economy. Simply put, delays and cost overruns reduce the
efficiency of available economic resources and limit the growth potential of the entire economy.
Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries
DOI: 10.9790/1684-12646171 www.iosrjournals.org 62 | Page
II. Introduction
Delays on projects are a universal phenomenon. They are almost always accompanied by cost and time
overruns. The following research aims to establish the root causes of delays, delay analysis methodologies and
impact of delays in the mining/manufacturing projects in India. Generally, mining projects are based on the
establishment of infrastructure that supports mining and the workings that are developed as the ground is
moved. Globally more research has been done in the area of construction projects. The effects of delays are only
linked in some cases of research. The literature available from the construction industry is relevant to mining as
the process of planning and execution of a project in mining is basically the same as any construction process.
Mining/manufacturing project activity is subject to high risks because of its size, uncertainty,
complexity, and high costs. Large engineering projects are high-stakes games characterized by substantial
irreversible commitments, skewed reward structures in case of success, and high probabilities of failure.
Therefore, a standard approach to mining/manufacturing project management, effective tools that can
be utilized to meet the project objectives, and studies regarding risk factors associated with these projects, are
required to be developed.
Mining/manufacturing delay could be defined as the time overrun either beyond completion date
specified in a contract or beyond the date that the parties agreed upon for delivery of a project. It is a project
slipping over its planned schedule and is considered as common problem in construction as well as mining
projects. To the owner, delay means loss of revenue through lack of production facilities and rentable space or a
dependence on present facilities. In some cases, to the contractor, delay means higher overhead costs because of
longer work period, higher material costs through inflation, and due to labor cost increases.
These projects subject to many variables and unpredictable factors such as performance of parties,
equipment availability and maintainability, resources availability, environmental conditions, involvement of
other parties, and contractual relations etc.
Mining project delays have an adverse effect on parties (owner, contractor, consultants) to a contract in
terms of a growth in adversarial relationships, distrust, litigation, arbitration, cash-flow problems, and a general
feeling of apprehension towards each other.
While increased mine mechanization and automation make considerable contributions to mine
productivity, unexpected equipment failures and lack of planned or routine maintenance prohibit the maximum
possible utilization of sophisticated mining equipment resulting delay and thus require a significant amount of
extra capital investment. So, it is essential to define the actual causes of delay in order to minimize it.
Objective of the Study
The main objectives of this study include the following.
To identify the causes of delay formining/manufacturing projects in Indian context.
Tocalculate exact effective delay time in executing a turn-key Project by a job shop Industry.
III. Techniques Of Calculating Delays
III.A. Data Analysis Approaches
The following approach should be used for data analysis
III.A.1. Relative importance index technique: To determine the relative importance of the various
causes and effects of delays. The same method is going to adopted in this study within various groups (i.e.
clients, consultants or contractors). The four-point scale ranged from 1 (not important) to 4 (extremely
important) will be adopted and will be transformed to relative importance indices (RII) for each factor as
follows: RII = Where, W is the weighting given to each factor by the respondents (ranging from 1 to 4), A is the
highest weight (i.e. 4 in this case), and N is the total number of respondents.
III.A.2. Importance index technique: In this technique, For each cause/factor two questions should
be asked: What is the frequency of occurrence for this cause? And what is the degree of severity of this cause on
project delay? Both frequency of occurrence and severity were categorized on a four-point scale. Frequency of
occurrence is categorized as follows: always, often, sometimes and rarely (on 4 to 1 point scale). Similarly,
degree of severity was categorized as follows: extreme, great, moderate and little (on 4 to l point scale).
Frequency index: A formula is used to rank causes of delay based on frequency of occurrence as
identified by the participants. Frequency Index (F.I.) (%) = Σ a (n/N) * 100/4 Where, a is the constant
expressing weighting given to each response (ranges from 1 for rarely up to 4 for always), n is the frequency of
the responses, and N is total number of responses.
Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries
DOI: 10.9790/1684-12646171 www.iosrjournals.org 63 | Page
Severity index: A formula is used to rank causes of delay based on severity as indicated by the
participants. Severity Index (S.I.)(%)= Σ a (n/N) * 100/4 Where a is the constant expressing weighting given to
each response (ranges from I for little up to 4 for severe), n is the frequency of the responses, and N is total
number of responses.
Importance index: The importance index of each cause is calculated as a function of both frequency
and severity indices, as follows: Importance Index (IMP.I.)(%) = [F.I.(%)* S.I. (%)]/100
III.B Data accuracy check approach
Spearman‘s rank correlation factor is going to be used to check the accuracy of collected data.
Spearman‘s rank correlation coefficient is a non-parametric test. Nonparametric tests are also referred to as
distribution free tests. These tests have the obvious advantage of not requiring the assumption of normality or
the assumption of homogeneity of variance.
Spearman‘s rank correlation coefficient r is used to measure and compare the association between the
rankings of two parties for a single cause of delay, while ignoring the ranking of the third party. And it is
calculated by the following formula: 1s‘= 1− [(6 Σ d2) / (n3− n)]
Where r is the Spearman rank correlation coefficient between two parties, d is the difference between
ranks assigned to variables for each cause, and n is the number of pairs of rank.
IV. Delay Analysis Methods
Delay analysis techniques can be classified into three separate categories: the Foresight Method, the
Hindsight Method, and the Contemporaneous Method. The differences between these delay analysis techniques
involve the baseline schedule used for measuring the delay, the point in time when the delay is measured, and
the treatment, if any, of concurrent delay.
IV.A. Foresight Method
Commonly thought of as the simplest and easiest, the Foresight Method generally employs two
approaches: Impacted As-Planned, where only the owner-caused delays are identified, and Adjusted As-
Planned, where only contractor-caused delays are identified. In both approaches, the alleged delays are reviewed
to determine where and how the revisions should be incorporated into the as-planned or baseline schedule. The
result of these implanted activities is an adjusted project completion date, which demonstrates, either directly or
indirectly, the owner‘s impact on the contractor‘s planned schedule of performance.
The Foresight Method is not generally favored by courts and boards, because it ignores the as-built
history of the project; it produces theoretical results; it does not measure the effect of delay on actual
performance; and it assumes that the as-planned schedule does not change.
IV.B. Hindsight Method
This method centers on an as-built schedule — a schedule depicting the dates that events actually
occurred. Delaying events are normally depicted as distinct activities on the as-built schedule, which are
invariably tied to the critical path. Typically, under this method, there are two approaches: As-Built Critical
Path, which allocates time by determining the responsibility for the delays on the so-called critical path of the
project, and Collapsed As-Built, which removes delays caused by one party to determine when the work would
have been completed, if not for the delays of the other party.
The Hindsight Method has a number of disadvantages that include difficulty determining which work
activities or delay events controlled the pace of the work; not considering what was critical at the time a delay
occurred; not considering float through various paths at different periods of time; not accounting for concurrent
delay; and not attempting to determine the individual impact of each delay.
IV.C. Contemporaneous Method
This third method hinges on the principle that in order to determine the impact of delaying events, the
status of the project must be established at the time those events occurred. In essence, the schedule needs, first,
to be updated at the time of the delay and, second, to be updated to incorporate any planning changes to coincide
with the contractor‘s plan for pursuing the work. The goal of this method is to develop a freeze-frame picture of
the project — identifying the delaying event, the impact of the delay, and the plan to complete the remaining
work at the time the delay occurred.
Two approaches are commonly used as part of this method: Time Impact Analysis, which looks at a
particular point in time and utilizes a series of chronological time slices to evaluate major scheduling variations
that occurred during the project, and Window Analysis, which examines the critical path between two points in
time and assesses the delay as it occurs.
Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries
DOI: 10.9790/1684-12646171 www.iosrjournals.org 64 | Page
Courts and boards hold that contemporaneous schedule updates should be considered in evaluating
delay. The Contemporaneous Method is favored because it provides a baseline for measuring delay; the status of
the project at the time a delay occurs; the impact of delaying events on remaining work; and insight into float,
changes to critical path, and revisions to the plan to complete.
V. Time Impact Analysis
Time Impact Analysis for any asserted delay shall include a network analysis indicating how the
Project Manager proposes to incarporate the delay into the project schedule. Each time Time Impact Analysis
shall demonstrate the actual time impact of delay as of both the date upon which the delay commenced and the
date upon which the delay terminated, reflect the scope and result of all measures which the Project Manager
took to migrate the effect and impact of the delay, reflects the status of the work at both the commencement and
cessation of the delay and provide the duration computations for all the affected activities. The activity
durations used in the time impact analysis shall be those reflected by the latest project schedule update, unless
such are otherwise adjusted by mutual agreement.
VI. Method for Data Analysis
The collected data was analyzed using an Importance Index (Ip.I). The Importance Index was
computed using the following formula:
5
Ip.I = Σ a i x i 100 (1)
I=1
Where Ip.I = importance index:
• ai = constant expressing the weight of the ith response, where i = 1,2,3,4,5;
• xi = level of the response given as a percentage of the total responses for each variable;
• i = response category index where i = 1, 2, 3, 4, 5; and
• W = the highest weight (5).
To assist respondents in identifying the level of effect of each variable that could cause delay,
Respondents were asked to rank on a scale of 1 (not at all or not relevant) to 5 (most relevant). Using
these indices, the rank of the variables can be determined. These rankings were used for comparative
importance of the variables as identified by the different group of contractors.
VII. Effect Of Delays In Project
The delay causes a cost overrun and time overrun of the Project. The time and cost are directly related
to each other. When the time of execution of project is delayed it leads to failure of guarantee/warranty of the
items/equipments, failure of service period of equipments, damage of equipments due to weather condition and
this will lead to non timely execution of job. The critical review under taken in this area of time delay and main
(Internal reasons) attribute are:
 Unforeseen ground conditions at client premises
 Change in scope of the Project
 Customers poor decision making at different stages of Project
 Contractors cash flow and financial difficulties faced by contractor
 Ineffective planning and scheduling by contractor
 Delay in procurement of Materials
 Improper storage of materials at site
 Absence of sound project management of project
 Problems with subcontractor
External reasons
 Political scenario
 Economic condition
 Government rules and regulations
 Market trend
Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries
DOI: 10.9790/1684-12646171 www.iosrjournals.org 65 | Page
Fig. 1 Effect of delay in Mining/Manufacturing project
The application of sound project management practice provides a project stakeholder with the means
to meet their objective. It can be achieved by using following methodology
 Analysis of contemporaneous project documentation
 Analysis of Project Management requirement stated in the contract
 Analysis of clarity of those requirement
 Development of cause and effect relationship between project problems and ensuring damages
 Allocation of the responsibility for Project management problems to delay and damages calculation.
VIII. Delay Calculating Methodologies
Delay work out is made by identifying the delay factor/event which affects the completion of a Project. In
general common factors that are observed and are categorically placed as under:
a) Delay from client/customer side
b) Delay from consultant side
c) Delay due to constrains of contract
d) Delay due to subcontractor
These can be interrelated with each other and shown in fig.2- (Causes of delay in a project).
Fig. 2 Showing the different causes of Project Delay
In this study, we have chosen the contemporaneous method. It is prepared, based on ―Observational‖
point of view. In this method the contractor prepares a network analysis before the work starts which shows the
detailed plan and the implementation process. This network analysis is thoughtfully prepared by someone who
understands all the facets of the entire project. It will include appropriate inputs from the various areas and the
final form is shared with customers for their comments and possible approval.
PROJECT
DELAY
DUE TO
CONSTRAINTS
IN CONTRACT
CLIENT
/CUSTOMER
CONTRACTOR
CONSULT
ANT
Over cost
Overtime
Effects of Delays
Abandoned
Litigation
Disputes
Negotiations
Law suits
Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries
DOI: 10.9790/1684-12646171 www.iosrjournals.org 66 | Page
Basically this method produces a contemporaneous running commentary on job progress, where all the
participants know status and update of the project. When the network is final, the customer reviews at
appropriate regular intervals usually each month and observed the work status and accordingly delay activities
are marked. The chart is again marked with start dates, percentage completion and completion dates for the
affected activity, forecasting jobs, future work schedule and completion etc. It also focuses on possible causes of
delays. We describe our points of delay as categorized above and have taken main reasons of delay by the four
factors (customer, consultant, contractor, constraints in contract). Apart from these main reasons there may be
other reasons which are also responsible for project delays but are not taken in consideration because of their
low weight-age in delay calculation.
A) Delay from client/customer
Fig. 3 Different reasons of delay due to client
B) Delay from consultant
Fig. 4 Different reasons of delay due to consultant
Providing basic inputs/ raw
data fom client
Delay in approval of
Engineering by client.
Delay in clearing the
hindrences at areas under
client/customer
Delay in approval of Drawings/
documents by consultants
Delay in approving changes in
facility/ upgrading of system
beyond contract
Delay in providing Inspection
clearence
Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries
DOI: 10.9790/1684-12646171 www.iosrjournals.org 67 | Page
C) Delay due to constrains of contract
Fig. 5 Different reasons of delay due to constrains of contract
D) Delay due to Contractor/Sub-contractor
Fig. 6 Different reasons of delay due to contractor/sub-contractor
Delay in accepting additional service
provider/ vendor
Delay in correct interpretation of
contract in terms of provisions of
contract
Contractor/Subcontractor
and their ease for
providing /accepting
services
Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries
DOI: 10.9790/1684-12646171 www.iosrjournals.org 68 | Page
Fig. 7 Typical flow chart for delay control
IX. Delay Time Calculation
In context to calculate the delay we have to define few terms used in the study
a) Date of Occurrence: This refers to the date when an activity started by the contractor based on agreed chart.
b) Date of Cessation: This refers to the date on which the said activity is completed.
c) Weight age: We adopt the principle that a activity which is the root of other activity gets delayed will delay
all other related activity. So 100% weight age is awarded to such root activities. The activities which are not
falling under root activity and is not affecting the total project weight age calculation may be derived from
time allocated for completion of their portion of work in comparison to total time of completion of project.
The weight age is calculated in percentage only.
Table 1 Calculation of delay
Sl.
No.
Nature of Hindrance Date of
Occurrence
(As per
approved
chart)
A
Date of
Cessation
(As per
approved
chart)
A‘
Date of
Cessation
( As per
actual
completion)
B
Gross
period
of
delay
(No.
of
days)
C
Weig
ht age
(in %)
D
Effective
period of
delay (No.
of days)
E= C x D
Gross
time
allotted
as per
appro
ved
Chart
Project
Contr
actual
time
allotted
(Days)
1 Delay due to Client
1.A Providing basic input
i.e. coordinates for
wagon tippler
complex
05.10.08 28.11.08 14.01.09 102 100 102 47 910
1.B Variation in soil data
provide at various
junction house
21.09.08 23.01.09 19.04.10 447 100 447 130 910
Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries
DOI: 10.9790/1684-12646171 www.iosrjournals.org 69 | Page
So, a total delay of project is 2538 days or 6.95 years. Apart from total delay, the delay caused due to
consultant and customer is 1167 days or 3.19 years.
A pie chart is made based on the above calculation and shown below:
1.C Change in voltage
level from 6.6 to
11kv incoming feeder
LTSS buildings
29.01.09 19.03.09 13.05.10 470 51.64 243 50 910
2 Delay due to
consultant
2A Delay in Approval of
Basic Engineering
Drawings of
Structural Design of
Gallery & Trestle for
Conv. No. 11
11.05.10 25.05.10 22.08.11 469 51.51 242 14 910
2B Delay in issue of
Inspection certificate/
Inspection waiver
certificate/ Dispatch
clearance
05.04.12 19.04.12 14.11.12 223 24.50 55 14 910
3 Delay due to
Constrains of
Contract
3A Delay in approval of
additional vendors
due to non
availability of
vendors in contract
18.06.09 2.07.09 11.12.09 177 19.45 35 14 910
3B Change in size of
Area Repair Shop
01.02.09 10.03.09 18.08.09 198 21.75 43.08 38 910
4 Delay due to
contractor
4A Delay by Yard
Equipment
manufacturer in
supply of equipments
10.01.09 04.07.10 18.01.11 738 81.09 598 541 910
4B Delay by Utilities
Sub Contractor in
supply of
equipments(Fire
fighting, water
systems)
05.01.09 27.06.10 23.04.11 839 92.19 773 539 910
Total Delay 2538 days
or
6.95
Years
Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries
DOI: 10.9790/1684-12646171 www.iosrjournals.org 70 | Page
X. Extra Claim
When this delay analysis is accepted by customer, the claims are generally made in the following
categories:
 Extra Wages and salaries
 Project Management cost
 Site activity cost
 Misc Item extra cost during project overrun
The extra claim is tabulated as:
Table 2 Extra claim
Sl. No. Category No. of
worker
Minimum wages
per day(Rs)
No. of
working days
per month
No. of
month
Total
wages/salaries to
be paid (Rs)
1 Skilled 20 nos. 221 26 83.4 9,584,328
2 Semi Skilled 10 nos. 210 26 83.4 4,55,3640
3 Un Skilled 20 nos. 202 26 83.4 8,760,336
4 Management
Staff
25 nos. @ 1200000/month 30 83.4 100080000
Total 122,978,304
1. Extra Wages and salaries: This consists of extra wages and salaries of workers, supervisors and
engineers during overtime or in case of extension of a project.
2. Project Management cost: This consists of bank guarantee charges towards customers for extra
period. The project completion is considered for 910 days or 30 months. The project management costs also
includes cost of record keeping, retrieving records as and when required and providing all support to other
departments and cost incurred in terms are tours. This figures comes to around 200 00000 for a period of 83.4
months (Table2).
Table 3 Site activity cost
3. Site Activity cost: The extra time for a site establishment must be included in a project. The
unexpected cost which is paid due to unforeseen reasons attributes to hike this cost against this category. This
can be shown in Table 3.
4. Misc Item extra cost during project overrun: This is basically procurement of items which are purchased in
emergency situation due to sudden damage of parts or, scarcity of parts. Total cost incurred during delay periods
are tabulated below.
Table 4 Misc Item extra cost during project overrun
Sl.
No.
Description Amount incurred Total amount
1 Emergency purchase of fasteners 10,0000 10,0000
2 Purchase of hydraulic parts for
wagon tippler
25,098780 25,098780
3 Purchase of couplings of motor
damaged due to wear out
10,087100 10,087100
4 Purchase of electrical switches 54980735 54980735
5 Purchase of High mast parts 40987600 40987600
Total 131,254,215
Sl. No. Category No. of persons Rent/cost of
Establishment per
month
No. of month Total amount to
be paid (Rs)
1 Site Guest House 10 25,000 83.4 2,085,000
2 Site office 15 2000 83.4 166800
3 Office boy wages 2 12000 83.4 1,000,800
4 Office
Expenditures
15 10000 83.4 834000
5 Vehicle cost 5 35000/vehicle 83.4 14,595,000
6 Fatal damage 100000 for total
period
100000
Total 18,781,600
Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries
DOI: 10.9790/1684-12646171 www.iosrjournals.org 71 | Page
Now we add all the extra cost (1+2+3) = 122,978,304 + 200 00000 + 18,781,600+ 131,254,215
Grand Total = Rs 293,014,119
This is the total extra cost incurred due to Project over run of 83.4 months.
XI. Conclusions
The study was carried out to investigate various reasons of delay in execution of a
mining/manufacturing project. Results show that less than 50% delay is attributable to customer and client and
more than 50% of problems are attributable to contractor. Also this study helps in identifying various reasons
and factors causing delay from customer, consultant and contractor‘s end. Also it helps in highlighting flaws of
contract.
The importance of delay causes in mining/manufacturing project in India has been identified clearly.
Although this research was conducted in the commercial sector in India, the results may also be applicable for
similar projects in other developing countries. The identification of important delay causes helps a contractor in
seeking extra time for completion from the customer. If the contractor wins in explaining the reasons of delay
and gets a contractual extension of time than the customer is bound to pay extra claim to contractor. The
contractor gain or loss is huge in terms of its credential in the market in terms of a successful presentation of
delay analysis.
Further methodology is suggested to work out critical causes from available ones by two techniques:
Relative importance index and Importance index as a function of severity index and frequency index. Survey
questionnaire must be prepared based on these techniques. It is proposed to carry out ranking of causes of delay
from two different techniques in the next phase of research.
References
[1] Al-Ghafly MA. , Delays in the construction of public utility projects in Saudi Arabia., Master thesis, CEM Dept., KFUPM,
Dhahran, Saudi Arabia, 1995.
[2] Al-Momani, A.H. (2000).Construction delay: a quantitative analysis, Journal of ProjectManagement18, 51-59.
[3] Alwi, S. (2002). ―Non Value-Adding Activities in the Indonesian Construction Industry: Variables and Causes‖. Unpublished
Doctoral Thesis, Queensland University of Technology, Brisbane,Australia.
[4] Arvan, L. and Leite. (1990), Cost Overruns in Long-Term Project,' International Journal of Industrial Organization, 8(3), 443-67.
Banerjee-Guha, Swapna (2009), Neoliberalizing the ‗Urb
[5] Chan, D. W. M. and Kumaraswamy, M. M. (1997) ―A Comparative Study of Causes of Time Overruns in Hong Kong Construction
Projects‖. International Journal of Project Management, Vol. 15, No. 1, 55-63.
[6] C.T.Ramanathan, N. S. Potty and A. B. Idrus, ―Analysis of time and cost overrun in Malaysian construction‖, Advanced Materials
Research Journal. Vol. 452-453, pp. 1002-1008
[7] Frimpong Y, Oluwoye J, Crawford L. Causes of delay and cost overruns in construction of groundwater projects in a developing
countries; Ghana as a case study. Int J Project Manage 2003;21:321–6.
[8] Fugar, F D K and Agyakwah‐Baah, A B ―Delays in building construction projects in Ghana‖, Australasian Journal of Construction
Economics and Building, 10 (1/2) (2010) 103‐116.
[9] Ganuza, Juan-José. (2007), Competition and cost overruns in Procurement,' International Journal of Industrial Organization, Vol.
55(4), 633-660.
[10] Hampson, K.D., Peters, R.J. and Walker, D.H.T. (2001) ―Negotiation and Conflict in Innovative Procurement Environments: The
National Museum of Australia‖. CIB World Building Congress, April, Wellington.
[11] Kometa ST, Olomolaiye PO, Harris FC. Attributes of UK construction clients influencing project consultants
performance.Construction Manage Econ 1994;12:433–443.
[12] Kumaraswamy, M.M. and Chan, W.M. (1998).Contributes to Construction Delays, Journal of Construction Management &
Economics, 16; 17-29.
[13] Ling, F. Y. Y. & Hoi, L. (2006). Risks faced by Singapore firms when undertaking construction projects in India. International
Journal of Project Management, Vol. 24, pp. 261-270.
[14] Luu, V. T.; Kim, S.; Tuan, N. V. & Ogunlana, S. O. (2009). Quantifying schedule risk in construction projects using Bayesian belief
networks. International Journal of Project Management, Vol. 27, pp. 39-50, www.intechopen.
[15] Mendenhall, W.; Reinmuth, J.E. and Beaver, R.J. (1993) Statistics for Management and Economics. Duxbury Press, California
[16] Miller, R. & Lessard, D. (2001). Understanding and managing risks in large engineering projects, International Journal of Project
Management, Vol. 19, No. 8, pp. 437-443.
[17] M. Sambasivan and Y.W. Soon (2007) Causes and effects of delays in Malaysian construction industry, International Journal of
Project Management. 25, p. 517-526. (2002)
[18] N. Vagenas, N. Runciman, and S. R.clément, ―A methodology for maintenance analysis of mining equipment‖ International Journal
of Surface Mining, Reclamation and Environment, vol. 11, no. 1, pp. 33–40, 1997.
[19] Ogunlana S.O. Prokuntong, K. and Jearkjirm, V. (1996). Construction Delays in Fast Growing Economy Comparing Thailand with
Other Economies. International Journal of Project Management 14 (1),37-45.
[20] Prakash Rao, B. And Joseph Camron Culas Causes of delays in construction projects International Journal of Current Research Vol.
6, Issue, 06, pp.7219-7222, June, 2014.

More Related Content

What's hot

Case study: Fire in IOC terminal Jaipur & IOC terminal Hazira
Case study: Fire in IOC terminal Jaipur & IOC terminal HaziraCase study: Fire in IOC terminal Jaipur & IOC terminal Hazira
Case study: Fire in IOC terminal Jaipur & IOC terminal HaziraAbhishant Baishya
 
Project Management- Unit II
Project Management- Unit IIProject Management- Unit II
Project Management- Unit IILamay Sabir
 
Environmental impact assessment case study
Environmental impact assessment case studyEnvironmental impact assessment case study
Environmental impact assessment case studyKundan Sanap
 
Environmental Impact Assessment
Environmental Impact AssessmentEnvironmental Impact Assessment
Environmental Impact AssessmentBahadur Prasad
 
Environment impact assessment
Environment impact assessmentEnvironment impact assessment
Environment impact assessmentBimal Antony
 
Role of project management in construction industry
Role of project management in construction industryRole of project management in construction industry
Role of project management in construction industryRubnawaz Bhatti
 
Tender Process | A Complete Procurement Guide
Tender Process | A Complete Procurement GuideTender Process | A Complete Procurement Guide
Tender Process | A Complete Procurement GuideTender Process
 
Environmental Impact Assessment (EIA) in Project Management
Environmental Impact Assessment (EIA) in Project ManagementEnvironmental Impact Assessment (EIA) in Project Management
Environmental Impact Assessment (EIA) in Project ManagementJoy Bhattacharjee
 
Environmental Impact Assessment
Environmental Impact AssessmentEnvironmental Impact Assessment
Environmental Impact AssessmentPrithvi Ghag
 
Engineering, procurement and construction (EPC) projects
Engineering, procurement and construction (EPC) projectsEngineering, procurement and construction (EPC) projects
Engineering, procurement and construction (EPC) projectsNam N.N Tran M.Eng, PMP
 
PMP : Precedence Diagram Method : Relationship Types | iZenBridge
PMP : Precedence Diagram Method : Relationship Types | iZenBridgePMP : Precedence Diagram Method : Relationship Types | iZenBridge
PMP : Precedence Diagram Method : Relationship Types | iZenBridgeSaket Bansal
 
Classification of contracts
Classification of contractsClassification of contracts
Classification of contractsAnil Kumar(6)
 
#FIDIC Understanding Basics# By SN Panigrahi
#FIDIC Understanding Basics# By SN Panigrahi#FIDIC Understanding Basics# By SN Panigrahi
#FIDIC Understanding Basics# By SN PanigrahiSN Panigrahi, PMP
 
causes and implication of delay in construction
causes and implication of delay in constructioncauses and implication of delay in construction
causes and implication of delay in constructionsudinak
 

What's hot (20)

Project planning and control
Project planning and controlProject planning and control
Project planning and control
 
Case study: Fire in IOC terminal Jaipur & IOC terminal Hazira
Case study: Fire in IOC terminal Jaipur & IOC terminal HaziraCase study: Fire in IOC terminal Jaipur & IOC terminal Hazira
Case study: Fire in IOC terminal Jaipur & IOC terminal Hazira
 
Project Management- Unit II
Project Management- Unit IIProject Management- Unit II
Project Management- Unit II
 
Extension of Time (EOT) & Related Costs in Construction - Presentation Slides
Extension of Time (EOT) & Related Costs in Construction - Presentation SlidesExtension of Time (EOT) & Related Costs in Construction - Presentation Slides
Extension of Time (EOT) & Related Costs in Construction - Presentation Slides
 
Environmental impact assessment case study
Environmental impact assessment case studyEnvironmental impact assessment case study
Environmental impact assessment case study
 
Environmental Impact Assessment
Environmental Impact AssessmentEnvironmental Impact Assessment
Environmental Impact Assessment
 
Environment impact assessment
Environment impact assessmentEnvironment impact assessment
Environment impact assessment
 
Time overruns
Time overrunsTime overruns
Time overruns
 
Role of project management in construction industry
Role of project management in construction industryRole of project management in construction industry
Role of project management in construction industry
 
Tender Process | A Complete Procurement Guide
Tender Process | A Complete Procurement GuideTender Process | A Complete Procurement Guide
Tender Process | A Complete Procurement Guide
 
Fidic
FidicFidic
Fidic
 
Environmental Impact Assessment (EIA) in Project Management
Environmental Impact Assessment (EIA) in Project ManagementEnvironmental Impact Assessment (EIA) in Project Management
Environmental Impact Assessment (EIA) in Project Management
 
Environmental Impact Assessment
Environmental Impact AssessmentEnvironmental Impact Assessment
Environmental Impact Assessment
 
Project selection
Project selection Project selection
Project selection
 
Engineering, procurement and construction (EPC) projects
Engineering, procurement and construction (EPC) projectsEngineering, procurement and construction (EPC) projects
Engineering, procurement and construction (EPC) projects
 
PMP : Precedence Diagram Method : Relationship Types | iZenBridge
PMP : Precedence Diagram Method : Relationship Types | iZenBridgePMP : Precedence Diagram Method : Relationship Types | iZenBridge
PMP : Precedence Diagram Method : Relationship Types | iZenBridge
 
TENDER DOCUMENT
TENDER DOCUMENTTENDER DOCUMENT
TENDER DOCUMENT
 
Classification of contracts
Classification of contractsClassification of contracts
Classification of contracts
 
#FIDIC Understanding Basics# By SN Panigrahi
#FIDIC Understanding Basics# By SN Panigrahi#FIDIC Understanding Basics# By SN Panigrahi
#FIDIC Understanding Basics# By SN Panigrahi
 
causes and implication of delay in construction
causes and implication of delay in constructioncauses and implication of delay in construction
causes and implication of delay in construction
 

Similar to Delay Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries

IRJET- To Study the Causes and Effects of Delays in Construction Project
IRJET-  	  To Study the Causes and Effects of Delays in Construction ProjectIRJET-  	  To Study the Causes and Effects of Delays in Construction Project
IRJET- To Study the Causes and Effects of Delays in Construction ProjectIRJET Journal
 
IRJET- Case Study on Budget and Schedule Overrun During the Construction Phas...
IRJET- Case Study on Budget and Schedule Overrun During the Construction Phas...IRJET- Case Study on Budget and Schedule Overrun During the Construction Phas...
IRJET- Case Study on Budget and Schedule Overrun During the Construction Phas...IRJET Journal
 
IRJET- Review Paper on “Budget and Schedule Overrun in the Construction Phase...
IRJET- Review Paper on “Budget and Schedule Overrun in the Construction Phase...IRJET- Review Paper on “Budget and Schedule Overrun in the Construction Phase...
IRJET- Review Paper on “Budget and Schedule Overrun in the Construction Phase...IRJET Journal
 
Investigating the Factors Affecting Delays in Infrastructure Projects
Investigating the Factors Affecting Delays in Infrastructure ProjectsInvestigating the Factors Affecting Delays in Infrastructure Projects
Investigating the Factors Affecting Delays in Infrastructure ProjectsDr. Amarjeet Singh
 
IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...
IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...
IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...IRJET Journal
 
Element of Cost overrun and Delay in Construction: A Review
Element of Cost overrun and Delay in Construction: A ReviewElement of Cost overrun and Delay in Construction: A Review
Element of Cost overrun and Delay in Construction: A ReviewIRJET Journal
 
Delay Analysis in Industrial Projects by using Relative Importance Index Method
Delay Analysis in Industrial Projects by using Relative Importance Index MethodDelay Analysis in Industrial Projects by using Relative Importance Index Method
Delay Analysis in Industrial Projects by using Relative Importance Index MethodIRJET Journal
 
Exploratory Study of Causes and Effects of Delay in Indian Residential Projects
Exploratory Study of Causes and Effects of Delay in Indian Residential ProjectsExploratory Study of Causes and Effects of Delay in Indian Residential Projects
Exploratory Study of Causes and Effects of Delay in Indian Residential ProjectsIRJET Journal
 
IRJET- Effects of Project Cost Analysis and Factors Affecting Inflation
IRJET- Effects of Project Cost Analysis and Factors Affecting InflationIRJET- Effects of Project Cost Analysis and Factors Affecting Inflation
IRJET- Effects of Project Cost Analysis and Factors Affecting InflationIRJET Journal
 
IRJET- Effect of Pre-Planning in High Rise Building for Time Management
IRJET- Effect of Pre-Planning in High Rise Building for Time ManagementIRJET- Effect of Pre-Planning in High Rise Building for Time Management
IRJET- Effect of Pre-Planning in High Rise Building for Time ManagementIRJET Journal
 
Risk Analysis and Strategic Evaluation of Procurement Process in Construction
Risk Analysis and Strategic Evaluation of Procurement Process in ConstructionRisk Analysis and Strategic Evaluation of Procurement Process in Construction
Risk Analysis and Strategic Evaluation of Procurement Process in ConstructionIRJET Journal
 
Impact of delayness on construction projects
Impact of delayness on construction projectsImpact of delayness on construction projects
Impact of delayness on construction projectsIRJET Journal
 
journalsresaim,+IJRESM_V3_I7_70.pdf
journalsresaim,+IJRESM_V3_I7_70.pdfjournalsresaim,+IJRESM_V3_I7_70.pdf
journalsresaim,+IJRESM_V3_I7_70.pdfKarthikeyanP288430
 
Study on the analysis and evaluation of delays in public sector construction ...
Study on the analysis and evaluation of delays in public sector construction ...Study on the analysis and evaluation of delays in public sector construction ...
Study on the analysis and evaluation of delays in public sector construction ...IRJET Journal
 
A Critical Literature Review On Main Cause Of Delay In Construction Projects
A Critical Literature Review On Main Cause Of Delay In Construction ProjectsA Critical Literature Review On Main Cause Of Delay In Construction Projects
A Critical Literature Review On Main Cause Of Delay In Construction ProjectsRick Vogel
 
IRJET-A Critical Literature Review on Main Cause of Delay in Construction Pro...
IRJET-A Critical Literature Review on Main Cause of Delay in Construction Pro...IRJET-A Critical Literature Review on Main Cause of Delay in Construction Pro...
IRJET-A Critical Literature Review on Main Cause of Delay in Construction Pro...IRJET Journal
 
Reasons for the Delay and Cost Overrun in Residential Projects - 2017
Reasons for the Delay and Cost Overrun in Residential Projects - 2017Reasons for the Delay and Cost Overrun in Residential Projects - 2017
Reasons for the Delay and Cost Overrun in Residential Projects - 2017Sankalp Swarnkar
 

Similar to Delay Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries (20)

IRJET- To Study the Causes and Effects of Delays in Construction Project
IRJET-  	  To Study the Causes and Effects of Delays in Construction ProjectIRJET-  	  To Study the Causes and Effects of Delays in Construction Project
IRJET- To Study the Causes and Effects of Delays in Construction Project
 
Risk management
Risk managementRisk management
Risk management
 
IRJET- Case Study on Budget and Schedule Overrun During the Construction Phas...
IRJET- Case Study on Budget and Schedule Overrun During the Construction Phas...IRJET- Case Study on Budget and Schedule Overrun During the Construction Phas...
IRJET- Case Study on Budget and Schedule Overrun During the Construction Phas...
 
IRJET- Review Paper on “Budget and Schedule Overrun in the Construction Phase...
IRJET- Review Paper on “Budget and Schedule Overrun in the Construction Phase...IRJET- Review Paper on “Budget and Schedule Overrun in the Construction Phase...
IRJET- Review Paper on “Budget and Schedule Overrun in the Construction Phase...
 
20320140503023
2032014050302320320140503023
20320140503023
 
Investigating the Factors Affecting Delays in Infrastructure Projects
Investigating the Factors Affecting Delays in Infrastructure ProjectsInvestigating the Factors Affecting Delays in Infrastructure Projects
Investigating the Factors Affecting Delays in Infrastructure Projects
 
IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...
IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...
IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...
 
Element of Cost overrun and Delay in Construction: A Review
Element of Cost overrun and Delay in Construction: A ReviewElement of Cost overrun and Delay in Construction: A Review
Element of Cost overrun and Delay in Construction: A Review
 
Delay Analysis in Industrial Projects by using Relative Importance Index Method
Delay Analysis in Industrial Projects by using Relative Importance Index MethodDelay Analysis in Industrial Projects by using Relative Importance Index Method
Delay Analysis in Industrial Projects by using Relative Importance Index Method
 
Exploratory Study of Causes and Effects of Delay in Indian Residential Projects
Exploratory Study of Causes and Effects of Delay in Indian Residential ProjectsExploratory Study of Causes and Effects of Delay in Indian Residential Projects
Exploratory Study of Causes and Effects of Delay in Indian Residential Projects
 
IRJET- Effects of Project Cost Analysis and Factors Affecting Inflation
IRJET- Effects of Project Cost Analysis and Factors Affecting InflationIRJET- Effects of Project Cost Analysis and Factors Affecting Inflation
IRJET- Effects of Project Cost Analysis and Factors Affecting Inflation
 
IRJET- Effect of Pre-Planning in High Rise Building for Time Management
IRJET- Effect of Pre-Planning in High Rise Building for Time ManagementIRJET- Effect of Pre-Planning in High Rise Building for Time Management
IRJET- Effect of Pre-Planning in High Rise Building for Time Management
 
Risk Analysis and Strategic Evaluation of Procurement Process in Construction
Risk Analysis and Strategic Evaluation of Procurement Process in ConstructionRisk Analysis and Strategic Evaluation of Procurement Process in Construction
Risk Analysis and Strategic Evaluation of Procurement Process in Construction
 
Impact of delayness on construction projects
Impact of delayness on construction projectsImpact of delayness on construction projects
Impact of delayness on construction projects
 
journalsresaim,+IJRESM_V3_I7_70.pdf
journalsresaim,+IJRESM_V3_I7_70.pdfjournalsresaim,+IJRESM_V3_I7_70.pdf
journalsresaim,+IJRESM_V3_I7_70.pdf
 
Ijciet 08 04_220
Ijciet 08 04_220Ijciet 08 04_220
Ijciet 08 04_220
 
Study on the analysis and evaluation of delays in public sector construction ...
Study on the analysis and evaluation of delays in public sector construction ...Study on the analysis and evaluation of delays in public sector construction ...
Study on the analysis and evaluation of delays in public sector construction ...
 
A Critical Literature Review On Main Cause Of Delay In Construction Projects
A Critical Literature Review On Main Cause Of Delay In Construction ProjectsA Critical Literature Review On Main Cause Of Delay In Construction Projects
A Critical Literature Review On Main Cause Of Delay In Construction Projects
 
IRJET-A Critical Literature Review on Main Cause of Delay in Construction Pro...
IRJET-A Critical Literature Review on Main Cause of Delay in Construction Pro...IRJET-A Critical Literature Review on Main Cause of Delay in Construction Pro...
IRJET-A Critical Literature Review on Main Cause of Delay in Construction Pro...
 
Reasons for the Delay and Cost Overrun in Residential Projects - 2017
Reasons for the Delay and Cost Overrun in Residential Projects - 2017Reasons for the Delay and Cost Overrun in Residential Projects - 2017
Reasons for the Delay and Cost Overrun in Residential Projects - 2017
 

More from iosrjce

An Examination of Effectuation Dimension as Financing Practice of Small and M...
An Examination of Effectuation Dimension as Financing Practice of Small and M...An Examination of Effectuation Dimension as Financing Practice of Small and M...
An Examination of Effectuation Dimension as Financing Practice of Small and M...iosrjce
 
Does Goods and Services Tax (GST) Leads to Indian Economic Development?
Does Goods and Services Tax (GST) Leads to Indian Economic Development?Does Goods and Services Tax (GST) Leads to Indian Economic Development?
Does Goods and Services Tax (GST) Leads to Indian Economic Development?iosrjce
 
Childhood Factors that influence success in later life
Childhood Factors that influence success in later lifeChildhood Factors that influence success in later life
Childhood Factors that influence success in later lifeiosrjce
 
Emotional Intelligence and Work Performance Relationship: A Study on Sales Pe...
Emotional Intelligence and Work Performance Relationship: A Study on Sales Pe...Emotional Intelligence and Work Performance Relationship: A Study on Sales Pe...
Emotional Intelligence and Work Performance Relationship: A Study on Sales Pe...iosrjce
 
Customer’s Acceptance of Internet Banking in Dubai
Customer’s Acceptance of Internet Banking in DubaiCustomer’s Acceptance of Internet Banking in Dubai
Customer’s Acceptance of Internet Banking in Dubaiiosrjce
 
A Study of Employee Satisfaction relating to Job Security & Working Hours amo...
A Study of Employee Satisfaction relating to Job Security & Working Hours amo...A Study of Employee Satisfaction relating to Job Security & Working Hours amo...
A Study of Employee Satisfaction relating to Job Security & Working Hours amo...iosrjce
 
Consumer Perspectives on Brand Preference: A Choice Based Model Approach
Consumer Perspectives on Brand Preference: A Choice Based Model ApproachConsumer Perspectives on Brand Preference: A Choice Based Model Approach
Consumer Perspectives on Brand Preference: A Choice Based Model Approachiosrjce
 
Student`S Approach towards Social Network Sites
Student`S Approach towards Social Network SitesStudent`S Approach towards Social Network Sites
Student`S Approach towards Social Network Sitesiosrjce
 
Broadcast Management in Nigeria: The systems approach as an imperative
Broadcast Management in Nigeria: The systems approach as an imperativeBroadcast Management in Nigeria: The systems approach as an imperative
Broadcast Management in Nigeria: The systems approach as an imperativeiosrjce
 
A Study on Retailer’s Perception on Soya Products with Special Reference to T...
A Study on Retailer’s Perception on Soya Products with Special Reference to T...A Study on Retailer’s Perception on Soya Products with Special Reference to T...
A Study on Retailer’s Perception on Soya Products with Special Reference to T...iosrjce
 
A Study Factors Influence on Organisation Citizenship Behaviour in Corporate ...
A Study Factors Influence on Organisation Citizenship Behaviour in Corporate ...A Study Factors Influence on Organisation Citizenship Behaviour in Corporate ...
A Study Factors Influence on Organisation Citizenship Behaviour in Corporate ...iosrjce
 
Consumers’ Behaviour on Sony Xperia: A Case Study on Bangladesh
Consumers’ Behaviour on Sony Xperia: A Case Study on BangladeshConsumers’ Behaviour on Sony Xperia: A Case Study on Bangladesh
Consumers’ Behaviour on Sony Xperia: A Case Study on Bangladeshiosrjce
 
Design of a Balanced Scorecard on Nonprofit Organizations (Study on Yayasan P...
Design of a Balanced Scorecard on Nonprofit Organizations (Study on Yayasan P...Design of a Balanced Scorecard on Nonprofit Organizations (Study on Yayasan P...
Design of a Balanced Scorecard on Nonprofit Organizations (Study on Yayasan P...iosrjce
 
Public Sector Reforms and Outsourcing Services in Nigeria: An Empirical Evalu...
Public Sector Reforms and Outsourcing Services in Nigeria: An Empirical Evalu...Public Sector Reforms and Outsourcing Services in Nigeria: An Empirical Evalu...
Public Sector Reforms and Outsourcing Services in Nigeria: An Empirical Evalu...iosrjce
 
Media Innovations and its Impact on Brand awareness & Consideration
Media Innovations and its Impact on Brand awareness & ConsiderationMedia Innovations and its Impact on Brand awareness & Consideration
Media Innovations and its Impact on Brand awareness & Considerationiosrjce
 
Customer experience in supermarkets and hypermarkets – A comparative study
Customer experience in supermarkets and hypermarkets – A comparative studyCustomer experience in supermarkets and hypermarkets – A comparative study
Customer experience in supermarkets and hypermarkets – A comparative studyiosrjce
 
Social Media and Small Businesses: A Combinational Strategic Approach under t...
Social Media and Small Businesses: A Combinational Strategic Approach under t...Social Media and Small Businesses: A Combinational Strategic Approach under t...
Social Media and Small Businesses: A Combinational Strategic Approach under t...iosrjce
 
Secretarial Performance and the Gender Question (A Study of Selected Tertiary...
Secretarial Performance and the Gender Question (A Study of Selected Tertiary...Secretarial Performance and the Gender Question (A Study of Selected Tertiary...
Secretarial Performance and the Gender Question (A Study of Selected Tertiary...iosrjce
 
Implementation of Quality Management principles at Zimbabwe Open University (...
Implementation of Quality Management principles at Zimbabwe Open University (...Implementation of Quality Management principles at Zimbabwe Open University (...
Implementation of Quality Management principles at Zimbabwe Open University (...iosrjce
 
Organizational Conflicts Management In Selected Organizaions In Lagos State, ...
Organizational Conflicts Management In Selected Organizaions In Lagos State, ...Organizational Conflicts Management In Selected Organizaions In Lagos State, ...
Organizational Conflicts Management In Selected Organizaions In Lagos State, ...iosrjce
 

More from iosrjce (20)

An Examination of Effectuation Dimension as Financing Practice of Small and M...
An Examination of Effectuation Dimension as Financing Practice of Small and M...An Examination of Effectuation Dimension as Financing Practice of Small and M...
An Examination of Effectuation Dimension as Financing Practice of Small and M...
 
Does Goods and Services Tax (GST) Leads to Indian Economic Development?
Does Goods and Services Tax (GST) Leads to Indian Economic Development?Does Goods and Services Tax (GST) Leads to Indian Economic Development?
Does Goods and Services Tax (GST) Leads to Indian Economic Development?
 
Childhood Factors that influence success in later life
Childhood Factors that influence success in later lifeChildhood Factors that influence success in later life
Childhood Factors that influence success in later life
 
Emotional Intelligence and Work Performance Relationship: A Study on Sales Pe...
Emotional Intelligence and Work Performance Relationship: A Study on Sales Pe...Emotional Intelligence and Work Performance Relationship: A Study on Sales Pe...
Emotional Intelligence and Work Performance Relationship: A Study on Sales Pe...
 
Customer’s Acceptance of Internet Banking in Dubai
Customer’s Acceptance of Internet Banking in DubaiCustomer’s Acceptance of Internet Banking in Dubai
Customer’s Acceptance of Internet Banking in Dubai
 
A Study of Employee Satisfaction relating to Job Security & Working Hours amo...
A Study of Employee Satisfaction relating to Job Security & Working Hours amo...A Study of Employee Satisfaction relating to Job Security & Working Hours amo...
A Study of Employee Satisfaction relating to Job Security & Working Hours amo...
 
Consumer Perspectives on Brand Preference: A Choice Based Model Approach
Consumer Perspectives on Brand Preference: A Choice Based Model ApproachConsumer Perspectives on Brand Preference: A Choice Based Model Approach
Consumer Perspectives on Brand Preference: A Choice Based Model Approach
 
Student`S Approach towards Social Network Sites
Student`S Approach towards Social Network SitesStudent`S Approach towards Social Network Sites
Student`S Approach towards Social Network Sites
 
Broadcast Management in Nigeria: The systems approach as an imperative
Broadcast Management in Nigeria: The systems approach as an imperativeBroadcast Management in Nigeria: The systems approach as an imperative
Broadcast Management in Nigeria: The systems approach as an imperative
 
A Study on Retailer’s Perception on Soya Products with Special Reference to T...
A Study on Retailer’s Perception on Soya Products with Special Reference to T...A Study on Retailer’s Perception on Soya Products with Special Reference to T...
A Study on Retailer’s Perception on Soya Products with Special Reference to T...
 
A Study Factors Influence on Organisation Citizenship Behaviour in Corporate ...
A Study Factors Influence on Organisation Citizenship Behaviour in Corporate ...A Study Factors Influence on Organisation Citizenship Behaviour in Corporate ...
A Study Factors Influence on Organisation Citizenship Behaviour in Corporate ...
 
Consumers’ Behaviour on Sony Xperia: A Case Study on Bangladesh
Consumers’ Behaviour on Sony Xperia: A Case Study on BangladeshConsumers’ Behaviour on Sony Xperia: A Case Study on Bangladesh
Consumers’ Behaviour on Sony Xperia: A Case Study on Bangladesh
 
Design of a Balanced Scorecard on Nonprofit Organizations (Study on Yayasan P...
Design of a Balanced Scorecard on Nonprofit Organizations (Study on Yayasan P...Design of a Balanced Scorecard on Nonprofit Organizations (Study on Yayasan P...
Design of a Balanced Scorecard on Nonprofit Organizations (Study on Yayasan P...
 
Public Sector Reforms and Outsourcing Services in Nigeria: An Empirical Evalu...
Public Sector Reforms and Outsourcing Services in Nigeria: An Empirical Evalu...Public Sector Reforms and Outsourcing Services in Nigeria: An Empirical Evalu...
Public Sector Reforms and Outsourcing Services in Nigeria: An Empirical Evalu...
 
Media Innovations and its Impact on Brand awareness & Consideration
Media Innovations and its Impact on Brand awareness & ConsiderationMedia Innovations and its Impact on Brand awareness & Consideration
Media Innovations and its Impact on Brand awareness & Consideration
 
Customer experience in supermarkets and hypermarkets – A comparative study
Customer experience in supermarkets and hypermarkets – A comparative studyCustomer experience in supermarkets and hypermarkets – A comparative study
Customer experience in supermarkets and hypermarkets – A comparative study
 
Social Media and Small Businesses: A Combinational Strategic Approach under t...
Social Media and Small Businesses: A Combinational Strategic Approach under t...Social Media and Small Businesses: A Combinational Strategic Approach under t...
Social Media and Small Businesses: A Combinational Strategic Approach under t...
 
Secretarial Performance and the Gender Question (A Study of Selected Tertiary...
Secretarial Performance and the Gender Question (A Study of Selected Tertiary...Secretarial Performance and the Gender Question (A Study of Selected Tertiary...
Secretarial Performance and the Gender Question (A Study of Selected Tertiary...
 
Implementation of Quality Management principles at Zimbabwe Open University (...
Implementation of Quality Management principles at Zimbabwe Open University (...Implementation of Quality Management principles at Zimbabwe Open University (...
Implementation of Quality Management principles at Zimbabwe Open University (...
 
Organizational Conflicts Management In Selected Organizaions In Lagos State, ...
Organizational Conflicts Management In Selected Organizaions In Lagos State, ...Organizational Conflicts Management In Selected Organizaions In Lagos State, ...
Organizational Conflicts Management In Selected Organizaions In Lagos State, ...
 

Recently uploaded

INFLUENCE OF NANOSILICA ON THE PROPERTIES OF CONCRETE
INFLUENCE OF NANOSILICA ON THE PROPERTIES OF CONCRETEINFLUENCE OF NANOSILICA ON THE PROPERTIES OF CONCRETE
INFLUENCE OF NANOSILICA ON THE PROPERTIES OF CONCRETEroselinkalist12
 
What are the advantages and disadvantages of membrane structures.pptx
What are the advantages and disadvantages of membrane structures.pptxWhat are the advantages and disadvantages of membrane structures.pptx
What are the advantages and disadvantages of membrane structures.pptxwendy cai
 
Study on Air-Water & Water-Water Heat Exchange in a Finned Tube Exchanger
Study on Air-Water & Water-Water Heat Exchange in a Finned Tube ExchangerStudy on Air-Water & Water-Water Heat Exchange in a Finned Tube Exchanger
Study on Air-Water & Water-Water Heat Exchange in a Finned Tube ExchangerAnamika Sarkar
 
Churning of Butter, Factors affecting .
Churning of Butter, Factors affecting  .Churning of Butter, Factors affecting  .
Churning of Butter, Factors affecting .Satyam Kumar
 
Past, Present and Future of Generative AI
Past, Present and Future of Generative AIPast, Present and Future of Generative AI
Past, Present and Future of Generative AIabhishek36461
 
Call Girls Delhi {Jodhpur} 9711199012 high profile service
Call Girls Delhi {Jodhpur} 9711199012 high profile serviceCall Girls Delhi {Jodhpur} 9711199012 high profile service
Call Girls Delhi {Jodhpur} 9711199012 high profile servicerehmti665
 
Gurgaon ✡️9711147426✨Call In girls Gurgaon Sector 51 escort service
Gurgaon ✡️9711147426✨Call In girls Gurgaon Sector 51 escort serviceGurgaon ✡️9711147426✨Call In girls Gurgaon Sector 51 escort service
Gurgaon ✡️9711147426✨Call In girls Gurgaon Sector 51 escort servicejennyeacort
 
chaitra-1.pptx fake news detection using machine learning
chaitra-1.pptx  fake news detection using machine learningchaitra-1.pptx  fake news detection using machine learning
chaitra-1.pptx fake news detection using machine learningmisbanausheenparvam
 
Heart Disease Prediction using machine learning.pptx
Heart Disease Prediction using machine learning.pptxHeart Disease Prediction using machine learning.pptx
Heart Disease Prediction using machine learning.pptxPoojaBan
 
IVE Industry Focused Event - Defence Sector 2024
IVE Industry Focused Event - Defence Sector 2024IVE Industry Focused Event - Defence Sector 2024
IVE Industry Focused Event - Defence Sector 2024Mark Billinghurst
 
Introduction-To-Agricultural-Surveillance-Rover.pptx
Introduction-To-Agricultural-Surveillance-Rover.pptxIntroduction-To-Agricultural-Surveillance-Rover.pptx
Introduction-To-Agricultural-Surveillance-Rover.pptxk795866
 
VIP Call Girls Service Hitech City Hyderabad Call +91-8250192130
VIP Call Girls Service Hitech City Hyderabad Call +91-8250192130VIP Call Girls Service Hitech City Hyderabad Call +91-8250192130
VIP Call Girls Service Hitech City Hyderabad Call +91-8250192130Suhani Kapoor
 
Architect Hassan Khalil Portfolio for 2024
Architect Hassan Khalil Portfolio for 2024Architect Hassan Khalil Portfolio for 2024
Architect Hassan Khalil Portfolio for 2024hassan khalil
 
HARMONY IN THE NATURE AND EXISTENCE - Unit-IV
HARMONY IN THE NATURE AND EXISTENCE - Unit-IVHARMONY IN THE NATURE AND EXISTENCE - Unit-IV
HARMONY IN THE NATURE AND EXISTENCE - Unit-IVRajaP95
 
Electronically Controlled suspensions system .pdf
Electronically Controlled suspensions system .pdfElectronically Controlled suspensions system .pdf
Electronically Controlled suspensions system .pdfme23b1001
 
Artificial-Intelligence-in-Electronics (K).pptx
Artificial-Intelligence-in-Electronics (K).pptxArtificial-Intelligence-in-Electronics (K).pptx
Artificial-Intelligence-in-Electronics (K).pptxbritheesh05
 

Recently uploaded (20)

🔝9953056974🔝!!-YOUNG call girls in Rajendra Nagar Escort rvice Shot 2000 nigh...
🔝9953056974🔝!!-YOUNG call girls in Rajendra Nagar Escort rvice Shot 2000 nigh...🔝9953056974🔝!!-YOUNG call girls in Rajendra Nagar Escort rvice Shot 2000 nigh...
🔝9953056974🔝!!-YOUNG call girls in Rajendra Nagar Escort rvice Shot 2000 nigh...
 
INFLUENCE OF NANOSILICA ON THE PROPERTIES OF CONCRETE
INFLUENCE OF NANOSILICA ON THE PROPERTIES OF CONCRETEINFLUENCE OF NANOSILICA ON THE PROPERTIES OF CONCRETE
INFLUENCE OF NANOSILICA ON THE PROPERTIES OF CONCRETE
 
What are the advantages and disadvantages of membrane structures.pptx
What are the advantages and disadvantages of membrane structures.pptxWhat are the advantages and disadvantages of membrane structures.pptx
What are the advantages and disadvantages of membrane structures.pptx
 
Study on Air-Water & Water-Water Heat Exchange in a Finned Tube Exchanger
Study on Air-Water & Water-Water Heat Exchange in a Finned Tube ExchangerStudy on Air-Water & Water-Water Heat Exchange in a Finned Tube Exchanger
Study on Air-Water & Water-Water Heat Exchange in a Finned Tube Exchanger
 
young call girls in Green Park🔝 9953056974 🔝 escort Service
young call girls in Green Park🔝 9953056974 🔝 escort Serviceyoung call girls in Green Park🔝 9953056974 🔝 escort Service
young call girls in Green Park🔝 9953056974 🔝 escort Service
 
9953056974 Call Girls In South Ex, Escorts (Delhi) NCR.pdf
9953056974 Call Girls In South Ex, Escorts (Delhi) NCR.pdf9953056974 Call Girls In South Ex, Escorts (Delhi) NCR.pdf
9953056974 Call Girls In South Ex, Escorts (Delhi) NCR.pdf
 
Churning of Butter, Factors affecting .
Churning of Butter, Factors affecting  .Churning of Butter, Factors affecting  .
Churning of Butter, Factors affecting .
 
Past, Present and Future of Generative AI
Past, Present and Future of Generative AIPast, Present and Future of Generative AI
Past, Present and Future of Generative AI
 
Call Girls Delhi {Jodhpur} 9711199012 high profile service
Call Girls Delhi {Jodhpur} 9711199012 high profile serviceCall Girls Delhi {Jodhpur} 9711199012 high profile service
Call Girls Delhi {Jodhpur} 9711199012 high profile service
 
Gurgaon ✡️9711147426✨Call In girls Gurgaon Sector 51 escort service
Gurgaon ✡️9711147426✨Call In girls Gurgaon Sector 51 escort serviceGurgaon ✡️9711147426✨Call In girls Gurgaon Sector 51 escort service
Gurgaon ✡️9711147426✨Call In girls Gurgaon Sector 51 escort service
 
chaitra-1.pptx fake news detection using machine learning
chaitra-1.pptx  fake news detection using machine learningchaitra-1.pptx  fake news detection using machine learning
chaitra-1.pptx fake news detection using machine learning
 
Heart Disease Prediction using machine learning.pptx
Heart Disease Prediction using machine learning.pptxHeart Disease Prediction using machine learning.pptx
Heart Disease Prediction using machine learning.pptx
 
IVE Industry Focused Event - Defence Sector 2024
IVE Industry Focused Event - Defence Sector 2024IVE Industry Focused Event - Defence Sector 2024
IVE Industry Focused Event - Defence Sector 2024
 
Introduction-To-Agricultural-Surveillance-Rover.pptx
Introduction-To-Agricultural-Surveillance-Rover.pptxIntroduction-To-Agricultural-Surveillance-Rover.pptx
Introduction-To-Agricultural-Surveillance-Rover.pptx
 
VIP Call Girls Service Hitech City Hyderabad Call +91-8250192130
VIP Call Girls Service Hitech City Hyderabad Call +91-8250192130VIP Call Girls Service Hitech City Hyderabad Call +91-8250192130
VIP Call Girls Service Hitech City Hyderabad Call +91-8250192130
 
Architect Hassan Khalil Portfolio for 2024
Architect Hassan Khalil Portfolio for 2024Architect Hassan Khalil Portfolio for 2024
Architect Hassan Khalil Portfolio for 2024
 
young call girls in Rajiv Chowk🔝 9953056974 🔝 Delhi escort Service
young call girls in Rajiv Chowk🔝 9953056974 🔝 Delhi escort Serviceyoung call girls in Rajiv Chowk🔝 9953056974 🔝 Delhi escort Service
young call girls in Rajiv Chowk🔝 9953056974 🔝 Delhi escort Service
 
HARMONY IN THE NATURE AND EXISTENCE - Unit-IV
HARMONY IN THE NATURE AND EXISTENCE - Unit-IVHARMONY IN THE NATURE AND EXISTENCE - Unit-IV
HARMONY IN THE NATURE AND EXISTENCE - Unit-IV
 
Electronically Controlled suspensions system .pdf
Electronically Controlled suspensions system .pdfElectronically Controlled suspensions system .pdf
Electronically Controlled suspensions system .pdf
 
Artificial-Intelligence-in-Electronics (K).pptx
Artificial-Intelligence-in-Electronics (K).pptxArtificial-Intelligence-in-Electronics (K).pptx
Artificial-Intelligence-in-Electronics (K).pptx
 

Delay Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries

  • 1. IOSR Journal of Mechanical and Civil Engineering (IOSR-JMCE) e-ISSN: 2278-1684,p-ISSN: 2320-334X, Volume 12, Issue 6 Ver. IV (Nov. - Dec. 2015), PP 61-71 www.iosrjournals.org DOI: 10.9790/1684-12646171 www.iosrjournals.org 61 | Page Delay Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries Prakash Kumar1 , Piush Raj2 1 , Assistant Professor , Production Engineering Department, B. I. T. Sindri, Dhanbad Jharkhand 2 , Junior Manager, Project, HEC, Ranchi, Jharkhand, India Abstract: Delays are unique and one of the largest issues mining/manufacturing companies is facing today. Delays in mining/manufacturing projects have become a major concern across all parts of the world. Substantial value is destroyed and companies face significant corporate risk if these delays occur during project execution. However, despite the concern regarding the project delays, there has been very limited research conducted in this area. Delay in the completion of a project can be a major problem for contractor companies leading to costly disputes and adverse relationships amongst project participants. Projects can be delayed for a large number of reasons. The reasons are related to the various types of uncertainty associated with activities during the mining/manufacturing processes. The most common factor of delay are natural disaster like flood, earthquake etc. and some others like financial and payment problems, improper planning, poor site management, insufficient experience, shortage of materials and equipment etc. Delays will also result in several negative effects like lawsuits between house owners and contractors, exaggerated prices, loss of productivity and revenue, and contract termination. So, comprehensive study on these delays is important. Present study works on identification of causes of delay in mining/manufacturing projects in Indian context. An approach is suggested to carry out ranking of these causes by two different techniques: Relative importance index and Importance index based on degree of severity and degree of frequency. In most of the cases schedule delays also appear in these projects and result in delay claim progressively. Several studies have proposed various schedule delay analysis methodologies; however, most of the studies focus on the analysis of surface data (as-planned and as-built schedules), few of them on evaluating the effect of root causes, such as the problem of lost productivity. Lost productivity, one essential delay cause, is usually experienced by a contractor while accomplishing its works less than planned rate of production. We analyze the situations of schedule impacts caused by loss of productivity through the case study. In this study, it has been proposed to calculate the schedule impact from lost productivity. The study results will be a basis for developing comprehensive delay analysis methodologies for different mining/manufacturing Projects. It is hoped that the findings of the paper will help the stakeholders to act on critical causes and further try to reduce delay of their projects. Keywords: Mining delays, Effects of delays, Cost overruns, Mining/Manufacturing project, Relative importance index, Importance index, Delay analysis, Loss of productivity. I. Overview Infrastructure projects in India are infamous for delays and cost overruns. Recently commissioned, Bandra-Worli Sea Link amply demonstrates the state of project delivery system in the country. The original cost estimate of the project, to be completed by 2004, was Rs. 300 crore. But due to delay in completion of the project by five years, the final cost of the project stood at Rs. 1600 crore. Indeed, very few projects get delivered in time and on cost. The delays and cost overruns have become hallmark of infrastructure projects in India. The quarterly reports of the Ministry of Statistics and Program Implementation (MOSPI) stand testimony to a saga of unfettered delays and cost overruns. Yet, the extents and the causes behind the time and the cost overruns have remained understudied. As a result, the types of the policy interventions required to rectify the malady have also remained unidentified. Delays and cost overruns have significant implications from economic as well as political point of view. Due to delays in project implementation, the people and the economy have to wait for the provisions of public goods and services longer than is necessary. Thus, delays limit the growth potential of the economy. Similarly, cost overruns reduce competitiveness of the economy. Services provided by infrastructure projects serve as input for other sectors of the economy. Cost overruns in these projects lead to an increase in the capital-output-ratio for the entire economy. Simply put, delays and cost overruns reduce the efficiency of available economic resources and limit the growth potential of the entire economy.
  • 2. Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries DOI: 10.9790/1684-12646171 www.iosrjournals.org 62 | Page II. Introduction Delays on projects are a universal phenomenon. They are almost always accompanied by cost and time overruns. The following research aims to establish the root causes of delays, delay analysis methodologies and impact of delays in the mining/manufacturing projects in India. Generally, mining projects are based on the establishment of infrastructure that supports mining and the workings that are developed as the ground is moved. Globally more research has been done in the area of construction projects. The effects of delays are only linked in some cases of research. The literature available from the construction industry is relevant to mining as the process of planning and execution of a project in mining is basically the same as any construction process. Mining/manufacturing project activity is subject to high risks because of its size, uncertainty, complexity, and high costs. Large engineering projects are high-stakes games characterized by substantial irreversible commitments, skewed reward structures in case of success, and high probabilities of failure. Therefore, a standard approach to mining/manufacturing project management, effective tools that can be utilized to meet the project objectives, and studies regarding risk factors associated with these projects, are required to be developed. Mining/manufacturing delay could be defined as the time overrun either beyond completion date specified in a contract or beyond the date that the parties agreed upon for delivery of a project. It is a project slipping over its planned schedule and is considered as common problem in construction as well as mining projects. To the owner, delay means loss of revenue through lack of production facilities and rentable space or a dependence on present facilities. In some cases, to the contractor, delay means higher overhead costs because of longer work period, higher material costs through inflation, and due to labor cost increases. These projects subject to many variables and unpredictable factors such as performance of parties, equipment availability and maintainability, resources availability, environmental conditions, involvement of other parties, and contractual relations etc. Mining project delays have an adverse effect on parties (owner, contractor, consultants) to a contract in terms of a growth in adversarial relationships, distrust, litigation, arbitration, cash-flow problems, and a general feeling of apprehension towards each other. While increased mine mechanization and automation make considerable contributions to mine productivity, unexpected equipment failures and lack of planned or routine maintenance prohibit the maximum possible utilization of sophisticated mining equipment resulting delay and thus require a significant amount of extra capital investment. So, it is essential to define the actual causes of delay in order to minimize it. Objective of the Study The main objectives of this study include the following. To identify the causes of delay formining/manufacturing projects in Indian context. Tocalculate exact effective delay time in executing a turn-key Project by a job shop Industry. III. Techniques Of Calculating Delays III.A. Data Analysis Approaches The following approach should be used for data analysis III.A.1. Relative importance index technique: To determine the relative importance of the various causes and effects of delays. The same method is going to adopted in this study within various groups (i.e. clients, consultants or contractors). The four-point scale ranged from 1 (not important) to 4 (extremely important) will be adopted and will be transformed to relative importance indices (RII) for each factor as follows: RII = Where, W is the weighting given to each factor by the respondents (ranging from 1 to 4), A is the highest weight (i.e. 4 in this case), and N is the total number of respondents. III.A.2. Importance index technique: In this technique, For each cause/factor two questions should be asked: What is the frequency of occurrence for this cause? And what is the degree of severity of this cause on project delay? Both frequency of occurrence and severity were categorized on a four-point scale. Frequency of occurrence is categorized as follows: always, often, sometimes and rarely (on 4 to 1 point scale). Similarly, degree of severity was categorized as follows: extreme, great, moderate and little (on 4 to l point scale). Frequency index: A formula is used to rank causes of delay based on frequency of occurrence as identified by the participants. Frequency Index (F.I.) (%) = Σ a (n/N) * 100/4 Where, a is the constant expressing weighting given to each response (ranges from 1 for rarely up to 4 for always), n is the frequency of the responses, and N is total number of responses.
  • 3. Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries DOI: 10.9790/1684-12646171 www.iosrjournals.org 63 | Page Severity index: A formula is used to rank causes of delay based on severity as indicated by the participants. Severity Index (S.I.)(%)= Σ a (n/N) * 100/4 Where a is the constant expressing weighting given to each response (ranges from I for little up to 4 for severe), n is the frequency of the responses, and N is total number of responses. Importance index: The importance index of each cause is calculated as a function of both frequency and severity indices, as follows: Importance Index (IMP.I.)(%) = [F.I.(%)* S.I. (%)]/100 III.B Data accuracy check approach Spearman‘s rank correlation factor is going to be used to check the accuracy of collected data. Spearman‘s rank correlation coefficient is a non-parametric test. Nonparametric tests are also referred to as distribution free tests. These tests have the obvious advantage of not requiring the assumption of normality or the assumption of homogeneity of variance. Spearman‘s rank correlation coefficient r is used to measure and compare the association between the rankings of two parties for a single cause of delay, while ignoring the ranking of the third party. And it is calculated by the following formula: 1s‘= 1− [(6 Σ d2) / (n3− n)] Where r is the Spearman rank correlation coefficient between two parties, d is the difference between ranks assigned to variables for each cause, and n is the number of pairs of rank. IV. Delay Analysis Methods Delay analysis techniques can be classified into three separate categories: the Foresight Method, the Hindsight Method, and the Contemporaneous Method. The differences between these delay analysis techniques involve the baseline schedule used for measuring the delay, the point in time when the delay is measured, and the treatment, if any, of concurrent delay. IV.A. Foresight Method Commonly thought of as the simplest and easiest, the Foresight Method generally employs two approaches: Impacted As-Planned, where only the owner-caused delays are identified, and Adjusted As- Planned, where only contractor-caused delays are identified. In both approaches, the alleged delays are reviewed to determine where and how the revisions should be incorporated into the as-planned or baseline schedule. The result of these implanted activities is an adjusted project completion date, which demonstrates, either directly or indirectly, the owner‘s impact on the contractor‘s planned schedule of performance. The Foresight Method is not generally favored by courts and boards, because it ignores the as-built history of the project; it produces theoretical results; it does not measure the effect of delay on actual performance; and it assumes that the as-planned schedule does not change. IV.B. Hindsight Method This method centers on an as-built schedule — a schedule depicting the dates that events actually occurred. Delaying events are normally depicted as distinct activities on the as-built schedule, which are invariably tied to the critical path. Typically, under this method, there are two approaches: As-Built Critical Path, which allocates time by determining the responsibility for the delays on the so-called critical path of the project, and Collapsed As-Built, which removes delays caused by one party to determine when the work would have been completed, if not for the delays of the other party. The Hindsight Method has a number of disadvantages that include difficulty determining which work activities or delay events controlled the pace of the work; not considering what was critical at the time a delay occurred; not considering float through various paths at different periods of time; not accounting for concurrent delay; and not attempting to determine the individual impact of each delay. IV.C. Contemporaneous Method This third method hinges on the principle that in order to determine the impact of delaying events, the status of the project must be established at the time those events occurred. In essence, the schedule needs, first, to be updated at the time of the delay and, second, to be updated to incorporate any planning changes to coincide with the contractor‘s plan for pursuing the work. The goal of this method is to develop a freeze-frame picture of the project — identifying the delaying event, the impact of the delay, and the plan to complete the remaining work at the time the delay occurred. Two approaches are commonly used as part of this method: Time Impact Analysis, which looks at a particular point in time and utilizes a series of chronological time slices to evaluate major scheduling variations that occurred during the project, and Window Analysis, which examines the critical path between two points in time and assesses the delay as it occurs.
  • 4. Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries DOI: 10.9790/1684-12646171 www.iosrjournals.org 64 | Page Courts and boards hold that contemporaneous schedule updates should be considered in evaluating delay. The Contemporaneous Method is favored because it provides a baseline for measuring delay; the status of the project at the time a delay occurs; the impact of delaying events on remaining work; and insight into float, changes to critical path, and revisions to the plan to complete. V. Time Impact Analysis Time Impact Analysis for any asserted delay shall include a network analysis indicating how the Project Manager proposes to incarporate the delay into the project schedule. Each time Time Impact Analysis shall demonstrate the actual time impact of delay as of both the date upon which the delay commenced and the date upon which the delay terminated, reflect the scope and result of all measures which the Project Manager took to migrate the effect and impact of the delay, reflects the status of the work at both the commencement and cessation of the delay and provide the duration computations for all the affected activities. The activity durations used in the time impact analysis shall be those reflected by the latest project schedule update, unless such are otherwise adjusted by mutual agreement. VI. Method for Data Analysis The collected data was analyzed using an Importance Index (Ip.I). The Importance Index was computed using the following formula: 5 Ip.I = Σ a i x i 100 (1) I=1 Where Ip.I = importance index: • ai = constant expressing the weight of the ith response, where i = 1,2,3,4,5; • xi = level of the response given as a percentage of the total responses for each variable; • i = response category index where i = 1, 2, 3, 4, 5; and • W = the highest weight (5). To assist respondents in identifying the level of effect of each variable that could cause delay, Respondents were asked to rank on a scale of 1 (not at all or not relevant) to 5 (most relevant). Using these indices, the rank of the variables can be determined. These rankings were used for comparative importance of the variables as identified by the different group of contractors. VII. Effect Of Delays In Project The delay causes a cost overrun and time overrun of the Project. The time and cost are directly related to each other. When the time of execution of project is delayed it leads to failure of guarantee/warranty of the items/equipments, failure of service period of equipments, damage of equipments due to weather condition and this will lead to non timely execution of job. The critical review under taken in this area of time delay and main (Internal reasons) attribute are:  Unforeseen ground conditions at client premises  Change in scope of the Project  Customers poor decision making at different stages of Project  Contractors cash flow and financial difficulties faced by contractor  Ineffective planning and scheduling by contractor  Delay in procurement of Materials  Improper storage of materials at site  Absence of sound project management of project  Problems with subcontractor External reasons  Political scenario  Economic condition  Government rules and regulations  Market trend
  • 5. Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries DOI: 10.9790/1684-12646171 www.iosrjournals.org 65 | Page Fig. 1 Effect of delay in Mining/Manufacturing project The application of sound project management practice provides a project stakeholder with the means to meet their objective. It can be achieved by using following methodology  Analysis of contemporaneous project documentation  Analysis of Project Management requirement stated in the contract  Analysis of clarity of those requirement  Development of cause and effect relationship between project problems and ensuring damages  Allocation of the responsibility for Project management problems to delay and damages calculation. VIII. Delay Calculating Methodologies Delay work out is made by identifying the delay factor/event which affects the completion of a Project. In general common factors that are observed and are categorically placed as under: a) Delay from client/customer side b) Delay from consultant side c) Delay due to constrains of contract d) Delay due to subcontractor These can be interrelated with each other and shown in fig.2- (Causes of delay in a project). Fig. 2 Showing the different causes of Project Delay In this study, we have chosen the contemporaneous method. It is prepared, based on ―Observational‖ point of view. In this method the contractor prepares a network analysis before the work starts which shows the detailed plan and the implementation process. This network analysis is thoughtfully prepared by someone who understands all the facets of the entire project. It will include appropriate inputs from the various areas and the final form is shared with customers for their comments and possible approval. PROJECT DELAY DUE TO CONSTRAINTS IN CONTRACT CLIENT /CUSTOMER CONTRACTOR CONSULT ANT Over cost Overtime Effects of Delays Abandoned Litigation Disputes Negotiations Law suits
  • 6. Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries DOI: 10.9790/1684-12646171 www.iosrjournals.org 66 | Page Basically this method produces a contemporaneous running commentary on job progress, where all the participants know status and update of the project. When the network is final, the customer reviews at appropriate regular intervals usually each month and observed the work status and accordingly delay activities are marked. The chart is again marked with start dates, percentage completion and completion dates for the affected activity, forecasting jobs, future work schedule and completion etc. It also focuses on possible causes of delays. We describe our points of delay as categorized above and have taken main reasons of delay by the four factors (customer, consultant, contractor, constraints in contract). Apart from these main reasons there may be other reasons which are also responsible for project delays but are not taken in consideration because of their low weight-age in delay calculation. A) Delay from client/customer Fig. 3 Different reasons of delay due to client B) Delay from consultant Fig. 4 Different reasons of delay due to consultant Providing basic inputs/ raw data fom client Delay in approval of Engineering by client. Delay in clearing the hindrences at areas under client/customer Delay in approval of Drawings/ documents by consultants Delay in approving changes in facility/ upgrading of system beyond contract Delay in providing Inspection clearence
  • 7. Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries DOI: 10.9790/1684-12646171 www.iosrjournals.org 67 | Page C) Delay due to constrains of contract Fig. 5 Different reasons of delay due to constrains of contract D) Delay due to Contractor/Sub-contractor Fig. 6 Different reasons of delay due to contractor/sub-contractor Delay in accepting additional service provider/ vendor Delay in correct interpretation of contract in terms of provisions of contract Contractor/Subcontractor and their ease for providing /accepting services
  • 8. Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries DOI: 10.9790/1684-12646171 www.iosrjournals.org 68 | Page Fig. 7 Typical flow chart for delay control IX. Delay Time Calculation In context to calculate the delay we have to define few terms used in the study a) Date of Occurrence: This refers to the date when an activity started by the contractor based on agreed chart. b) Date of Cessation: This refers to the date on which the said activity is completed. c) Weight age: We adopt the principle that a activity which is the root of other activity gets delayed will delay all other related activity. So 100% weight age is awarded to such root activities. The activities which are not falling under root activity and is not affecting the total project weight age calculation may be derived from time allocated for completion of their portion of work in comparison to total time of completion of project. The weight age is calculated in percentage only. Table 1 Calculation of delay Sl. No. Nature of Hindrance Date of Occurrence (As per approved chart) A Date of Cessation (As per approved chart) A‘ Date of Cessation ( As per actual completion) B Gross period of delay (No. of days) C Weig ht age (in %) D Effective period of delay (No. of days) E= C x D Gross time allotted as per appro ved Chart Project Contr actual time allotted (Days) 1 Delay due to Client 1.A Providing basic input i.e. coordinates for wagon tippler complex 05.10.08 28.11.08 14.01.09 102 100 102 47 910 1.B Variation in soil data provide at various junction house 21.09.08 23.01.09 19.04.10 447 100 447 130 910
  • 9. Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries DOI: 10.9790/1684-12646171 www.iosrjournals.org 69 | Page So, a total delay of project is 2538 days or 6.95 years. Apart from total delay, the delay caused due to consultant and customer is 1167 days or 3.19 years. A pie chart is made based on the above calculation and shown below: 1.C Change in voltage level from 6.6 to 11kv incoming feeder LTSS buildings 29.01.09 19.03.09 13.05.10 470 51.64 243 50 910 2 Delay due to consultant 2A Delay in Approval of Basic Engineering Drawings of Structural Design of Gallery & Trestle for Conv. No. 11 11.05.10 25.05.10 22.08.11 469 51.51 242 14 910 2B Delay in issue of Inspection certificate/ Inspection waiver certificate/ Dispatch clearance 05.04.12 19.04.12 14.11.12 223 24.50 55 14 910 3 Delay due to Constrains of Contract 3A Delay in approval of additional vendors due to non availability of vendors in contract 18.06.09 2.07.09 11.12.09 177 19.45 35 14 910 3B Change in size of Area Repair Shop 01.02.09 10.03.09 18.08.09 198 21.75 43.08 38 910 4 Delay due to contractor 4A Delay by Yard Equipment manufacturer in supply of equipments 10.01.09 04.07.10 18.01.11 738 81.09 598 541 910 4B Delay by Utilities Sub Contractor in supply of equipments(Fire fighting, water systems) 05.01.09 27.06.10 23.04.11 839 92.19 773 539 910 Total Delay 2538 days or 6.95 Years
  • 10. Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries DOI: 10.9790/1684-12646171 www.iosrjournals.org 70 | Page X. Extra Claim When this delay analysis is accepted by customer, the claims are generally made in the following categories:  Extra Wages and salaries  Project Management cost  Site activity cost  Misc Item extra cost during project overrun The extra claim is tabulated as: Table 2 Extra claim Sl. No. Category No. of worker Minimum wages per day(Rs) No. of working days per month No. of month Total wages/salaries to be paid (Rs) 1 Skilled 20 nos. 221 26 83.4 9,584,328 2 Semi Skilled 10 nos. 210 26 83.4 4,55,3640 3 Un Skilled 20 nos. 202 26 83.4 8,760,336 4 Management Staff 25 nos. @ 1200000/month 30 83.4 100080000 Total 122,978,304 1. Extra Wages and salaries: This consists of extra wages and salaries of workers, supervisors and engineers during overtime or in case of extension of a project. 2. Project Management cost: This consists of bank guarantee charges towards customers for extra period. The project completion is considered for 910 days or 30 months. The project management costs also includes cost of record keeping, retrieving records as and when required and providing all support to other departments and cost incurred in terms are tours. This figures comes to around 200 00000 for a period of 83.4 months (Table2). Table 3 Site activity cost 3. Site Activity cost: The extra time for a site establishment must be included in a project. The unexpected cost which is paid due to unforeseen reasons attributes to hike this cost against this category. This can be shown in Table 3. 4. Misc Item extra cost during project overrun: This is basically procurement of items which are purchased in emergency situation due to sudden damage of parts or, scarcity of parts. Total cost incurred during delay periods are tabulated below. Table 4 Misc Item extra cost during project overrun Sl. No. Description Amount incurred Total amount 1 Emergency purchase of fasteners 10,0000 10,0000 2 Purchase of hydraulic parts for wagon tippler 25,098780 25,098780 3 Purchase of couplings of motor damaged due to wear out 10,087100 10,087100 4 Purchase of electrical switches 54980735 54980735 5 Purchase of High mast parts 40987600 40987600 Total 131,254,215 Sl. No. Category No. of persons Rent/cost of Establishment per month No. of month Total amount to be paid (Rs) 1 Site Guest House 10 25,000 83.4 2,085,000 2 Site office 15 2000 83.4 166800 3 Office boy wages 2 12000 83.4 1,000,800 4 Office Expenditures 15 10000 83.4 834000 5 Vehicle cost 5 35000/vehicle 83.4 14,595,000 6 Fatal damage 100000 for total period 100000 Total 18,781,600
  • 11. Delays Analysis of Projects and Effects of Delays in the Mining/Manufacturing Industries DOI: 10.9790/1684-12646171 www.iosrjournals.org 71 | Page Now we add all the extra cost (1+2+3) = 122,978,304 + 200 00000 + 18,781,600+ 131,254,215 Grand Total = Rs 293,014,119 This is the total extra cost incurred due to Project over run of 83.4 months. XI. Conclusions The study was carried out to investigate various reasons of delay in execution of a mining/manufacturing project. Results show that less than 50% delay is attributable to customer and client and more than 50% of problems are attributable to contractor. Also this study helps in identifying various reasons and factors causing delay from customer, consultant and contractor‘s end. Also it helps in highlighting flaws of contract. The importance of delay causes in mining/manufacturing project in India has been identified clearly. Although this research was conducted in the commercial sector in India, the results may also be applicable for similar projects in other developing countries. The identification of important delay causes helps a contractor in seeking extra time for completion from the customer. If the contractor wins in explaining the reasons of delay and gets a contractual extension of time than the customer is bound to pay extra claim to contractor. The contractor gain or loss is huge in terms of its credential in the market in terms of a successful presentation of delay analysis. Further methodology is suggested to work out critical causes from available ones by two techniques: Relative importance index and Importance index as a function of severity index and frequency index. Survey questionnaire must be prepared based on these techniques. It is proposed to carry out ranking of causes of delay from two different techniques in the next phase of research. References [1] Al-Ghafly MA. , Delays in the construction of public utility projects in Saudi Arabia., Master thesis, CEM Dept., KFUPM, Dhahran, Saudi Arabia, 1995. [2] Al-Momani, A.H. (2000).Construction delay: a quantitative analysis, Journal of ProjectManagement18, 51-59. [3] Alwi, S. (2002). ―Non Value-Adding Activities in the Indonesian Construction Industry: Variables and Causes‖. Unpublished Doctoral Thesis, Queensland University of Technology, Brisbane,Australia. [4] Arvan, L. and Leite. (1990), Cost Overruns in Long-Term Project,' International Journal of Industrial Organization, 8(3), 443-67. Banerjee-Guha, Swapna (2009), Neoliberalizing the ‗Urb [5] Chan, D. W. M. and Kumaraswamy, M. M. (1997) ―A Comparative Study of Causes of Time Overruns in Hong Kong Construction Projects‖. International Journal of Project Management, Vol. 15, No. 1, 55-63. [6] C.T.Ramanathan, N. S. Potty and A. B. Idrus, ―Analysis of time and cost overrun in Malaysian construction‖, Advanced Materials Research Journal. Vol. 452-453, pp. 1002-1008 [7] Frimpong Y, Oluwoye J, Crawford L. Causes of delay and cost overruns in construction of groundwater projects in a developing countries; Ghana as a case study. Int J Project Manage 2003;21:321–6. [8] Fugar, F D K and Agyakwah‐Baah, A B ―Delays in building construction projects in Ghana‖, Australasian Journal of Construction Economics and Building, 10 (1/2) (2010) 103‐116. [9] Ganuza, Juan-José. (2007), Competition and cost overruns in Procurement,' International Journal of Industrial Organization, Vol. 55(4), 633-660. [10] Hampson, K.D., Peters, R.J. and Walker, D.H.T. (2001) ―Negotiation and Conflict in Innovative Procurement Environments: The National Museum of Australia‖. CIB World Building Congress, April, Wellington. [11] Kometa ST, Olomolaiye PO, Harris FC. Attributes of UK construction clients influencing project consultants performance.Construction Manage Econ 1994;12:433–443. [12] Kumaraswamy, M.M. and Chan, W.M. (1998).Contributes to Construction Delays, Journal of Construction Management & Economics, 16; 17-29. [13] Ling, F. Y. Y. & Hoi, L. (2006). Risks faced by Singapore firms when undertaking construction projects in India. International Journal of Project Management, Vol. 24, pp. 261-270. [14] Luu, V. T.; Kim, S.; Tuan, N. V. & Ogunlana, S. O. (2009). Quantifying schedule risk in construction projects using Bayesian belief networks. International Journal of Project Management, Vol. 27, pp. 39-50, www.intechopen. [15] Mendenhall, W.; Reinmuth, J.E. and Beaver, R.J. (1993) Statistics for Management and Economics. Duxbury Press, California [16] Miller, R. & Lessard, D. (2001). Understanding and managing risks in large engineering projects, International Journal of Project Management, Vol. 19, No. 8, pp. 437-443. [17] M. Sambasivan and Y.W. Soon (2007) Causes and effects of delays in Malaysian construction industry, International Journal of Project Management. 25, p. 517-526. (2002) [18] N. Vagenas, N. Runciman, and S. R.clément, ―A methodology for maintenance analysis of mining equipment‖ International Journal of Surface Mining, Reclamation and Environment, vol. 11, no. 1, pp. 33–40, 1997. [19] Ogunlana S.O. Prokuntong, K. and Jearkjirm, V. (1996). Construction Delays in Fast Growing Economy Comparing Thailand with Other Economies. International Journal of Project Management 14 (1),37-45. [20] Prakash Rao, B. And Joseph Camron Culas Causes of delays in construction projects International Journal of Current Research Vol. 6, Issue, 06, pp.7219-7222, June, 2014.