HOW TO MINIMIZE DELAYS IN CONSTRUCTION OF COMMERCIAL PROJECT
challenges of highway projects in India
1. A note of Highway projects in India
Majority of road projects in India are affected by time overrun and this time overruns vary
from a few months to as high as five or more years, placing the project viability at risk.
The effects of delay in Road project are cost overrun, poor quality completion,
litigation/arbitration and claims.
I Clients’ related issues
(Owner)
Description
Land/site handover & Delay in
regulatory approvals
One of the most important reasons for the delay of road
project. Project is conceived/started after part land
clearance with the expectation over project period the
issues will be taken up/resolved but actually solved on
time
Insufficient funding
Funds are not adequately released during relevant
phases of projects ‘execution.
Milestones payments are not made on time due to
organizational lapses or bureaucracy.
Inadequate cash flow leads to delay in delivery of
Materials and equipment to the site and delay in payment
of workers’ salaries.
Interference with project
performance
Top management staff of the Client’s establishment
interfere in project execution because of vested interest
This happens mostly, if the management staff were
instrumental in the appointment of the vendor/contractor.
Delay or non-payment for
Completed works
This happens when agreed milestones for payment are
not followed or when there is no cash flow projection in
the project implementation plan.
Impractical allocation of
resources
Funds, manpower, materials, equipment are inadequate
to complete the project because project owners or clients
have not properly assessed whether they have the
required resources to complete such projects.
Unrealistic contract duration
The stated completion duration is impracticable and this
could be caused by wrong packaging of the contract
document, political interference or
unprofessional/inexperienced client’s staff.
2. Wrong choice of Consultants &
Contractors
Clients select Consultants and Contractors as their
vendors.
If the selection process is faulty, unqualified vendors will
be engaged.
This could lead to faulty works and frequent rework and
delay in project completion
Slow decision making
Clients are the project Owners. When they do not make
decisions on time regarding project matters, they slow
down activities at the project sites.
Slow decision making could be caused by an
organization’s internal bureaucracy or wrong channels of
communication.
Design alterations & change
orders
Change in specifications and scope which were not
considered originally or changes of design to address
some omissions that were vital to project functionality.
Alterations may require temporary stoppages that delay
overall
Project completion.
II Contractor-related issues Description
Poor coordination of
subcontractors
Some aspects of construction works are subcontracted to
nominated specialised subcontractors. These
subcontractors must be properly coordinated by the Prime
contractor to ensure timely delivery of assigned aspects
of works.
Contractors must therefore ensure that each
subcontractor delivers at the stipulated time as per
contract with quality.
Inappropriate construction
methods
Construction activities are required to be carried out using
best practices and tools.
When the procedures are not followed, errors occur and
leading to rework and delays.
Inadequate planning/ Ineffective
procurement planning
Contractors appoint Project Managers who are expected
to draw up workable project plans and modalities for their
implementation.
A faulty plan will lead to delay in project completion.
3. Most Local Contractors rarely have practicable work
programs at the initial stage of project planning.
Lack of appropriate work programs impairs monitoring of
project progress against the stipulated time.
Inadequate experience A contractor who does not possess requisite experience
usually makes construction errors.
These errors lead to rework and delays in activities.
Mistakes during construction
stage
Inexperienced contractors usually make errors during
construction.
Sometimes contractors employ low skilled staff in order to
make more profit by paying them lower salaries.
Tendencies of errors are, thus, higher.
Rework of an already executed aspect of a scope slows
down project progress.
This has serious impact if it involves execution of critical
tasks.
Incompetent site management Contractor’s employees that are not skilled in project
management are not able to manage their project site
appropriately, thus, culminating in faulty work, reworks
and delay in completion of tasks.
Wrong choice of Bankers Banks provide funds for most projects. Their actions and
inactions directly impact on a contractor’s ability to
execute the project as scheduled.
III Labour and equipment
related issues
Description
Unskilled site manpower
Employment of unskilled personnel at the project sites
impedes execution of work to specification and leads to
error or mistakes during construction.
Time is then spent on alterations and corrections.
Improper equipment selection
& Faulty equipment
The use of the incorrect equipment extends tasks while
faulty equipment leads to delay due to the time spent to
repair.
Labour disputes Labour disputes such as strikes slow down construction
4. as time is spent on negotiation and settlement of
grievances.
IV Materials-related issues Description
Poor quality materials Poor quality materials lead to poor quality workmanship,
thus an unacceptable product.
Most often, the project owners insist that correction be
made or that parts of work be completely redone.
Material shortages This results in slowed activities and sometimes temporary
abandonment of sites.
V Consultant-related issues Description
Inappropriate design
Late preparation of drawings
and other contract documents
Improper design stalls project execution because of the
time it takes for such design to be reviewed, amended
and accepted for construction works.
When errors are observed in the design, works are
temporary suspended until such errors are removed.
This is predominant in organisations where selection
processes of vendors are compromised.
Poor contract management
Most projects have consultants as the contract managers.
They liaise between the client and the contractor.
Projects get delayed when the required management
principles are not utilised during projects’ execution.
Late identification & resolution
of drawings & specification
errors & omissions
Projects are required to be completed on schedule, within
budget and according to specification.
If consultants do not identify errors and omissions in the
working drawings early enough, already completed
activities may require alterations when such errors and
omissions are discovered after project commencement.
Improper contract
packaging/delivery strategy
Clients usually outsource packaging/delivery of contracts
to the consultants who are professionals.
Errors in this task hinder the overall project performance
because issues not properly captured must be addressed
before project activities can progress otherwise, issue
may arise that lead to legal redress.
Over inspection
Inspectors are required to track performance of the
project through periodical monitoring.
5. Too frequent inspection becomes a distraction to the
contractors, hence could impede contractors’ progress.
Long waiting time for
inspection & testing
Certain aspects of projects require inspection and testing
before further activities could be carried out.
Usually, Consultants and Clients’ staff are tasked with the
responsibility of coordinating such exercises. Delays in
these impede project progress.
Inappropriate coordination of
information
If projects issues or contractor’s requests are not
addressed timely and information is not effectively
managed, project activities can be negatively affected.
There must be a good communication management plan
in place so that site information is properly channelled
and coordinated.
Lack of coordination of information fosters
misunderstanding, potentially causing conflicts that
require resolution time.
VI Community related issues Description
Lack of community buy-in
Local communities are stakeholders in public sector road
projects that are carried out to improve socio-economic
conditions.
Proper needs assessments are important as communities
usually partner with projects they know will address their
needs.
It is therefore appropriate to ensure a buy-in from
expected beneficiaries of projects so that they could
cooperate with the Construction duration
Delay or Non-payment of
Compensation
At times people in the community are required to
relinquish their properties for demolition to achieve project
objectives.
In contracts, provisions are made for payment of
compensation.
Delay in making these payments or non-payments may
stall project execution because, the affected owners of
such properties resist attempts for their properties to be
demolished without provision for replacement.
VII Contractual relationship
related issues
Description
6. Lack of adequate
communication between the
parties
Poor or inadequate communication between parties leads
to misunderstanding and misrepresentation of facts.
This could breed conflicts and consequently hinders
smooth progress of activities.
Contractual disputes/
negotiations
Major disputes and negotiations between parties in
project impede progress of work as aggrieved parties wait
until grievances are resolved before they continue.
VIII External issues Description
Weather conditions In areas where there is frequent rainfall, inexperienced
contractor /consultants do not account for weather
projections in their project implementation plan thus
proposed time line is not possible.
Change in government's
leadership & policies
Certain projects are stalled and abandoned when political
leadership that initiated is changed.
Sometimes, change in government policies such as
monetary and fiscal policies could lead to an increase in
the cost of construction materials and equipment.
Contractors will not be able to continue with the project as
scheduled because of the time they need to spend on
approvals for price fluctuations and contract revision.
Natural disasters (e.g. floods)
There are areas that usually experience natural disasters
in stretches of road project such as floods. These
disasters are generally unpredictable and cause delay
abnormally in project completion.
Interference by political
leaders
This is usually experienced in Road projects because
they are linearly stretched to vast areas.
Some political leaders have vested interest in particular
projects. They interfere by requesting additional scope
requirements not captured in the original design or by
imposing unqualified contractors / subcontractors on the
client.
The above action leads to poor project performance
especially in terms of time and quality also.
Conclusion: The success of a road project depends on various factors. Some are in control
of Govt body and some of them are in control of private stakeholder therefore close and
timely participation of different stakeholders is mandatory for quality completion of project.
7. The vagaries of a road project can be arrested if it is emphasised and developed on 4 “R” s
– risk allocation, regulation, renegotiation and resource raising.