International Journal of Engineering and Science Invention (IJESI) is an international journal intended for professionals and researchers in all fields of computer science and electronics. IJESI publishes research articles and reviews within the whole field Engineering Science and Technology, new teaching methods, assessment, validation and the impact of new technologies and it will continue to provide information on the latest trends and developments in this ever-expanding subject. The publications of papers are selected through double peer reviewed to ensure originality, relevance, and readability. The articles published in our journal can be accessed online.
Importance and Functions of Bills of Quantities in the Construction Industry:...inventionjournals
Bills of Quantities (BQ) is one of systematic ways applied in the construction industry in which its primary function is to record items of works for tendering purposes and to create a fair agreement among the parties involved for contracting purposes. However, there are some issues pertaining to BQ functions such as BQ is a misunderstood facet in the construction industry today, BQ is only useful for tendering purposes, BQ’s benefit is not fully utilised by the construction team and most of them cannot relate BQ with everyday construction works and processes. Therefore, the purpose of this paper is to study on the importance of BQ and its functions in the construction industry. A content analysis was used to identify the importance and functions of BQ from reviewing articles and books. Findings from this paper are beneficial in providing knowledge to the education field and construction teams on the importance and functions of BQ in the construction industry.
It is realized that Nepalese construction had undertaken a high rise in its image internationally and nationally and has been participating in various organization as an active member. Besides these, there are many rumours and conflicts about the capability of Nepalese contractors about their technical and financial ability for not completing the projects undertaken by them within the given timeframe and of standard quality. Although construction entrepreneur of Class A in Nepal, have the opportunities to withstand in construction industry (as country is still in construction phase of infrastructure development) with full enthusiasm and effort, they seems to be demoralized by the policies, rules, guidance and support from the government and procedure of procurement of donor agencies during bidding in Mega Projects.
The study has covered construction firms registered as class A construction entrepreneur. The numbers of construction firms studied were fifty one (51). Random sampling method was performed to select the respondents. A questionnaire was developed to collect the datas for the study. The close ended question, open ended question, and ranking method of prioritization was adopted to obtain the necessary datas from the respondents.
The purpose of the study was to compare the existing equipment capabilities of Class A construction entrepreneurs with the prescribed requirement as per CBA 2055 & CBR 2056 and also to determine the current capacity of the class A construction entrepreneurs in terms of technical and financial capabilities. The study also has covered the exploration of common problems and difficulties felt in criteria of achieving qualification documents during bidding procedure , receiving payment during payment schedule, , taxation part, hiring qualified human resource in different construction sector and insecure felt during stages of tender purchase, tender drop and construction site execution works by class A construction entrepreneurs.
Percentage, frequency and charts were used to analyze the data. The result has showed that, in owning equipments most of the companies have failed to meet the prescribed standard as per CBA 2055 & CBR 2056. Only few numbers of contractors are extremely satisfied with their business. There are various factors like annual turnover & similar experience part in qualification procedure, escalated amount & running bill payment in payment procedure, insecurity due to hooliganism in construction business during site execution and tender drop, taxation system during refunding of the tax deducted at source amount. The research has also shown the unavailability of human resources in tunnel sector, hydropower sector and bridge sector in construction sector in present context.
IRJET- Developing Cost Prediction Model for Building ProjectIRJET Journal
1. The document discusses developing a cost prediction model for building projects using multiple regression analysis. It aims to identify factors affecting project cost and analyze their significance.
2. Seven major factors were selected for the cost prediction model: design related factors, time or cost related factors, parties experience related factors, financial issues related factors, bidding situations related factors, project characteristics related factors and estimating process related factors.
3. The cost prediction model will be developed using SPSS software by determining the factors governing project cost through a questionnaire survey that examines these seven factors.
A study on factors affecting performance of indian cement industryAlexander Decker
This document summarizes a study on the performance of the Indian cement industry from 1991-2006. It analyzes factors like capacity utilization, productivity, profits, and costs. The study focuses on the industry macro level and uses Chettinadu Cement Corporation Limited as a case study at the micro level. Key findings include:
1) Labor and capital productivity in the industry declined over time but remained positive, indicating rational resource use. Technology also contributed significantly to increased production.
2) Estimated production functions for the industry and case study found constant returns to scale and positive marginal productivity of labor but negative marginal productivity of capital.
3) Most plants shifted to dry production processes, which are more fuel efficient and
Presentation by Mr. Kevin NG, Director, Chun Wo Building Construction Ltd.
HKIPM‐HKIBIM Joint Conference: BIM in Project Management
Details of Conference
Date: 2‐Apr‐2014 (Wed)
Time: 2:00 pm – 5:00 pm
Venue: Chiang Chen Studio Theatre – The Hong Kong Polytechnic University
Organizers:
Hong Kong Institute of Project Management (HKIPM)
http://www.hkipm.org.hk/
The Hong Kong Institute of Building Information Modelling (HKIBIM)
http://www.hkibim.org
Sole Sponsor:
建造業議會 - Construction Industry Council
http://www.hkcic.org/
Mr. Wan is a senior assistant technical director at TSR company with over 15 years of experience as a quantity surveyor. As a quantity surveyor, he prepares cost estimates for clients and ensures proper qualifications are met which involves registering with professional bodies and passing exams. In the pre-construction phase, he measures quantities from tender drawings to estimate project costs, and in post-construction he compiles variation orders and finalizes the contract sum. Key responsibilities include cost estimation, contract negotiation, variation evaluation, payment applications, and cash flow management.
We are an independent firm of Project Managers and Quantity Surveyors based in Preston, UK that has 60 years of combined experience in client negotiation. We offer a range of services including project management, quantity surveying, employers agency, commercial consultancy, and CDM coordination. As a Quantity Surveyor, some of our key responsibilities include measuring quantities of construction materials, preparing bills of quantities and schedules, cost planning, and ensuring projects are delivered on budget.
Importance and Functions of Bills of Quantities in the Construction Industry:...inventionjournals
Bills of Quantities (BQ) is one of systematic ways applied in the construction industry in which its primary function is to record items of works for tendering purposes and to create a fair agreement among the parties involved for contracting purposes. However, there are some issues pertaining to BQ functions such as BQ is a misunderstood facet in the construction industry today, BQ is only useful for tendering purposes, BQ’s benefit is not fully utilised by the construction team and most of them cannot relate BQ with everyday construction works and processes. Therefore, the purpose of this paper is to study on the importance of BQ and its functions in the construction industry. A content analysis was used to identify the importance and functions of BQ from reviewing articles and books. Findings from this paper are beneficial in providing knowledge to the education field and construction teams on the importance and functions of BQ in the construction industry.
It is realized that Nepalese construction had undertaken a high rise in its image internationally and nationally and has been participating in various organization as an active member. Besides these, there are many rumours and conflicts about the capability of Nepalese contractors about their technical and financial ability for not completing the projects undertaken by them within the given timeframe and of standard quality. Although construction entrepreneur of Class A in Nepal, have the opportunities to withstand in construction industry (as country is still in construction phase of infrastructure development) with full enthusiasm and effort, they seems to be demoralized by the policies, rules, guidance and support from the government and procedure of procurement of donor agencies during bidding in Mega Projects.
The study has covered construction firms registered as class A construction entrepreneur. The numbers of construction firms studied were fifty one (51). Random sampling method was performed to select the respondents. A questionnaire was developed to collect the datas for the study. The close ended question, open ended question, and ranking method of prioritization was adopted to obtain the necessary datas from the respondents.
The purpose of the study was to compare the existing equipment capabilities of Class A construction entrepreneurs with the prescribed requirement as per CBA 2055 & CBR 2056 and also to determine the current capacity of the class A construction entrepreneurs in terms of technical and financial capabilities. The study also has covered the exploration of common problems and difficulties felt in criteria of achieving qualification documents during bidding procedure , receiving payment during payment schedule, , taxation part, hiring qualified human resource in different construction sector and insecure felt during stages of tender purchase, tender drop and construction site execution works by class A construction entrepreneurs.
Percentage, frequency and charts were used to analyze the data. The result has showed that, in owning equipments most of the companies have failed to meet the prescribed standard as per CBA 2055 & CBR 2056. Only few numbers of contractors are extremely satisfied with their business. There are various factors like annual turnover & similar experience part in qualification procedure, escalated amount & running bill payment in payment procedure, insecurity due to hooliganism in construction business during site execution and tender drop, taxation system during refunding of the tax deducted at source amount. The research has also shown the unavailability of human resources in tunnel sector, hydropower sector and bridge sector in construction sector in present context.
IRJET- Developing Cost Prediction Model for Building ProjectIRJET Journal
1. The document discusses developing a cost prediction model for building projects using multiple regression analysis. It aims to identify factors affecting project cost and analyze their significance.
2. Seven major factors were selected for the cost prediction model: design related factors, time or cost related factors, parties experience related factors, financial issues related factors, bidding situations related factors, project characteristics related factors and estimating process related factors.
3. The cost prediction model will be developed using SPSS software by determining the factors governing project cost through a questionnaire survey that examines these seven factors.
A study on factors affecting performance of indian cement industryAlexander Decker
This document summarizes a study on the performance of the Indian cement industry from 1991-2006. It analyzes factors like capacity utilization, productivity, profits, and costs. The study focuses on the industry macro level and uses Chettinadu Cement Corporation Limited as a case study at the micro level. Key findings include:
1) Labor and capital productivity in the industry declined over time but remained positive, indicating rational resource use. Technology also contributed significantly to increased production.
2) Estimated production functions for the industry and case study found constant returns to scale and positive marginal productivity of labor but negative marginal productivity of capital.
3) Most plants shifted to dry production processes, which are more fuel efficient and
Presentation by Mr. Kevin NG, Director, Chun Wo Building Construction Ltd.
HKIPM‐HKIBIM Joint Conference: BIM in Project Management
Details of Conference
Date: 2‐Apr‐2014 (Wed)
Time: 2:00 pm – 5:00 pm
Venue: Chiang Chen Studio Theatre – The Hong Kong Polytechnic University
Organizers:
Hong Kong Institute of Project Management (HKIPM)
http://www.hkipm.org.hk/
The Hong Kong Institute of Building Information Modelling (HKIBIM)
http://www.hkibim.org
Sole Sponsor:
建造業議會 - Construction Industry Council
http://www.hkcic.org/
Mr. Wan is a senior assistant technical director at TSR company with over 15 years of experience as a quantity surveyor. As a quantity surveyor, he prepares cost estimates for clients and ensures proper qualifications are met which involves registering with professional bodies and passing exams. In the pre-construction phase, he measures quantities from tender drawings to estimate project costs, and in post-construction he compiles variation orders and finalizes the contract sum. Key responsibilities include cost estimation, contract negotiation, variation evaluation, payment applications, and cash flow management.
We are an independent firm of Project Managers and Quantity Surveyors based in Preston, UK that has 60 years of combined experience in client negotiation. We offer a range of services including project management, quantity surveying, employers agency, commercial consultancy, and CDM coordination. As a Quantity Surveyor, some of our key responsibilities include measuring quantities of construction materials, preparing bills of quantities and schedules, cost planning, and ensuring projects are delivered on budget.
Covarrubias et al. 2016 - VSM for Improving the Certificate of Occupancy Pro...Andres Covarrubias Vicuña
This document summarizes a study that used Value Stream Mapping (VSM) to improve the Certificate of Occupancy (CO) process for real estate projects in Chile. The study found the CO process was bureaucratic and caused delays. It conducted surveys of practitioners to identify inefficiencies. It then created current and future state VSM diagrams, with the future state showing improvement strategies. These strategies were tested in a case study housing project, demonstrating the ability of VSM to reduce CO process duration. The study contributes a list of Chilean CO process inefficiencies and evidence that VSM can successfully improve administrative construction processes.
This document is a research proposal submitted by Than Lek Mei to compare the cost of buildings constructed using the conventional construction method versus the Industrialized Building System (IBS) in Malaysia. The proposal includes an introduction that provides background on IBS implementation in Malaysia, a problem statement on the low adoption of IBS despite its benefits, and a literature review on previous similar studies that have shown conflicting results. The research aims and objectives are defined as determining the most common IBS systems used in Malaysia, identifying factors affecting the costs of both methods, and comparing costs between methods for residential buildings. The proposed research design involves document analysis, questionnaires, interviews, and case studies.
Good a framework for building quality into construction projects part isoenarto soendjaja
The document discusses a framework for building quality into construction projects. It begins by noting that while total quality management (TQM) approaches have been applied in manufacturing, their use in construction has received less attention. The document then reviews existing quality improvement initiatives in construction and identifies limitations. It establishes requirements for an effective quality framework, including addressing the construction process and quality elements. The framework developed incorporates manufacturing improvement methods and includes quality policy, construction process, people/culture, and improvement methods. Guidelines have also been created for implementing quality improvement methods.
Quantity surveying dissertation effectiveness of life cycle costing in sustai...Steve Jones
This dissertation examines the effectiveness of life cycle costing (LCC) in sustainable construction. LCC allows evaluation of design options by considering all capital, operational, maintenance, and disposal costs over a building's lifetime. While an initial increase in capital expenditure may result in long-term savings, LCC faces limitations in its application within the industry. The research aims to identify how LCC can be integrated with sustainable design and whether it can effectively reduce environmental impacts. An online questionnaire was distributed to collect data from industry professionals on LCC use and barriers. The results will be analyzed to draw conclusions and recommendations on supporting LCC as a sustainability tool.
Lean Waste Assessment and Blue Print for Elimination of Waste Through Lean Di...IRJET Journal
The document discusses lean waste assessment and methods to eliminate waste in the construction industry through lean digital methods. It analyzes the types of managerial waste in construction projects, ranks them based on frequency of occurrence, and ranks various lean waste elimination methods based on their use in industry. The goal is to determine the key drivers of waste in construction and the most suitable waste elimination method to reduce managerial waste from a lean perspective.
The document discusses perceptions of time, cost, and quality (TCQ) management on building projects based on a survey of clients, architects, quantity surveyors, engineers, project managers, and contractors in South Africa.
The key findings from the survey include:
1) Clients rated quality as more important than time, contrary to other project participants.
2) Most clients believed the procurement team matched their needs to appropriate procurement systems, but the procurement team did not generally see this as true.
3) Clients believed they rarely changed original project briefs after starting, but consultants saw brief changes occurring more often.
4) Perceptions varied on whether projects were completed within agreed budgets, with
This thesis proposal examines multi-criteria bid evaluation systems for construction projects in Nepal. It discusses how the Department of Urban Development and Building Construction currently awards contracts primarily to the lowest bidder, which can lead to delays, cost overruns and quality issues. The proposal aims to identify qualification criteria beyond price to evaluate contractors. It will recommend a suitable multi-criteria evaluation model for selecting contractors through a literature review and surveys of engineers, consultants and contractors regarding their perceptions. The findings could influence procurement policies and help improve the success of public construction projects in Nepal.
A Case Study On Applying Lean Construction To ConcreteDawn Cook
The document discusses applying lean construction principles to concrete construction projects. It studies a concrete construction project to identify waste and proposes solutions. At the project level, lack of coordination among subcontractors caused schedule delays. The paper proposes using last planner concepts, linear scheduling, and graphic scheduling to improve communication and look-ahead planning. At the operation level, a systematic approach is applied to identify waste, redesign work procedures, and use 3D animation for employee training to reduce waste and resistance to changes.
Study of Factors Affecting the Implementation of BIM: An Evaluation of Risk V...IRJET Journal
This document summarizes a research paper that studied the factors affecting the implementation of building information modeling (BIM) and the risk variability at different construction stages. It first provides background on BIM and its applications in quantity surveying, including developing cost schedules and quantification. It then discusses problems with traditional paper-based methods for developing bills of quantities. The study objectives were to examine BIM applications in quantity surveying, identify factors influencing BIM adoption, and determine construction cost risks and variability. A literature review covered past research on using BIM for quantity takeoffs, estimation, and how BIM impacts the role of quantity surveyors. The conclusion was that BIM-assisted estimates provide better performance than traditional methods.
Cost Effective Methods in Construction Engineeringcivejjour
The economic impact of construction cost overrun is a possible loss of the economic justification for the
project. The financial impact of a cost overrun results in demand for construction investment credits.
Therefore reliable estimates of construction cost are an important aspect to the contemporary construction
companies especially during the conceptual phase of lifecycle management. In this paper a cost-effective
analysis is done using one of the cost effective construction technique called Rat Trap Bond versus Flemish
bond and when estimated with CPWD 2012 schedule of rates it is proved that Low cost techniques such as
rat trap bond provides better cost effectiveness as compared to conventional Flemish bond construction
method.
Cost Effective Methods in Construction Engineeringcivejjour
The economic impact of construction cost overrun is a possible loss of the economic justification for the project. The financial impact of a cost overrun results in demand for construction investment credits. Therefore reliable estimates of construction cost are an important aspect to the contemporary construction companies especially during the conceptual phase of lifecycle management. In this paper a cost-effective analysis is done using one of the cost effective construction technique called Rat Trap Bond versus Flemish bond and when estimated with CPWD 2012 schedule of rates it is proved that Low cost techniques such as rat trap bond provides better cost effectiveness as compared to conventional Flemish bond construction method.
This document summarizes research adapting the Supply Chain Operations Reference (SCOR) model to the construction industry. The SCOR model was originally developed for manufacturing but lacks consideration of construction industry characteristics. Through case studies of construction projects over five years, the researchers identified necessary adaptations. They developed the Builder's SCOR (BSCOR) model which retains SCOR's structure but adds new processes and metrics to capture material delivery to sites, on-site procurement, construction, and planning activities. The BSCOR model allows mapping and measuring performance of construction supply chains from suppliers to project completion.
Building information-modeling-and-construction-projects-performance-the-effec...oircjournals
In most of the construction projects, there is always an element of running into delays in project completion time, costs overruns from variations and associated time overruns, lack of satisfying client requirements, clashes on site during construction – just to mention a few. Building Information Modelling (BIM) is being used to solve most of these challenges that pose such risks to a project. The study looked the effect of scheduling on performance of project constructions in Uasin Gishu County. The study targeted a population of 197 respondents who constitute of Technical staff and Non - technical staff. The study used census research design. Questionnaires were used to collect information from respondents. In order to ascertain reliability of the research instruments, the researcher piloted the instruments by distributing 30 questionnaires to respondents from Uasin Gishu County Government selected randomly from the various sections, which were not be part of the county to be sampled for this study. Descriptive statistics was used to analyse the data. Descriptive statistics included frequency, percentages, means, standard deviation and frequency distribution. Inferential statistics used was correlation and linear regression. The study found out that there was a significant and positive effect of project scheduling on construction projects performance Uasin Gishu County Government (β=0.198; p<0.05). The study concluded that proper project scheduling leads to an increased project performance risk management plays an important role in project management because without it project managers cannot define their objectives for future and project monitoring plays a vital role in project manager’s decision making processes since it helps project managers and their teams to foresee potential risks and obstacles that if left unaddressed could derail the project. The study recommends that the County Government should continue with good practices of ensuring resources are allocated with good practices of ensuring resources are allocated to projects from interception until closure.
Investigating the Effectiveness of Construction Practices in Delayed Resident...ijtsrd
Construction schedule delays could also be explained by means of the late completion of construction add comparison of designed schedule of project. If the explanations of the development projects schedule delay are found then the project schedule delay in construction may be reduced. During this study, factors of schedule delay were selected after the past review of literature then arranged them in primary sets. On following the survey outcomes, the highest causative groups and factors that require more consideration of delays in kokan region were explained. Satej R. Desai | A. T. Pawar "Investigating the Effectiveness of Construction Practices in Delayed Residential Projects in Gadhinglaj City through Time and Cost Perspective" Published in International Journal of Trend in Scientific Research and Development (ijtsrd), ISSN: 2456-6470, Volume-4 | Issue-3 , April 2020, URL: https://www.ijtsrd.com/papers/ijtsrd30530.pdf Paper Url :https://www.ijtsrd.com/engineering/civil-engineering/30530/investigating-the-effectiveness-of-construction-practices-in-delayed-residential-projects-in-gadhinglaj-city-through-time-and-cost-perspective/satej-r-desai
Multivariate approach to benchmarking quality prediction parameters in buildi...Alexander Decker
This document discusses the development of a multivariate model to benchmark quality prediction parameters in building maintenance works. It begins with an introduction on the importance of quality assurance in construction. A literature review is then presented on previous studies related to factors affecting construction quality. The document then describes the research methods, which included distributing questionnaires to construction professionals and analyzing the data using factor analysis and stepwise multiple regression. The goal of the research was to develop a total maintenance operation management model that incorporates key quality parameters to help practitioners monitor and improve quality in building maintenance works.
Basics of Quantity Surveying
Introduction
Course Objectives
Course Outline
Understand the history of Quantity Surveying
Understand the duties and functions of a Quantity Surveying
Know standard method of Measurement of building works
Understand in detail the knowledge of Measurement
Understand the history of Quantity Surveying
Understand the duties and functions of a Quantity Surveying
Know standard method of Measurement of building works
Understand in detail the knowledge of Measurement
Recommendation of an appropriate procurement route to suit the type of project
Risk management, including identification and
Due diligence reporting by confirming a scope of services provided in a main contractor’s tender
Selection of an appropriate form of contract
Life-cycle costing options for various types of construction to demonstrate benefits whilst a building is occupied
Advice on dispute resolution services if there is conflict of opinion with a contractor
Business feasibility studies to assess the viability of a scheme prior to design
Acting as client’s/employer’s agent under the title of project manager
Certification of buildings with Energy Performance Certificates (EPC)
Construction Design and Management Regulations (CDM) coordinator with health and safety.
IRJET- Study of Supplier Evaluation and Development Practices in Supply Chain...IRJET Journal
This document discusses supplier evaluation and development practices in the construction industry supply chain. It begins with an abstract that outlines the purpose of studying supplier evaluation methods and selection issues. It then provides background on the importance of materials procurement in construction projects. The introduction defines supply chain management and discusses the key role that suppliers play. It indicates that while supplier evaluation is common in manufacturing, it is less developed in the construction industry. The problem statement reviews research on supply chain management and the construction supply chain to understand current practices and barriers to effective supplier evaluation.
A Comparative Study Of Construction Cost And Commercial Management Services I...Scott Faria
This document provides a summary of a research study that compares construction cost and commercial management practices in the UK and China. It finds that while the UK has a well-established quantity surveying profession dating back over 170 years, China is still transforming its historically state-run construction industry to a more market-based system. The study develops a framework to map the UK's cost and commercial management systems to China's engineering cost systems. It analyzes the structures and operations of the relevant professional bodies RICS and CECA. It also reports the findings of industry surveys that show differences in firm profiles, fee structures, and use of technologies between the two countries. The study concludes that while both countries' practices have progressed significantly, variations still exist
Development of Building Quality Measurement Tool: Building Construction Quali...IRJET Journal
This document discusses the development of a Building Construction Quality Index (BCQI) tool to objectively measure the quality of building construction projects in India. It reviews different definitions of construction quality and existing quality measurement systems. It then describes developing the BCQI, which rates projects based on weighted quality attributes and sub-attributes identified through literature review. The tool allows comparing completed and ongoing project quality, tracking quality over time, and providing guidelines for continuous quality improvement. The document aims to contribute to improved quality measurement and management in the Indian construction industry.
Procurement principle towards effective management of construction projectseSAT Publishing House
IJRET : International Journal of Research in Engineering and Technology is an international peer reviewed, online journal published by eSAT Publishing House for the enhancement of research in various disciplines of Engineering and Technology. The aim and scope of the journal is to provide an academic medium and an important reference for the advancement and dissemination of research results that support high-level learning, teaching and research in the fields of Engineering and Technology. We bring together Scientists, Academician, Field Engineers, Scholars and Students of related fields of Engineering and Technology.
“An Outlook of the Ongoing and Future Relationship between Blockchain Technologies and Process-aware Information Systems.” Invited talk at the joint workshop on Blockchain for Information Systems (BC4IS) and Blockchain for Trusted Data Sharing (B4TDS), co-located with with the 36th International Conference on Advanced Information Systems Engineering (CAiSE), 3 June 2024, Limassol, Cyprus.
In the rapidly evolving landscape of technologies, XML continues to play a vital role in structuring, storing, and transporting data across diverse systems. The recent advancements in artificial intelligence (AI) present new methodologies for enhancing XML development workflows, introducing efficiency, automation, and intelligent capabilities. This presentation will outline the scope and perspective of utilizing AI in XML development. The potential benefits and the possible pitfalls will be highlighted, providing a balanced view of the subject.
We will explore the capabilities of AI in understanding XML markup languages and autonomously creating structured XML content. Additionally, we will examine the capacity of AI to enrich plain text with appropriate XML markup. Practical examples and methodological guidelines will be provided to elucidate how AI can be effectively prompted to interpret and generate accurate XML markup.
Further emphasis will be placed on the role of AI in developing XSLT, or schemas such as XSD and Schematron. We will address the techniques and strategies adopted to create prompts for generating code, explaining code, or refactoring the code, and the results achieved.
The discussion will extend to how AI can be used to transform XML content. In particular, the focus will be on the use of AI XPath extension functions in XSLT, Schematron, Schematron Quick Fixes, or for XML content refactoring.
The presentation aims to deliver a comprehensive overview of AI usage in XML development, providing attendees with the necessary knowledge to make informed decisions. Whether you’re at the early stages of adopting AI or considering integrating it in advanced XML development, this presentation will cover all levels of expertise.
By highlighting the potential advantages and challenges of integrating AI with XML development tools and languages, the presentation seeks to inspire thoughtful conversation around the future of XML development. We’ll not only delve into the technical aspects of AI-powered XML development but also discuss practical implications and possible future directions.
Covarrubias et al. 2016 - VSM for Improving the Certificate of Occupancy Pro...Andres Covarrubias Vicuña
This document summarizes a study that used Value Stream Mapping (VSM) to improve the Certificate of Occupancy (CO) process for real estate projects in Chile. The study found the CO process was bureaucratic and caused delays. It conducted surveys of practitioners to identify inefficiencies. It then created current and future state VSM diagrams, with the future state showing improvement strategies. These strategies were tested in a case study housing project, demonstrating the ability of VSM to reduce CO process duration. The study contributes a list of Chilean CO process inefficiencies and evidence that VSM can successfully improve administrative construction processes.
This document is a research proposal submitted by Than Lek Mei to compare the cost of buildings constructed using the conventional construction method versus the Industrialized Building System (IBS) in Malaysia. The proposal includes an introduction that provides background on IBS implementation in Malaysia, a problem statement on the low adoption of IBS despite its benefits, and a literature review on previous similar studies that have shown conflicting results. The research aims and objectives are defined as determining the most common IBS systems used in Malaysia, identifying factors affecting the costs of both methods, and comparing costs between methods for residential buildings. The proposed research design involves document analysis, questionnaires, interviews, and case studies.
Good a framework for building quality into construction projects part isoenarto soendjaja
The document discusses a framework for building quality into construction projects. It begins by noting that while total quality management (TQM) approaches have been applied in manufacturing, their use in construction has received less attention. The document then reviews existing quality improvement initiatives in construction and identifies limitations. It establishes requirements for an effective quality framework, including addressing the construction process and quality elements. The framework developed incorporates manufacturing improvement methods and includes quality policy, construction process, people/culture, and improvement methods. Guidelines have also been created for implementing quality improvement methods.
Quantity surveying dissertation effectiveness of life cycle costing in sustai...Steve Jones
This dissertation examines the effectiveness of life cycle costing (LCC) in sustainable construction. LCC allows evaluation of design options by considering all capital, operational, maintenance, and disposal costs over a building's lifetime. While an initial increase in capital expenditure may result in long-term savings, LCC faces limitations in its application within the industry. The research aims to identify how LCC can be integrated with sustainable design and whether it can effectively reduce environmental impacts. An online questionnaire was distributed to collect data from industry professionals on LCC use and barriers. The results will be analyzed to draw conclusions and recommendations on supporting LCC as a sustainability tool.
Lean Waste Assessment and Blue Print for Elimination of Waste Through Lean Di...IRJET Journal
The document discusses lean waste assessment and methods to eliminate waste in the construction industry through lean digital methods. It analyzes the types of managerial waste in construction projects, ranks them based on frequency of occurrence, and ranks various lean waste elimination methods based on their use in industry. The goal is to determine the key drivers of waste in construction and the most suitable waste elimination method to reduce managerial waste from a lean perspective.
The document discusses perceptions of time, cost, and quality (TCQ) management on building projects based on a survey of clients, architects, quantity surveyors, engineers, project managers, and contractors in South Africa.
The key findings from the survey include:
1) Clients rated quality as more important than time, contrary to other project participants.
2) Most clients believed the procurement team matched their needs to appropriate procurement systems, but the procurement team did not generally see this as true.
3) Clients believed they rarely changed original project briefs after starting, but consultants saw brief changes occurring more often.
4) Perceptions varied on whether projects were completed within agreed budgets, with
This thesis proposal examines multi-criteria bid evaluation systems for construction projects in Nepal. It discusses how the Department of Urban Development and Building Construction currently awards contracts primarily to the lowest bidder, which can lead to delays, cost overruns and quality issues. The proposal aims to identify qualification criteria beyond price to evaluate contractors. It will recommend a suitable multi-criteria evaluation model for selecting contractors through a literature review and surveys of engineers, consultants and contractors regarding their perceptions. The findings could influence procurement policies and help improve the success of public construction projects in Nepal.
A Case Study On Applying Lean Construction To ConcreteDawn Cook
The document discusses applying lean construction principles to concrete construction projects. It studies a concrete construction project to identify waste and proposes solutions. At the project level, lack of coordination among subcontractors caused schedule delays. The paper proposes using last planner concepts, linear scheduling, and graphic scheduling to improve communication and look-ahead planning. At the operation level, a systematic approach is applied to identify waste, redesign work procedures, and use 3D animation for employee training to reduce waste and resistance to changes.
Study of Factors Affecting the Implementation of BIM: An Evaluation of Risk V...IRJET Journal
This document summarizes a research paper that studied the factors affecting the implementation of building information modeling (BIM) and the risk variability at different construction stages. It first provides background on BIM and its applications in quantity surveying, including developing cost schedules and quantification. It then discusses problems with traditional paper-based methods for developing bills of quantities. The study objectives were to examine BIM applications in quantity surveying, identify factors influencing BIM adoption, and determine construction cost risks and variability. A literature review covered past research on using BIM for quantity takeoffs, estimation, and how BIM impacts the role of quantity surveyors. The conclusion was that BIM-assisted estimates provide better performance than traditional methods.
Cost Effective Methods in Construction Engineeringcivejjour
The economic impact of construction cost overrun is a possible loss of the economic justification for the
project. The financial impact of a cost overrun results in demand for construction investment credits.
Therefore reliable estimates of construction cost are an important aspect to the contemporary construction
companies especially during the conceptual phase of lifecycle management. In this paper a cost-effective
analysis is done using one of the cost effective construction technique called Rat Trap Bond versus Flemish
bond and when estimated with CPWD 2012 schedule of rates it is proved that Low cost techniques such as
rat trap bond provides better cost effectiveness as compared to conventional Flemish bond construction
method.
Cost Effective Methods in Construction Engineeringcivejjour
The economic impact of construction cost overrun is a possible loss of the economic justification for the project. The financial impact of a cost overrun results in demand for construction investment credits. Therefore reliable estimates of construction cost are an important aspect to the contemporary construction companies especially during the conceptual phase of lifecycle management. In this paper a cost-effective analysis is done using one of the cost effective construction technique called Rat Trap Bond versus Flemish bond and when estimated with CPWD 2012 schedule of rates it is proved that Low cost techniques such as rat trap bond provides better cost effectiveness as compared to conventional Flemish bond construction method.
This document summarizes research adapting the Supply Chain Operations Reference (SCOR) model to the construction industry. The SCOR model was originally developed for manufacturing but lacks consideration of construction industry characteristics. Through case studies of construction projects over five years, the researchers identified necessary adaptations. They developed the Builder's SCOR (BSCOR) model which retains SCOR's structure but adds new processes and metrics to capture material delivery to sites, on-site procurement, construction, and planning activities. The BSCOR model allows mapping and measuring performance of construction supply chains from suppliers to project completion.
Building information-modeling-and-construction-projects-performance-the-effec...oircjournals
In most of the construction projects, there is always an element of running into delays in project completion time, costs overruns from variations and associated time overruns, lack of satisfying client requirements, clashes on site during construction – just to mention a few. Building Information Modelling (BIM) is being used to solve most of these challenges that pose such risks to a project. The study looked the effect of scheduling on performance of project constructions in Uasin Gishu County. The study targeted a population of 197 respondents who constitute of Technical staff and Non - technical staff. The study used census research design. Questionnaires were used to collect information from respondents. In order to ascertain reliability of the research instruments, the researcher piloted the instruments by distributing 30 questionnaires to respondents from Uasin Gishu County Government selected randomly from the various sections, which were not be part of the county to be sampled for this study. Descriptive statistics was used to analyse the data. Descriptive statistics included frequency, percentages, means, standard deviation and frequency distribution. Inferential statistics used was correlation and linear regression. The study found out that there was a significant and positive effect of project scheduling on construction projects performance Uasin Gishu County Government (β=0.198; p<0.05). The study concluded that proper project scheduling leads to an increased project performance risk management plays an important role in project management because without it project managers cannot define their objectives for future and project monitoring plays a vital role in project manager’s decision making processes since it helps project managers and their teams to foresee potential risks and obstacles that if left unaddressed could derail the project. The study recommends that the County Government should continue with good practices of ensuring resources are allocated with good practices of ensuring resources are allocated to projects from interception until closure.
Investigating the Effectiveness of Construction Practices in Delayed Resident...ijtsrd
Construction schedule delays could also be explained by means of the late completion of construction add comparison of designed schedule of project. If the explanations of the development projects schedule delay are found then the project schedule delay in construction may be reduced. During this study, factors of schedule delay were selected after the past review of literature then arranged them in primary sets. On following the survey outcomes, the highest causative groups and factors that require more consideration of delays in kokan region were explained. Satej R. Desai | A. T. Pawar "Investigating the Effectiveness of Construction Practices in Delayed Residential Projects in Gadhinglaj City through Time and Cost Perspective" Published in International Journal of Trend in Scientific Research and Development (ijtsrd), ISSN: 2456-6470, Volume-4 | Issue-3 , April 2020, URL: https://www.ijtsrd.com/papers/ijtsrd30530.pdf Paper Url :https://www.ijtsrd.com/engineering/civil-engineering/30530/investigating-the-effectiveness-of-construction-practices-in-delayed-residential-projects-in-gadhinglaj-city-through-time-and-cost-perspective/satej-r-desai
Multivariate approach to benchmarking quality prediction parameters in buildi...Alexander Decker
This document discusses the development of a multivariate model to benchmark quality prediction parameters in building maintenance works. It begins with an introduction on the importance of quality assurance in construction. A literature review is then presented on previous studies related to factors affecting construction quality. The document then describes the research methods, which included distributing questionnaires to construction professionals and analyzing the data using factor analysis and stepwise multiple regression. The goal of the research was to develop a total maintenance operation management model that incorporates key quality parameters to help practitioners monitor and improve quality in building maintenance works.
Basics of Quantity Surveying
Introduction
Course Objectives
Course Outline
Understand the history of Quantity Surveying
Understand the duties and functions of a Quantity Surveying
Know standard method of Measurement of building works
Understand in detail the knowledge of Measurement
Understand the history of Quantity Surveying
Understand the duties and functions of a Quantity Surveying
Know standard method of Measurement of building works
Understand in detail the knowledge of Measurement
Recommendation of an appropriate procurement route to suit the type of project
Risk management, including identification and
Due diligence reporting by confirming a scope of services provided in a main contractor’s tender
Selection of an appropriate form of contract
Life-cycle costing options for various types of construction to demonstrate benefits whilst a building is occupied
Advice on dispute resolution services if there is conflict of opinion with a contractor
Business feasibility studies to assess the viability of a scheme prior to design
Acting as client’s/employer’s agent under the title of project manager
Certification of buildings with Energy Performance Certificates (EPC)
Construction Design and Management Regulations (CDM) coordinator with health and safety.
IRJET- Study of Supplier Evaluation and Development Practices in Supply Chain...IRJET Journal
This document discusses supplier evaluation and development practices in the construction industry supply chain. It begins with an abstract that outlines the purpose of studying supplier evaluation methods and selection issues. It then provides background on the importance of materials procurement in construction projects. The introduction defines supply chain management and discusses the key role that suppliers play. It indicates that while supplier evaluation is common in manufacturing, it is less developed in the construction industry. The problem statement reviews research on supply chain management and the construction supply chain to understand current practices and barriers to effective supplier evaluation.
A Comparative Study Of Construction Cost And Commercial Management Services I...Scott Faria
This document provides a summary of a research study that compares construction cost and commercial management practices in the UK and China. It finds that while the UK has a well-established quantity surveying profession dating back over 170 years, China is still transforming its historically state-run construction industry to a more market-based system. The study develops a framework to map the UK's cost and commercial management systems to China's engineering cost systems. It analyzes the structures and operations of the relevant professional bodies RICS and CECA. It also reports the findings of industry surveys that show differences in firm profiles, fee structures, and use of technologies between the two countries. The study concludes that while both countries' practices have progressed significantly, variations still exist
Development of Building Quality Measurement Tool: Building Construction Quali...IRJET Journal
This document discusses the development of a Building Construction Quality Index (BCQI) tool to objectively measure the quality of building construction projects in India. It reviews different definitions of construction quality and existing quality measurement systems. It then describes developing the BCQI, which rates projects based on weighted quality attributes and sub-attributes identified through literature review. The tool allows comparing completed and ongoing project quality, tracking quality over time, and providing guidelines for continuous quality improvement. The document aims to contribute to improved quality measurement and management in the Indian construction industry.
Procurement principle towards effective management of construction projectseSAT Publishing House
IJRET : International Journal of Research in Engineering and Technology is an international peer reviewed, online journal published by eSAT Publishing House for the enhancement of research in various disciplines of Engineering and Technology. The aim and scope of the journal is to provide an academic medium and an important reference for the advancement and dissemination of research results that support high-level learning, teaching and research in the fields of Engineering and Technology. We bring together Scientists, Academician, Field Engineers, Scholars and Students of related fields of Engineering and Technology.
“An Outlook of the Ongoing and Future Relationship between Blockchain Technologies and Process-aware Information Systems.” Invited talk at the joint workshop on Blockchain for Information Systems (BC4IS) and Blockchain for Trusted Data Sharing (B4TDS), co-located with with the 36th International Conference on Advanced Information Systems Engineering (CAiSE), 3 June 2024, Limassol, Cyprus.
In the rapidly evolving landscape of technologies, XML continues to play a vital role in structuring, storing, and transporting data across diverse systems. The recent advancements in artificial intelligence (AI) present new methodologies for enhancing XML development workflows, introducing efficiency, automation, and intelligent capabilities. This presentation will outline the scope and perspective of utilizing AI in XML development. The potential benefits and the possible pitfalls will be highlighted, providing a balanced view of the subject.
We will explore the capabilities of AI in understanding XML markup languages and autonomously creating structured XML content. Additionally, we will examine the capacity of AI to enrich plain text with appropriate XML markup. Practical examples and methodological guidelines will be provided to elucidate how AI can be effectively prompted to interpret and generate accurate XML markup.
Further emphasis will be placed on the role of AI in developing XSLT, or schemas such as XSD and Schematron. We will address the techniques and strategies adopted to create prompts for generating code, explaining code, or refactoring the code, and the results achieved.
The discussion will extend to how AI can be used to transform XML content. In particular, the focus will be on the use of AI XPath extension functions in XSLT, Schematron, Schematron Quick Fixes, or for XML content refactoring.
The presentation aims to deliver a comprehensive overview of AI usage in XML development, providing attendees with the necessary knowledge to make informed decisions. Whether you’re at the early stages of adopting AI or considering integrating it in advanced XML development, this presentation will cover all levels of expertise.
By highlighting the potential advantages and challenges of integrating AI with XML development tools and languages, the presentation seeks to inspire thoughtful conversation around the future of XML development. We’ll not only delve into the technical aspects of AI-powered XML development but also discuss practical implications and possible future directions.
Threats to mobile devices are more prevalent and increasing in scope and complexity. Users of mobile devices desire to take full advantage of the features
available on those devices, but many of the features provide convenience and capability but sacrifice security. This best practices guide outlines steps the users can take to better protect personal devices and information.
For the full video of this presentation, please visit: https://www.edge-ai-vision.com/2024/06/building-and-scaling-ai-applications-with-the-nx-ai-manager-a-presentation-from-network-optix/
Robin van Emden, Senior Director of Data Science at Network Optix, presents the “Building and Scaling AI Applications with the Nx AI Manager,” tutorial at the May 2024 Embedded Vision Summit.
In this presentation, van Emden covers the basics of scaling edge AI solutions using the Nx tool kit. He emphasizes the process of developing AI models and deploying them globally. He also showcases the conversion of AI models and the creation of effective edge AI pipelines, with a focus on pre-processing, model conversion, selecting the appropriate inference engine for the target hardware and post-processing.
van Emden shows how Nx can simplify the developer’s life and facilitate a rapid transition from concept to production-ready applications.He provides valuable insights into developing scalable and efficient edge AI solutions, with a strong focus on practical implementation.
Building Production Ready Search Pipelines with Spark and MilvusZilliz
Spark is the widely used ETL tool for processing, indexing and ingesting data to serving stack for search. Milvus is the production-ready open-source vector database. In this talk we will show how to use Spark to process unstructured data to extract vector representations, and push the vectors to Milvus vector database for search serving.
Removing Uninteresting Bytes in Software FuzzingAftab Hussain
Imagine a world where software fuzzing, the process of mutating bytes in test seeds to uncover hidden and erroneous program behaviors, becomes faster and more effective. A lot depends on the initial seeds, which can significantly dictate the trajectory of a fuzzing campaign, particularly in terms of how long it takes to uncover interesting behaviour in your code. We introduce DIAR, a technique designed to speedup fuzzing campaigns by pinpointing and eliminating those uninteresting bytes in the seeds. Picture this: instead of wasting valuable resources on meaningless mutations in large, bloated seeds, DIAR removes the unnecessary bytes, streamlining the entire process.
In this work, we equipped AFL, a popular fuzzer, with DIAR and examined two critical Linux libraries -- Libxml's xmllint, a tool for parsing xml documents, and Binutil's readelf, an essential debugging and security analysis command-line tool used to display detailed information about ELF (Executable and Linkable Format). Our preliminary results show that AFL+DIAR does not only discover new paths more quickly but also achieves higher coverage overall. This work thus showcases how starting with lean and optimized seeds can lead to faster, more comprehensive fuzzing campaigns -- and DIAR helps you find such seeds.
- These are slides of the talk given at IEEE International Conference on Software Testing Verification and Validation Workshop, ICSTW 2022.
GraphRAG for Life Science to increase LLM accuracyTomaz Bratanic
GraphRAG for life science domain, where you retriever information from biomedical knowledge graphs using LLMs to increase the accuracy and performance of generated answers
In his public lecture, Christian Timmerer provides insights into the fascinating history of video streaming, starting from its humble beginnings before YouTube to the groundbreaking technologies that now dominate platforms like Netflix and ORF ON. Timmerer also presents provocative contributions of his own that have significantly influenced the industry. He concludes by looking at future challenges and invites the audience to join in a discussion.
TrustArc Webinar - 2024 Global Privacy SurveyTrustArc
How does your privacy program stack up against your peers? What challenges are privacy teams tackling and prioritizing in 2024?
In the fifth annual Global Privacy Benchmarks Survey, we asked over 1,800 global privacy professionals and business executives to share their perspectives on the current state of privacy inside and outside of their organizations. This year’s report focused on emerging areas of importance for privacy and compliance professionals, including considerations and implications of Artificial Intelligence (AI) technologies, building brand trust, and different approaches for achieving higher privacy competence scores.
See how organizational priorities and strategic approaches to data security and privacy are evolving around the globe.
This webinar will review:
- The top 10 privacy insights from the fifth annual Global Privacy Benchmarks Survey
- The top challenges for privacy leaders, practitioners, and organizations in 2024
- Key themes to consider in developing and maintaining your privacy program
HCL Notes and Domino License Cost Reduction in the World of DLAUpanagenda
Webinar Recording: https://www.panagenda.com/webinars/hcl-notes-and-domino-license-cost-reduction-in-the-world-of-dlau/
The introduction of DLAU and the CCB & CCX licensing model caused quite a stir in the HCL community. As a Notes and Domino customer, you may have faced challenges with unexpected user counts and license costs. You probably have questions on how this new licensing approach works and how to benefit from it. Most importantly, you likely have budget constraints and want to save money where possible. Don’t worry, we can help with all of this!
We’ll show you how to fix common misconfigurations that cause higher-than-expected user counts, and how to identify accounts which you can deactivate to save money. There are also frequent patterns that can cause unnecessary cost, like using a person document instead of a mail-in for shared mailboxes. We’ll provide examples and solutions for those as well. And naturally we’ll explain the new licensing model.
Join HCL Ambassador Marc Thomas in this webinar with a special guest appearance from Franz Walder. It will give you the tools and know-how to stay on top of what is going on with Domino licensing. You will be able lower your cost through an optimized configuration and keep it low going forward.
These topics will be covered
- Reducing license cost by finding and fixing misconfigurations and superfluous accounts
- How do CCB and CCX licenses really work?
- Understanding the DLAU tool and how to best utilize it
- Tips for common problem areas, like team mailboxes, functional/test users, etc
- Practical examples and best practices to implement right away
HCL Notes und Domino Lizenzkostenreduzierung in der Welt von DLAUpanagenda
Webinar Recording: https://www.panagenda.com/webinars/hcl-notes-und-domino-lizenzkostenreduzierung-in-der-welt-von-dlau/
DLAU und die Lizenzen nach dem CCB- und CCX-Modell sind für viele in der HCL-Community seit letztem Jahr ein heißes Thema. Als Notes- oder Domino-Kunde haben Sie vielleicht mit unerwartet hohen Benutzerzahlen und Lizenzgebühren zu kämpfen. Sie fragen sich vielleicht, wie diese neue Art der Lizenzierung funktioniert und welchen Nutzen sie Ihnen bringt. Vor allem wollen Sie sicherlich Ihr Budget einhalten und Kosten sparen, wo immer möglich. Das verstehen wir und wir möchten Ihnen dabei helfen!
Wir erklären Ihnen, wie Sie häufige Konfigurationsprobleme lösen können, die dazu führen können, dass mehr Benutzer gezählt werden als nötig, und wie Sie überflüssige oder ungenutzte Konten identifizieren und entfernen können, um Geld zu sparen. Es gibt auch einige Ansätze, die zu unnötigen Ausgaben führen können, z. B. wenn ein Personendokument anstelle eines Mail-Ins für geteilte Mailboxen verwendet wird. Wir zeigen Ihnen solche Fälle und deren Lösungen. Und natürlich erklären wir Ihnen das neue Lizenzmodell.
Nehmen Sie an diesem Webinar teil, bei dem HCL-Ambassador Marc Thomas und Gastredner Franz Walder Ihnen diese neue Welt näherbringen. Es vermittelt Ihnen die Tools und das Know-how, um den Überblick zu bewahren. Sie werden in der Lage sein, Ihre Kosten durch eine optimierte Domino-Konfiguration zu reduzieren und auch in Zukunft gering zu halten.
Diese Themen werden behandelt
- Reduzierung der Lizenzkosten durch Auffinden und Beheben von Fehlkonfigurationen und überflüssigen Konten
- Wie funktionieren CCB- und CCX-Lizenzen wirklich?
- Verstehen des DLAU-Tools und wie man es am besten nutzt
- Tipps für häufige Problembereiche, wie z. B. Team-Postfächer, Funktions-/Testbenutzer usw.
- Praxisbeispiele und Best Practices zum sofortigen Umsetzen
Goodbye Windows 11: Make Way for Nitrux Linux 3.5.0!SOFTTECHHUB
As the digital landscape continually evolves, operating systems play a critical role in shaping user experiences and productivity. The launch of Nitrux Linux 3.5.0 marks a significant milestone, offering a robust alternative to traditional systems such as Windows 11. This article delves into the essence of Nitrux Linux 3.5.0, exploring its unique features, advantages, and how it stands as a compelling choice for both casual users and tech enthusiasts.
Climate Impact of Software Testing at Nordic Testing DaysKari Kakkonen
My slides at Nordic Testing Days 6.6.2024
Climate impact / sustainability of software testing discussed on the talk. ICT and testing must carry their part of global responsibility to help with the climat warming. We can minimize the carbon footprint but we can also have a carbon handprint, a positive impact on the climate. Quality characteristics can be added with sustainability, and then measured continuously. Test environments can be used less, and in smaller scale and on demand. Test techniques can be used in optimizing or minimizing number of tests. Test automation can be used to speed up testing.
Driving Business Innovation: Latest Generative AI Advancements & Success StorySafe Software
Are you ready to revolutionize how you handle data? Join us for a webinar where we’ll bring you up to speed with the latest advancements in Generative AI technology and discover how leveraging FME with tools from giants like Google Gemini, Amazon, and Microsoft OpenAI can supercharge your workflow efficiency.
During the hour, we’ll take you through:
Guest Speaker Segment with Hannah Barrington: Dive into the world of dynamic real estate marketing with Hannah, the Marketing Manager at Workspace Group. Hear firsthand how their team generates engaging descriptions for thousands of office units by integrating diverse data sources—from PDF floorplans to web pages—using FME transformers, like OpenAIVisionConnector and AnthropicVisionConnector. This use case will show you how GenAI can streamline content creation for marketing across the board.
Ollama Use Case: Learn how Scenario Specialist Dmitri Bagh has utilized Ollama within FME to input data, create custom models, and enhance security protocols. This segment will include demos to illustrate the full capabilities of FME in AI-driven processes.
Custom AI Models: Discover how to leverage FME to build personalized AI models using your data. Whether it’s populating a model with local data for added security or integrating public AI tools, find out how FME facilitates a versatile and secure approach to AI.
We’ll wrap up with a live Q&A session where you can engage with our experts on your specific use cases, and learn more about optimizing your data workflows with AI.
This webinar is ideal for professionals seeking to harness the power of AI within their data management systems while ensuring high levels of customization and security. Whether you're a novice or an expert, gain actionable insights and strategies to elevate your data processes. Join us to see how FME and AI can revolutionize how you work with data!
Cosa hanno in comune un mattoncino Lego e la backdoor XZ?Speck&Tech
ABSTRACT: A prima vista, un mattoncino Lego e la backdoor XZ potrebbero avere in comune il fatto di essere entrambi blocchi di costruzione, o dipendenze di progetti creativi e software. La realtà è che un mattoncino Lego e il caso della backdoor XZ hanno molto di più di tutto ciò in comune.
Partecipate alla presentazione per immergervi in una storia di interoperabilità, standard e formati aperti, per poi discutere del ruolo importante che i contributori hanno in una comunità open source sostenibile.
BIO: Sostenitrice del software libero e dei formati standard e aperti. È stata un membro attivo dei progetti Fedora e openSUSE e ha co-fondato l'Associazione LibreItalia dove è stata coinvolta in diversi eventi, migrazioni e formazione relativi a LibreOffice. In precedenza ha lavorato a migrazioni e corsi di formazione su LibreOffice per diverse amministrazioni pubbliche e privati. Da gennaio 2020 lavora in SUSE come Software Release Engineer per Uyuni e SUSE Manager e quando non segue la sua passione per i computer e per Geeko coltiva la sua curiosità per l'astronomia (da cui deriva il suo nickname deneb_alpha).
Maruthi Prithivirajan, Head of ASEAN & IN Solution Architecture, Neo4j
Get an inside look at the latest Neo4j innovations that enable relationship-driven intelligence at scale. Learn more about the newest cloud integrations and product enhancements that make Neo4j an essential choice for developers building apps with interconnected data and generative AI.
1. International Journal of Engineering Science Invention
ISSN (Online): 2319 – 6734, ISSN (Print): 2319 – 6726
www.ijesi.org Volume 3 Issue 4ǁ April 2014 ǁ PP.31-34
www.ijesi.org 31 | Page
Applicability Bill of Quantities in Construction Procurement
Atikah Razali1
, Anas Tajudin2
, Ahmad Fadzli Ahmad Tajuddin3
1
PhD Candidate Student, Kulliyyah of Architecture and Environmental Design,
International Islamic University,Gombak, 53100 Kuala Lumpur, Malaysia
2
Faculty of Management and Information Technology,
Sultan Azlan Shah University College, 33000 Kuala Kangsar, Perak, Malaysia.
3
Public Service Department Malaysia, 50480 Kuala Lumpur, Malaysia
ABSTRACT : Bill of quantities (B/Qs) is an essential document in a construction project which provides the
detail of the contract amount. Historically, the formal form of B/Qs was initiated in the United Kingdom after
the Industrial Revolution in the 19th century. It was mainly used by contractors for paying their workers and
claiming payments from clients by submitting it as partisan final account. Particularly, B/Qs is widely used in
the traditional procurement for cost estimating and as part of tender and contract document. However, as
construction industry evolved and changed technologically, economically, legally, and procedurally, sodoes the
usage of B/Qs in the construction projects. It is not known whether B/Qs in its current format is suitable to be
used with the more modern procurement systems or not. Based on literature, the issue on the declining usage of
B/Qs due to the non-traditional procurement system adopted in construction industry has been encountered in
the UK’s, Australia’s and also Malaysia’s construction industry due to several factors. One of the common
factors is due to complexity and time consuming in the preparation of B/Qs document. Thus, this article intends
to develop strategies to close the gaps between B/Qs documentation in terms of format and style with the
procurement system. Besides that, this article may establish the functions of B/Qs in the construction
procurement system.
KEYWORDS : Bill of Quantities, construction, procurement system, tender document
I. INTRODUCTION
B/Qs is widely used in the traditional procurement method for cost estimating and as part of tender and
contract document. However, its use is beginning to wane because the application of non-traditional
procurement system has become the norm. It is not known whether B/Qs in its current format is suitable to be
used with the more modern procurement systems or not. This is because, based on literature, the issue on the
declining usage of B/Qs due to the non-traditional procurement system adopted in construction industry has
been encountered in the UK’s, Australia’s and also Malaysia’s construction industry due to several factors. One
of the common factors is due to complexity and time consuming in the preparation of B/Qs document.According
to Rosli et al., (2006), the usage of B/Qs declined because of the complexity in the preparation of B/Qs
documentation which consumes times. A Bill of Quantities or B/Qs is a complex document consists of
qualitative and quantitative aspects of every constituent part of a proposed construction project such as items of
works with complete description of material, workmanship, and the quantities, and compiled together with the
form of tender, specification, preliminary bill and list of drawings to form a tender document (Hacket and
Robinson, 2003; Chan, 2002; NSW Legislative Council, 1991; Marsden, 1998; Seeley, 1997; Willis, et al, 2002
cited in Rosli et al, 2006).Besides that, in traditional procurement method, B/Qs is a part of tender document
and the preparation of B/Qs starts after the completion of detailed design. This process contradicts to non-
procurement system which the tender document prepared during the development of concept design stage of the
construction project.
Thus, this shows that, it is not known whether B/Qs in its current format is suitable to be used with the
more modern procurement systems or not. Therefore, in order to ensure the effectiveness of B/Qs, this research
intends to identify various types of B/Qs in terms of the format, style of presentation and method of
measurement, factors that contribute to the constraints in the production of B/Qs, various types of procurement
systems and establish link between B/Qs format, style of presentation, method of measurement with
procurement systems. Hence, this research intends to develop strategies to close the gaps between B/Qs
documentation in terms of format and style with the procurement system and at the same time establish the
functions of B/Qs in the construction procurement system.
2. Applicability Bill Of Quantities In…
www.ijesi.org 32 | Page
II. LITERATURE REVIEW
A Bill of Quantities or B/Qs is a document detailing the qualitative and quantitative aspects of every
constituent part of a proposed construction project such as items of works with complete description of material,
workmanship, and the quantities, and B/Qs is compiled together with the form of tender, specification,
preliminary bill and list of drawings to form a tender document (Willis, et al., 2002 cited in Rosli, et al., 2006;
Hacket and Robinson, 2003; Chan, 2002; Marsden, 1998; Seeley, 1997; NSW Legislative Council, 1991). Bills
of quantities (B/Qs) has existed and developed over 300 years (Miliken, 1996). According to Rosli, et al.,
(2006), B/Qs emerged due to the emergence of QS profession. The QS profession was established as early as
1785 as a “measurer”, “custom surveyor” or “surveyor” but the first recorded usage of the term “quantity
surveyor” was in year 1859 (ASAQ, 2006, cited in Rosli, et al., 2006). In Malaysia, the B/Qs is introduced and
widely used as tendering and contracting purposes in the 1940s since the profession of quantity surveyor was
introduced to this country (Rosli, et al., 2006).
B/Qs document is comprised of detailing description and quantities of all of the construction work of a
project and the processes involved in the preparation of B/Qs document are “taking off”, drafting, checking,
editing and printing the 300-500 pages (Rosli, et al., 2006).Based on Brook (1998), B/Qs has two primary uses
(cited in Davis et al., 2004):
a) Pre-Contract: B/Qs assists contractors in the formulation of their tenders as the BQs breaks down the
contract works in a formal, detailed, and structured manner for tendering purposes.
b) Post-Contract: B/Qs assists the contractors and quantity surveyors in the valuing of progress payments and
variations and it provides a financial structure for contract administration.
However, based on RICS (1991) research, there is a declining usage of the B/Qs in the construction
industry and it was predicted that B/Qs may totally disappear from the construction industry in the near future.
In Australia, the Legislative Council NSW has already identified from year 1991, the need for continuing
research and debated and advocated further research to establish whether B/Qs remains as an essential part of
contract documentation prepared by the QS. According to RICS 1991, in UK, the use of B/Qs has declined from
65% in 1984 to 56% in 1989. Based on AIQS (Victorian chapter) survey in Table 1, it also indicates that a sharp
downward trend in the production of B/Qs (cited in Davis et al., 2004).
Table 1: B/Qs Production as Percentage of Office Workload
1993 1994 1995 1996 1997 1998 1999
27% 30% 22% 16% 15% 17% 11%
Source: (AIQS Victoria, cited in Davis et al., 2004)
One of the possible factors that contributes to the declining usage of B/Qs in the construction industry
is that, it is not fully utilized by the project team and many were not able to relate B/Qs for everyday project
with the development process. AIQS, (2001), claimed that B/Qs is perhaps the most misunderstood facet of
building contracts today. Moreover, the debate over the relative advantages and disadvantages of B/Qs has been
long standing and generates strongly held and conflicting views (NPWC/NBCC, 1990). There are clear
arguments for and against B/Qs, but very limited research to support them in which, many of the arguments are
based on anecdote, intuition or common sense (Davis et al., 2004).In Malaysia, there is one research conducted
by Rosli et al. (2006) pertaining to the B/Qs performance in today’s construction procurement system. They
exaggerated that B/Qs is not necessarily useful for every type of project or procurement system and this is the
main issue contributing to the declining usage of B/Qs in the construction industry in Malaysia. They claimed
that this scenario is because of the processes of design, documentation and construction tend to run almost
parallel to one another and the tendering process is much shortened.
However, for non-traditional procurement system, the contractors still have to prepare a document
comprised of the concept design or schematic design and a proper cost document for bidding purposes and this
document can be as detailed as to become a “concise B/Qs” but there is no specific term used for such document
(Rosli et al., 2006).Therefore, the adaptability of B/Qs depends on the types of procurement system in
traditional procurement and non-traditional procurement system where both processes involved are different.
According to Odhigu et al. (2011), in traditional procurement system, the design and the construction are carried
out by separate organizations and some basic characteristics of traditional procurement system are as follows:
3. Applicability Bill Of Quantities In…
www.ijesi.org 33 | Page
a) Project delivery is a sequential process.
b) The design of the project is largely completed before work commences on site.
c) The responsibility for managing the project is divided between the client’s consultants and the
contractors, and there is therefore little scope for involvement of either of the parties in the other’s
activities.
d) Reimbursement of the client’s consultants is normally on a fee and expenses basis, whereas the contractor
is paid for the work completed on admeasure or lump sum basis.
There are four stages of traditional procurement system which are preparation, design, tender and
construction such as in Figure 1.
Figure 1: Traditional Procurement System
However, in non-traditional procurement system, the design and the construction are carried parallel as
in Figure 2 (Rosli et al., 2006). Non-traditional procurement system is divided as integrated and management
oriented procurement system, in which, integrated procurement system is Design and Build (DB), Package Deal,
and Turnkey method whereas management oriented system is management contracting.
Figure 2: Typical Processes of Non-traditional Procurement System
Thus, in order to suit the B/Qs with today’s construction procurement, the Construction Industry
Development Board (CIDB) (2010) suggested that the B/Qs will be more effective if it;
[1] Comprehensively and accurately reflects the nature of the work proposed and the circumstances under
which it will be executed;
[2] Is prepared in a standard manner for all contracts; and
[3] Is brief and simple to use, while still being itemised in sufficient detail to distinguish between different
classes of work, and between work of the same nature carried out in differing circumstances and locations.
III. RESEARCH ISSUES
Evidently, as the construction procurement changes from time to time, so does the adaptability of B/Qs.
However, how far the declining usage of B/Qs is due to today’s construction procurement and there is less
concern on that. Therefore, the criticisms of B/Qs in which the preparation of B/Qs is very complex and time
consuming must be taken in a positive manner and should be addressed professionally and scientifically.
Moreover, it is not known whether B/Qs in its current format is suitable/appropriate to be used with the more
modern procurement systems. Literature suggested that the use of BQ is on the decline where there are some
complaints of the lengthy time taken to prepare them.
IV. SUGGESTIONS AND CONCLUSION
Bill of quantities is a document prepared by a quantity surveyor. Therefore, one of the significance of
this research is it contributes to a body of knowledge in the quantity surveying field, both in practical and
4. Applicability Bill Of Quantities In…
www.ijesi.org 34 | Page
education. The research may alert the construction teams on the causes of errors that occurred in a bill of
quantities, so that it enables them to reduce the inaccuracy risk in such document. At the same time, it helps to
minimise the problems pertaining to the bill of quantities for construction projects which have been mentioned
by previous researchers through the review of literatures. Therefore, this research not only highlighted the errors
and causes of errors in a bill of quantities, but it also touches on the effects of inaccuracy of a bill of quantities
on construction projects. Hence, this is evidence that this document is very significant in a construction project.
An accurate bill of quantities will fulfill the satisfaction of many parties such as the clients, contractors and
others. On the other hand, the proposed strategies also contribute to the enhancement of quality of quantity
surveying services. Moreover, the literature review on the basic knowledge of a bill of quantities such as
definition, types, format, and processes involved during preparation of the document and the functions enrich or
extend the current knowledge of the quantity surveying field and construction industry.In a nutshell, this
research study is conducted to identify the errors and causes of errors in the bill of quantities document.
Furthermore, this ongoing research also touches the effects of errors in a bill of quantities to a construction
project which enables the researcher to propose strategies to minimize the errors in the bill of quantities
document. The proposed strategies will not only enhance the quantity surveying services, but will also improve
the construction projects works and teams satisfaction and contribute to new knowledge dissemination.
V. ACKNOWLEDGEMENTS
Special thanks to faculty members of Kulliyyah of Architecture and Environmental Design,
International Islamic University Malaysia for their suggestions and recommendations.
REFERENCES
[1] AIQS (Australian Institute of Quantity Surveyor), (2001).Guaranteed Bills of Quantities- Discussion Paper. 25th
August 2000.
Letter. pp. 1-7.
[2] CIDB, (2010). Inform Practice Note # 21. CIDB Development through Partnership; Construction Procurement and Delivery:
Brooklyn Square.
[3] Davis, P. R., Love, P. E. D., & Baccarini, D, (2009). Bills of Quantities: Nemesis or Nirvana? Structural Survey, Vol. 27 (2). Pp 99-
108.
[4] Davis, Peter, R., David, & Baccarini. (2004). The Use of Bills of Quantities in Construction Projects - An Australian Survey in
Ellis, Robert and Bell, Malcolm (ed.), Proceeding of the COBRA 2004 International Construction Research Conference of the
Royal Institution of Chartered Surveyor, Leeds Metropolitan University, Leeds, 7-8 September, RICS Foundation, London.
[5] Koumi,J. (1995). Quality is better ensured by Practitioners than by Researchers (In) Steward, D.(Ed)< One World Many Voices:
Quality in Open and Distance Learning, Proceedings of the 17th
World Conference of ICDE, (Vol. 2), UK.
[6] Miliken, J. (1996). “Bills of Quantities and the Tendering Process”. Building Economist, June, pp. 14-17.
[7] Molloy, J.B. (2001). Destroying the Purposes of Bills of Quantities. HKIS Newsletter 10(8) Sept 2001.Retrieved March 04,
2011.http://www.hkis.org.hk,
[8] NPWC/NBCC.(1990). No dispute. Strategies for Improvement in the Australian Building and Construction Industry. NPWC,
Canberra.
[9] Onosakponome, O. F., AzharYahya, Nazatul Shima Abdul Rani, & Junaid M. Shaikh. (2011). Cost Benefit Analysis of
Procurement Systems and the Performance of Construction Projects in East Malaysia. Information Management and Business
Review. May 2011, Vol. 2, No. 5, pp. 181-192.
[10] Othman, R. and Said, J. (2007). Enhancing Control through Participation: Issues of Conflict in Public Sector Organizations. Journal
of Financial Reporting and Accounting, 5(2).
[11] Pell, J.P., Sirel, J.M., Marsden, A.K., Ford, I., and Cobbem, S.M. (2001).Effects of Reducing Ambulance Response Times on
Deaths from Out of Hospital Cardiac Arrest: Cohort Study. BMJ, 322: 1385-1388.
[12] RICS (Royal Institution of Chartered Surveyors). (1991). Quantity Surveying 2000: The Future Role of the Chartered Quantity
Surveyor, RICS, London.
[13] Rosli Abdul Rashid, Ismail Mat Taib , Wan Basiron Wan Ahmad, Md. Asrul Nasid, Wan Nordiana Wan Ali & Zainab Mohd
Zainordin. (2006). Effect of Procurement Systems on the Performance of Construction Projects .Conference paper in Padang, 21-24
June2006.
[14] Rosli Abdul Rashid, Muzani Mustapa & Siti Nurhuda Abd Wahid (2006). Bills of Quantities - Are they still useful and relevant
today? Paper presented at International Conference on Construction Industry 2006, Padang, Indonesia, 21-25 June. Retrieved March
03, 2011. http://eprints.utm.my/511/1/BQ_paper_Padang_12_6_06_Rosli.pdf
[15] Tagayun V. A. (2000). Estimating Bill of Materials. Manila: Tagayun Associates
[16] Yamane, Taro (1973). “Statistics: An Introductory Analysis.” New York: Harper & Row.
[17] Zill, D.G.(2005). Differential Equations with Boundary-Value Problems. 6th
ed. New York: Brooks/Cole Thomson Learning Inc.