BIM - Building Information Modelling - 2014 Olswang Construction Law Conference
•
3 likes•2,482 views
The document summarizes a presentation on Building Information Modelling (BIM) given at a 2014 construction law conference. It defines BIM as a 3D model containing project information and intelligent objects that enables data sharing, clash detection, pre-fabrication, and collaborative working. It notes that the UK government intends for BIM to be used on all projects by 2016 and that 39% of the UK construction industry currently uses BIM. It discusses an employer's information requirements for BIM, the new role of an information manager, BIM protocols, and how BIM can benefit facilities management.
Report
Share
Report
Share
Download to read offline
Recommended
Bim service presentation
Structural Design Detailing ( India )
Website- www.structuraldesigndetailing.com
Email- con@structuraldesigndetailing.com
structuraldesigndetailing.com@gmail.com
Contact No - + 91 9222086563 , + 91 8097027355
Mumbai|Sangli |Navi Mumbai|Vadodara|
Revit and Building Information Modeling (BIM) Presentation
Fiedler Group's comprehensive Revit and Building Information Modeling (BIM) presentation. Free download also available.
Synergis University 2014-BIM for Construction
BIM for Construction provides an overview of building information modeling (BIM) for the construction industry. It discusses how BIM enables more collaborative, proactive, and predictable processes compared to traditional analog methods. BIM allows all project stakeholders to explore a project digitally before construction through visualization, analysis, documentation, fabrication, and building simulation. Implementing BIM can reduce costs from fewer errors and changes, improve safety and quality, and provide facilities management benefits through its use over the entire building lifecycle. The presentation covers BIM technologies, applications in design, construction, and operation, as well as benefits for key disciplines like architecture, structure, and MEP.
Bim Presentation
Building information modeling (BIM) allows project teams to visualize, simulate, and analyze a building design using a 3D parametric model before construction begins. This model represents all physical and functional aspects of the building and enables seamless sharing of information throughout the project lifecycle. BIM facilitates improved coordination, identification of issues, and changes between owners, architects, engineers, and contractors compared to traditional document-based approaches. It also supports increased prefabrication, construction planning, and post-occupancy facility management.
BIM: an overview
presentation by Paul Wilkinson to CIMCIG BIM conference, Building Centre, London WC1 on Wednesday 25 April 2012.
Presentation explains what BIM is (and isn't), and outlines why it has become important in 2012, as the UK construction industry looks to meet a UK Government BIM deadline by 2016.
International BIM Implementation for The Saudi Big 5
This lecture highlights international high-level principles around how to implement and use BIM in the design, construction and operation of the built environment, including Aspects of procurement management and asset management. It is intended that these principles be used as a comprehensive framework for individuals and organisations.
Therefore, I advise any professional or firm considering using BIM to attend the lecture.
Webinar: BIM for MEP engineers | 23 March 2017
BIM is here to stay. But how can engineers effectively work with BIM content for MEP projects? During the webinar ‘Win with BIM using high quality and up-to-date content’ Stefan van Eerde and Jaap Groen from MEPcontent will discuss the role of content in the BIM cycle.
In this webinar you will learn:
- What is 'good' data for BIM projects?
- How does MEPcontent help BIM engineers?
- Live demo: content from MEPcontent directly into a Revit project
- How to transform generic to manufacturer specific content in Revit
- How to deal with various BIM Standards
- How to use apps in Revit to save a lot of time
Bim
The seminar discussed Building Information Modeling (BIM) and its advantages over traditional CAD. BIM is a digital representation of the physical and functional characteristics of a building and extends beyond 2D and 3D drawings to represent a building's width, height, time, cost and environmental impacts. It allows for more collaborative work and better decision making compared to CAD. Popular BIM software includes Revit, BIM 360 and Archicad. While BIM provides benefits like simulation and parametric modeling, it also faces challenges like a lack of specialists and software incompatibility. The seminar concluded that BIM is a promising new approach that saves time and improves construction quality through better communication of information.
Recommended
Bim service presentation
Structural Design Detailing ( India )
Website- www.structuraldesigndetailing.com
Email- con@structuraldesigndetailing.com
structuraldesigndetailing.com@gmail.com
Contact No - + 91 9222086563 , + 91 8097027355
Mumbai|Sangli |Navi Mumbai|Vadodara|
Revit and Building Information Modeling (BIM) Presentation
Fiedler Group's comprehensive Revit and Building Information Modeling (BIM) presentation. Free download also available.
Synergis University 2014-BIM for Construction
BIM for Construction provides an overview of building information modeling (BIM) for the construction industry. It discusses how BIM enables more collaborative, proactive, and predictable processes compared to traditional analog methods. BIM allows all project stakeholders to explore a project digitally before construction through visualization, analysis, documentation, fabrication, and building simulation. Implementing BIM can reduce costs from fewer errors and changes, improve safety and quality, and provide facilities management benefits through its use over the entire building lifecycle. The presentation covers BIM technologies, applications in design, construction, and operation, as well as benefits for key disciplines like architecture, structure, and MEP.
Bim Presentation
Building information modeling (BIM) allows project teams to visualize, simulate, and analyze a building design using a 3D parametric model before construction begins. This model represents all physical and functional aspects of the building and enables seamless sharing of information throughout the project lifecycle. BIM facilitates improved coordination, identification of issues, and changes between owners, architects, engineers, and contractors compared to traditional document-based approaches. It also supports increased prefabrication, construction planning, and post-occupancy facility management.
BIM: an overview
presentation by Paul Wilkinson to CIMCIG BIM conference, Building Centre, London WC1 on Wednesday 25 April 2012.
Presentation explains what BIM is (and isn't), and outlines why it has become important in 2012, as the UK construction industry looks to meet a UK Government BIM deadline by 2016.
International BIM Implementation for The Saudi Big 5
This lecture highlights international high-level principles around how to implement and use BIM in the design, construction and operation of the built environment, including Aspects of procurement management and asset management. It is intended that these principles be used as a comprehensive framework for individuals and organisations.
Therefore, I advise any professional or firm considering using BIM to attend the lecture.
Webinar: BIM for MEP engineers | 23 March 2017
BIM is here to stay. But how can engineers effectively work with BIM content for MEP projects? During the webinar ‘Win with BIM using high quality and up-to-date content’ Stefan van Eerde and Jaap Groen from MEPcontent will discuss the role of content in the BIM cycle.
In this webinar you will learn:
- What is 'good' data for BIM projects?
- How does MEPcontent help BIM engineers?
- Live demo: content from MEPcontent directly into a Revit project
- How to transform generic to manufacturer specific content in Revit
- How to deal with various BIM Standards
- How to use apps in Revit to save a lot of time
Bim
The seminar discussed Building Information Modeling (BIM) and its advantages over traditional CAD. BIM is a digital representation of the physical and functional characteristics of a building and extends beyond 2D and 3D drawings to represent a building's width, height, time, cost and environmental impacts. It allows for more collaborative work and better decision making compared to CAD. Popular BIM software includes Revit, BIM 360 and Archicad. While BIM provides benefits like simulation and parametric modeling, it also faces challenges like a lack of specialists and software incompatibility. The seminar concluded that BIM is a promising new approach that saves time and improves construction quality through better communication of information.
What is BIM?
What are its benefits to the construction industry?
More details on http://www.aproplan.com/blog/construction-advice/what-is-bim
Building Information Modeling
Fiedler Group's comprehensive Revit and Building Information Modeling (BIM) presentation. A information slideshare from Fiedler Group.
BIM case study
This document presents a case study on the use of building information modeling (BIM) on the UCSF Medical Center project in San Francisco, California. It discusses how BIM was used throughout planning, design, and construction, resulting in cost savings of over $100 million. Key aspects of the BIM implementation included co-locating over 100 project stakeholders in an integrated workspace, establishing cluster teams to enhance collaboration, and using BIM for coordination, quantity take-offs, scheduling, and facility management. The extensive use of BIM on this large, complex project helped reduce costs, improve schedule reliability, and increase productivity during construction.
BIM (Building Information Modeling) for digital construction
This document discusses Building Information Modeling (BIM) and how it improves construction processes. It defines BIM as an intelligent 3D modeling process used in architecture, engineering, and construction. The document outlines the benefits of BIM such as clash detection, quantity take-offs, coordination, and prefabrication. It also discusses how BIM reduces waste and improves documentation, maintenance, and facilities management. Traditional construction methods are compared to digital construction using BIM. Finally, common BIM software, implementation around the world, and how to become a BIM professional are summarized.
Bim services
OlilO provides BIM services that include BIM Modeling, BIM Automation, Architectural BIM, Structural BIM, MEP BIM, Mechnical BIM, Electrical BIM, Plumbing BIM etc.
https://www.olilo.ae/bim-services.html
MTECH BIM project case study
Several BIM case studies are shown to illustrate the value of BIM to the building construction industry.
www.mtech.com.hk
bim+ Presentation BIM Manager
bim+ offers great tools for BIM Managers to optimise the building process and secure information, costs, and schedules.
final bim
The document discusses the need to implement Building Information Modeling (BIM) in public infrastructure projects in India. It first defines BIM and explains its advantages over traditional 2D CAD, such as integrated 3D modeling, energy analysis, clash detection, and data sharing across project teams. It then outlines challenges Indian infrastructure projects face, like delays and cost overruns, that BIM could help address. Some key challenges to adopting BIM in India are legal issues around data ownership, lack of skills and software, and rigid attitudes towards digital tools. The document argues greater government support is needed to promote BIM's benefits of improved project scheduling, cost estimation, and facility management.
AUD_DXB_BIM_Educationsl_Presentation
This document discusses building information modeling (BIM) and its uses throughout the project lifecycle. BIM integrates information about a building design into a 3D model over time, allowing all stakeholders to effectively collaborate. It discusses how BIM has revolutionized the architecture, engineering, and construction industry by enabling parametric information integration through a centralized database. The document outlines the various stages and uses of BIM from initial planning and design through construction, operation, and eventual demolition or recycling of a building.
what is BIM
BIM is a process for generating and managing building data throughout the lifecycle of a building using 3D modeling software. It applies to all aspects of building construction from design through facilities management. BIM brings together information about all building components, integrates different aspects more effectively, reduces mistakes, and minimizes costs. It is used by architects, contractors, owners, planners, designers, and engineers.
The future of BIM is open - or - Is proprietary BIM unsustainable
The document discusses the future of building information modeling (BIM) being open rather than closed or proprietary. It notes that open, documented, and free formats like SQL and XML may be better communication formats for BIM going forward, rather than closed commercial options like Revit or ArchiCAD. The future of BIM is seen as being open like the internet, with open standards allowing building data to be used more flexibly across different analysis and design programs from multiple developers.
CM - An introduction to Building Information Modelling (BIM)
Lezione del 17 dicembre 2015 dell'Ing. Konstantinos Gkoumas al Corso di Costruzioni Metalliche del Prof. Ing. Franco Bontempi, Facolta' di Ingegneria Civile e Industriale, Universita' degli Studi di Roma La Sapienza.
What is True BIM?
True BIM? Drawings from Model. 5D-enabled.
Complete BIM? BIM + Contract + ICT
Perfect BIM? No Way
Ideal BIM? All Participants contribute
Ultimate BIM? Digital, Paperless
BIM: What kind of information is modeled in Parametric Building Information M...
The document discusses Building Information Modeling (BIM) services which have become essential for architecture, engineering, and construction projects. BIM is a process and technology that provides accurate 3D parametric models containing design, construction, and scheduling information to help professionals effectively plan and execute building projects. BIM modeling services involve separately modeling the architecture, structure, and mechanical, electrical, and plumbing components to create information-rich 3D models that represent all physical and functional aspects of a facility.
Quality BIM Services : BIM Junction
BIM Junction has emerged as one of the leading BIM service provider all across the globe. We specialize in BIM, MEP Co-ordination, CAD drafting, HVAC, Clash Detection etc.
Building information modelling - redefining the role of the project manager: ...
Building information modelling - redefining the role of the project manager: ...Association for Project Management
Presentation at Building Information Modelling - redefining the role of the project manager. Conference from the APM Knowledge SIG, 27th March 2014, University of SalfordBUILDING INFORMATION MODELLING
Three-dimensional, virtual representation of a design project
Adds fourth dimension of time and fifth dimension of cost
“Cloud” allows different members of cross-functional team to work on the project in one place
Building Information Modeling (BIM) is the process of generating and managing building data during its life cycle. BIM uses three-dimensional, real-time, dynamic building modeling software to increase productivity in building design and construction
To create a BIM, a modeler uses intelligent objects (Families) to build the model.
Turn Revit data into useful information with visualization techniques and wor...
BIM technology has been improving and its use is spreading in the construction industry more and more every year, reaching a point that we can make sure that it here to stay, but even today
most of the BIM processes and workflows are clear and established for the geometric and visualization tools of the technology but not for the Data management. We all agree that the parametrization and the data provided by the BIM Software is the key of the everything, but even today is not really clear which are the best practices to obtain data and process it to
understand patterns or get conclusions that can lead us into better designs on every project.
That is why the main objective of this lecture is to dig on the better practices to go from raw Revit Data to great visualizations that will lead us into better decisions and workflows on our
construction projects.
Implementing Building Information Modelling in Construction
Building Information Modeling (BIM) is an integrated software that simulates the entire construction design process, including materials, boundaries, and requirements. BIM manages graphical displays, construction details, and data, allowing architects and engineers to easily create drawings, reports, and analyze designs. It simulates infrastructure in a few clicks and empowers facilities management and material purchasing. BIM eliminates data redundancy, supports standards, and saves costs through interconnected digital design. It helps track asset management, construction sequencing, information sharing, and ensures all stakeholders have up-to-date information to implement BIM throughout the construction process.
BIM Building Information Modeling History
The document discusses Building Information Modeling (BIM). It defines BIM as a process and software used to manage a building's data during its lifecycle. The document outlines that BIM has evolved from 2D hand drawings to 3D parametric modeling. It notes current BIM uses 3D components for documentation, exchange, and visualization. Finally, it explores the future of BIM including international BIM libraries, using QR codes to access furniture data, and electronic permit submissions through 3D city platforms.
Building Information Modeling (BIM)
The presentation covers following areas:
- Typical Problems in Construction Industry
- What is BIM?
-BIM Process
- Influence of BIM on Industry Problems
- BIM Application
- BIM Advantages
- BIM Workflow
- BIM & Project Management
- BIM & Design Team Members
- BIM around the Globe
- Construction Industry with BIM
All work presented in the presentation is carried out by graduates of NUST, Islambad including Abdul Mughees Khan, Syed Kashif Ali Shah, Sharjeel Ahmad Tariq, Malik Awais Ahmad and Hamza Khan Shinwari.
Special credit of the work goes to Engr Tahir Shamshad, Vice President NESPAK and Engr Zia Ud Din, Asst Professor NUST under guidance and mentor ship the whole work was performed.
For more details feel free to contact: amugheeskhan@gmail.com
การพัฒรากระบวนการ BIM หรือ Building Information Modeling ที่ยั้งยืนในประเทศไทย
การพัฒรากระบวนการ BIM หรือ Building Information Modeling ที่ยั้งยืนในประเทศไทย
More Related Content
What's hot
What is BIM?
What are its benefits to the construction industry?
More details on http://www.aproplan.com/blog/construction-advice/what-is-bim
Building Information Modeling
Fiedler Group's comprehensive Revit and Building Information Modeling (BIM) presentation. A information slideshare from Fiedler Group.
BIM case study
This document presents a case study on the use of building information modeling (BIM) on the UCSF Medical Center project in San Francisco, California. It discusses how BIM was used throughout planning, design, and construction, resulting in cost savings of over $100 million. Key aspects of the BIM implementation included co-locating over 100 project stakeholders in an integrated workspace, establishing cluster teams to enhance collaboration, and using BIM for coordination, quantity take-offs, scheduling, and facility management. The extensive use of BIM on this large, complex project helped reduce costs, improve schedule reliability, and increase productivity during construction.
BIM (Building Information Modeling) for digital construction
This document discusses Building Information Modeling (BIM) and how it improves construction processes. It defines BIM as an intelligent 3D modeling process used in architecture, engineering, and construction. The document outlines the benefits of BIM such as clash detection, quantity take-offs, coordination, and prefabrication. It also discusses how BIM reduces waste and improves documentation, maintenance, and facilities management. Traditional construction methods are compared to digital construction using BIM. Finally, common BIM software, implementation around the world, and how to become a BIM professional are summarized.
Bim services
OlilO provides BIM services that include BIM Modeling, BIM Automation, Architectural BIM, Structural BIM, MEP BIM, Mechnical BIM, Electrical BIM, Plumbing BIM etc.
https://www.olilo.ae/bim-services.html
MTECH BIM project case study
Several BIM case studies are shown to illustrate the value of BIM to the building construction industry.
www.mtech.com.hk
bim+ Presentation BIM Manager
bim+ offers great tools for BIM Managers to optimise the building process and secure information, costs, and schedules.
final bim
The document discusses the need to implement Building Information Modeling (BIM) in public infrastructure projects in India. It first defines BIM and explains its advantages over traditional 2D CAD, such as integrated 3D modeling, energy analysis, clash detection, and data sharing across project teams. It then outlines challenges Indian infrastructure projects face, like delays and cost overruns, that BIM could help address. Some key challenges to adopting BIM in India are legal issues around data ownership, lack of skills and software, and rigid attitudes towards digital tools. The document argues greater government support is needed to promote BIM's benefits of improved project scheduling, cost estimation, and facility management.
AUD_DXB_BIM_Educationsl_Presentation
This document discusses building information modeling (BIM) and its uses throughout the project lifecycle. BIM integrates information about a building design into a 3D model over time, allowing all stakeholders to effectively collaborate. It discusses how BIM has revolutionized the architecture, engineering, and construction industry by enabling parametric information integration through a centralized database. The document outlines the various stages and uses of BIM from initial planning and design through construction, operation, and eventual demolition or recycling of a building.
what is BIM
BIM is a process for generating and managing building data throughout the lifecycle of a building using 3D modeling software. It applies to all aspects of building construction from design through facilities management. BIM brings together information about all building components, integrates different aspects more effectively, reduces mistakes, and minimizes costs. It is used by architects, contractors, owners, planners, designers, and engineers.
The future of BIM is open - or - Is proprietary BIM unsustainable
The document discusses the future of building information modeling (BIM) being open rather than closed or proprietary. It notes that open, documented, and free formats like SQL and XML may be better communication formats for BIM going forward, rather than closed commercial options like Revit or ArchiCAD. The future of BIM is seen as being open like the internet, with open standards allowing building data to be used more flexibly across different analysis and design programs from multiple developers.
CM - An introduction to Building Information Modelling (BIM)
Lezione del 17 dicembre 2015 dell'Ing. Konstantinos Gkoumas al Corso di Costruzioni Metalliche del Prof. Ing. Franco Bontempi, Facolta' di Ingegneria Civile e Industriale, Universita' degli Studi di Roma La Sapienza.
What is True BIM?
True BIM? Drawings from Model. 5D-enabled.
Complete BIM? BIM + Contract + ICT
Perfect BIM? No Way
Ideal BIM? All Participants contribute
Ultimate BIM? Digital, Paperless
BIM: What kind of information is modeled in Parametric Building Information M...
The document discusses Building Information Modeling (BIM) services which have become essential for architecture, engineering, and construction projects. BIM is a process and technology that provides accurate 3D parametric models containing design, construction, and scheduling information to help professionals effectively plan and execute building projects. BIM modeling services involve separately modeling the architecture, structure, and mechanical, electrical, and plumbing components to create information-rich 3D models that represent all physical and functional aspects of a facility.
Quality BIM Services : BIM Junction
BIM Junction has emerged as one of the leading BIM service provider all across the globe. We specialize in BIM, MEP Co-ordination, CAD drafting, HVAC, Clash Detection etc.
Building information modelling - redefining the role of the project manager: ...
Building information modelling - redefining the role of the project manager: ...Association for Project Management
Presentation at Building Information Modelling - redefining the role of the project manager. Conference from the APM Knowledge SIG, 27th March 2014, University of SalfordBUILDING INFORMATION MODELLING
Three-dimensional, virtual representation of a design project
Adds fourth dimension of time and fifth dimension of cost
“Cloud” allows different members of cross-functional team to work on the project in one place
Building Information Modeling (BIM) is the process of generating and managing building data during its life cycle. BIM uses three-dimensional, real-time, dynamic building modeling software to increase productivity in building design and construction
To create a BIM, a modeler uses intelligent objects (Families) to build the model.
Turn Revit data into useful information with visualization techniques and wor...
BIM technology has been improving and its use is spreading in the construction industry more and more every year, reaching a point that we can make sure that it here to stay, but even today
most of the BIM processes and workflows are clear and established for the geometric and visualization tools of the technology but not for the Data management. We all agree that the parametrization and the data provided by the BIM Software is the key of the everything, but even today is not really clear which are the best practices to obtain data and process it to
understand patterns or get conclusions that can lead us into better designs on every project.
That is why the main objective of this lecture is to dig on the better practices to go from raw Revit Data to great visualizations that will lead us into better decisions and workflows on our
construction projects.
Implementing Building Information Modelling in Construction
Building Information Modeling (BIM) is an integrated software that simulates the entire construction design process, including materials, boundaries, and requirements. BIM manages graphical displays, construction details, and data, allowing architects and engineers to easily create drawings, reports, and analyze designs. It simulates infrastructure in a few clicks and empowers facilities management and material purchasing. BIM eliminates data redundancy, supports standards, and saves costs through interconnected digital design. It helps track asset management, construction sequencing, information sharing, and ensures all stakeholders have up-to-date information to implement BIM throughout the construction process.
What's hot (19)
BIM (Building Information Modeling) for digital construction
BIM (Building Information Modeling) for digital construction
The future of BIM is open - or - Is proprietary BIM unsustainable
The future of BIM is open - or - Is proprietary BIM unsustainable
CM - An introduction to Building Information Modelling (BIM)
CM - An introduction to Building Information Modelling (BIM)
BIM: What kind of information is modeled in Parametric Building Information M...
BIM: What kind of information is modeled in Parametric Building Information M...
Building information modelling - redefining the role of the project manager: ...
Building information modelling - redefining the role of the project manager: ...
Turn Revit data into useful information with visualization techniques and wor...
Turn Revit data into useful information with visualization techniques and wor...
Implementing Building Information Modelling in Construction
Implementing Building Information Modelling in Construction
Viewers also liked
BIM Building Information Modeling History
The document discusses Building Information Modeling (BIM). It defines BIM as a process and software used to manage a building's data during its lifecycle. The document outlines that BIM has evolved from 2D hand drawings to 3D parametric modeling. It notes current BIM uses 3D components for documentation, exchange, and visualization. Finally, it explores the future of BIM including international BIM libraries, using QR codes to access furniture data, and electronic permit submissions through 3D city platforms.
Building Information Modeling (BIM)
The presentation covers following areas:
- Typical Problems in Construction Industry
- What is BIM?
-BIM Process
- Influence of BIM on Industry Problems
- BIM Application
- BIM Advantages
- BIM Workflow
- BIM & Project Management
- BIM & Design Team Members
- BIM around the Globe
- Construction Industry with BIM
All work presented in the presentation is carried out by graduates of NUST, Islambad including Abdul Mughees Khan, Syed Kashif Ali Shah, Sharjeel Ahmad Tariq, Malik Awais Ahmad and Hamza Khan Shinwari.
Special credit of the work goes to Engr Tahir Shamshad, Vice President NESPAK and Engr Zia Ud Din, Asst Professor NUST under guidance and mentor ship the whole work was performed.
For more details feel free to contact: amugheeskhan@gmail.com
การพัฒรากระบวนการ BIM หรือ Building Information Modeling ที่ยั้งยืนในประเทศไทย
การพัฒรากระบวนการ BIM หรือ Building Information Modeling ที่ยั้งยืนในประเทศไทย
Bringing together World of BIM and World of Products
The integration of real-world products into BIM is the key to unlocking 4D (time), 5D (cost), 6D (green) and 7D (FM). BIMSpecify - an innovative specification, costing and collaboration platform for BIM Projects.
BIMSpecify brings together the 'World of BIM' and the 'World of Products' into a real-time collaborative environment. BIMSpecify allows manufacturers to publish entire product catalogs and costbooks into Revit, thereby allowing Architects to specify real-world building products directly onto elements within BIM Projects.
Moreover manufacturers and other users can simultaneously collaborate with architects and designers on the same project from anywhere in the world. Multiple users can specify products, have real-time discussions, schedule reminders, add photos, snags, files - directly from inside Revit or remotely via 2D or 3D DWF files. Both online and offline – BIMSpecify’s real-time collaboration engine keeps everybody in sync.
Bills of Quantities and Product reports such as Ironmongery schedules are generated real time by the BIM project. Where it It can take traditional specifiers weeks to produce an ironmongery schedule for a large project, BIMSpecify takes minutes. BIMSpecify can also allow manufacturers to track building products and their exact quantities as they are specified & updated in BIM projects.
BIM Presentation
BIM programs and practices can greatly impact productivity in the construction industry. BIM allows for improved coordination between teams, which reduces errors and rework. Studies show that BIM users report fewer errors in design and less rework during construction. They also see improved communication and reduced project timelines. When implemented properly with trained staff, BIM supports gathering and sharing information across projects to help optimize results and efficiency throughout the construction process.
What is BIM from software technology viewpoint ?
The document discusses Building Information Modeling (BIM) from a software technology viewpoint. It describes BIM as 3D design with attached information that exists from early design through demolition. There are three layers to BIM software: applications, data models, and data storage. For fluent data flow between software, applications should use a shared data model to prevent data conversions and loss. An optimal approach involves a single shared model stored in a cloud database with a web service for collaborative access.
HMG BIM Stategy - Mark Bew
The document provides an overview of the UK government's Building Information Modelling (BIM) strategy. It discusses the goals of using open, sharable asset information to improve cost, value, and carbon performance for government projects. The strategy involves both "pulling" requirements from government clients and "pushing" standards and training through the supply chain. The target is to achieve level 2 BIM by 2016, where integrated project models and data are collaboratively used. Key aspects covered include the BIM program structure, delivery standards, Common Data Environment, and questions from early adopters.
What does BIM mean for Civil Engineers?
BIM is a norm for the building industry. How about for infrastructures? Some countries are over confident on the implementation of BIM in both building and civil engineering industries. Is the BIM technology for infrastructures mature and easily available? Are the professionals ready for BIM?
Vũ trụ & các học thuyết
Sơ lược một số học thuyết của vũ trụ:
Thuyết địa tâm; Thuyết nhật tâm; Vũ trụ luận; Newton; Aristotle, Bigbang; Einstein...
Slide này được dùng thuyết trình trong chương trình tìm hiểu Vũ trụ và Triết học tại trường Đại Học Bách Khoa TpHCM, năm 2010.
Trong Slides có sử dụng một số hình ảnh từ internet và các tạp chí như Scientific America, Science, Britannica Illustrated Encyclopedia.
Master key system part 24
This document contains the final lesson of Charles Haanel's Master Key System course. It discusses how developing an understanding of the Universal Mind and one's connection to it allows one to manifest positive conditions by thinking the truth. It emphasizes that the Universal Mind is omnipresent and creative, and one can access it within to overcome error, lack, disease or limitations by convincing themselves of the truth. Practicing focused, sustained truthful thinking will enable one to express ideal conditions in their life and environment.
Downtowndoughcookiecutters
This search engine optimization report provides rankings for 67 keywords and one URL on 7 search engines from April 13, 2010 and compares them to rankings from March 1, 2010. Key findings include: 53 listings ranked #1, 146 in the top 5, and 310 listings either new or moved up. The report also provides detailed ranking results for each keyword and URL on each search engine.
Elements of success: Southern district forum
The document discusses elements of successful communications including using social media and storytelling. It emphasizes that stories are more effective than data at conveying important messages and motivating action. Examples are provided of how to develop a communications strategy, capture compelling stories, and leverage social media platforms like Facebook, Twitter, and photo contests to engage audiences and spread an organization's message.
Terminating a Construction Contract: Getting it Right
The document discusses terminating construction contracts, including:
- The different types of termination under common law and standard form building contracts like the JCT SBC 2011.
- The JCT SBC 2011 outlines specific grounds and procedures for termination if the contractor suspends work, fails to proceed regularly, or becomes insolvent.
- Wrongful termination is a repudiatory breach that entitles the innocent party to damages but not contract reinstatement.
Olswang 2nd Annual Construction Law Conference
The document summarizes the agenda for the Construction Law Conference 2015 event on "On Time and Budget" to be held on 5 February 2015. The agenda includes sessions on sustainability, insurance, case law updates, liquidated damages, CDM 2015, and networking. There will be a welcome and introduction, followed by several speaker presentations and a Q&A session on various construction law topics. The event will conclude with refreshments and networking.
Doing More With Less
Instituted Total Quality Management (TQM), Statistical Process Control (SPC), and Benchmarking techniques
Viewers also liked (20)
การพัฒรากระบวนการ BIM หรือ Building Information Modeling ที่ยั้งยืนในประเทศไทย
การพัฒรากระบวนการ BIM หรือ Building Information Modeling ที่ยั้งยืนในประเทศไทย
Bringing together World of BIM and World of Products
Bringing together World of BIM and World of Products
Terminating a Construction Contract: Getting it Right
Terminating a Construction Contract: Getting it Right
Namasmaran B E S T S E L L E R O N S U P E R L I V I N G Dr
Namasmaran B E S T S E L L E R O N S U P E R L I V I N G Dr
Similar to BIM - Building Information Modelling - 2014 Olswang Construction Law Conference
Data innovations and cloud 2018-10-19 slideshare
Ronald Baan, an independent data architect, gave a presentation on digital innovations and the cloud. He discussed how building information management (BIM) uses cloud computing and semantic modeling to improve collaboration between parties involved in infrastructure projects. Baan explained that moving project data to the cloud allows for better data sharing, but organizations must first semantically define all data structures. He also emphasized that a hybrid cloud approach provides more flexibility and agility than a solely centralized or decentralized system. In the end, Baan argued that adopting cloud technologies requires organizations to embrace digital transformation and have an "all digital" mindset.
ENR FutureTech Article - David Epps
1) While information mobility tools on construction sites have grown in popularity, the use of 3D and building information models (BIM) for collaboration on jobsites is still limited. Experts say that BIM mobility has potential benefits but widespread adoption depends on project complexity and contractor size.
2) Holder Construction uses 4D modeling software to create construction simulations that help project superintendents visualize and plan schedules. However, a survey found that most contractors do not extensively use mobile devices to access and author 3D models on sites due to data limitations and worker training.
3) As cloud computing advances and owners increasingly expect electronic project handovers, experts predict that BIM collaboration will continue growing. But proving clear returns
BIM SHOW LIVE 14: Big BIM Theory
BIM (Building Information Modeling) involves creating a digital model of a building to allow everyone to understand it. The use of BIM in the UK construction industry is increasing, with the government requiring its use by 2016. There is high demand for quality BIM objects that contain information, geometry, behavior and presentation attributes. The National BIM Library provides object standards and access to thousands of BIM objects to help the industry adopt BIM practices.
Next generation Polyglot Architectures using Neo4j by Stefan Kolmar
https://www.bigdataspain.org/2016/program/thu-next-generation-polyglot-architectures-using-neo4j.html
https://www.youtube.com/watch?v=kVbUJHNyccc&t=18s&index=32&list=PL6O3g23-p8Tr5eqnIIPdBD_8eE5JBDBik
#AU2016 Unlock the "I" in BIM with Data Democratization
In order to achieve a positive return on investment (ROI) in Building Information Modeling (BIM), data should transfer freely and reliably between relevant project stakeholders. Cloud collaboration tools seek to address the AEC industry’s past challenges with effective BIM collaboration. This presentation describes how the democratization of data allows project teams to disrupt traditional practices and and create exponential value to the design and construction process.
PLS 2016: How does the BIM process fit with street lighting design and mainte...
PLS 2016: How does the BIM process fit with street lighting design and mainte...Institution of Lighting Professionals
The Government Construction Strategy was published by the Cabinet Office in 2011, announcing that all centrally procured contracts should be compliant with BIM by 2016. The key objective of this approach is to reduce the capital cost and the carbon burden from the construction and operation of the built environment by a fifth. So how should a lighting engineer tackle building a digital street lighting information model?
Talk by Will Baron, Keysoft SolutionsBIM For Free_28May2013_CaseyRutland_BIM for beginners
The document provides an introduction to building information modeling (BIM) for beginners. It discusses common BIM acronyms and myths, the benefits of BIM for projects and companies, different BIM tools available, and the importance of developing a BIM culture within an organization. It encourages readers to start adopting BIM now rather than waiting, and provides tips on where to learn more and take initial steps towards BIM competence.
AAM Group GIS - BIM Integration
AAM Group presentation at the Esri User Conference 2016.
The presentation discusses the convergence of GIS, CAD and BIM and how this aids in Urban Planning and Management
BIM For Free_28May2013_CaseyRutland_BIM for beginners
This document provides an introduction to Building Information Modeling (BIM) for beginners. It discusses key BIM acronyms and concepts, common myths and pitfalls to avoid, and benefits of BIM for projects and companies. It also reviews various BIM tools and the importance of developing a BIM culture and integrating it as a business process rather than just a software add-on. The document encourages readers to start adopting BIM now through small, manageable projects and continuing education on BIM best practices.
BIM For Free_28May2013_CaseyRutland_BIM for beginners
This document provides an introduction to Building Information Modeling (BIM) for beginners. It discusses key BIM acronyms and concepts, common myths and pitfalls to avoid, and benefits of BIM for projects and companies. It also reviews various BIM tools and the importance of developing a BIM culture and integrating it as a business process rather than just a software add-on. The document encourages readers to start adopting BIM now through small, manageable projects and continuing education on BIM best practices.
BIM 6D SERVICES - Building Information Modelling
We at building information modeling.net manage to work according to the need and requirements of the clients and thus are one of the leading BIM 6D Service Providers Globally.
BIM 6D Services
Our services are not limited to 6D BIM Services, but we are masters in completing BIM services, along with following different levels of developments such as LOD300, LOD400, LOD500, COBie services, and much more. By following the software like Autodesk Revit, ZWCAD+, and more. Thus, with this said contact us today and get your BIM project designed and drafted by the leading company.
An Introduction to BIM for Manufacturers
Ian Chapman, Director the NBS National BIM Library, provides an introduction to the world of Building Information Modelling and what it means (and can be utlised by) manufacturers. This presentation formed part of the Digital Building Theatre programme at Ecobuild 2016.
A Bumpy Road to Digital Twin
I gave this talk at the ITEA3 Smart City Business Event. In this talk, I introduced mago3D project, an open source based digital twin platform first. And then shared the real cases that I and my company have carried out in various industries. I concluded the talk with what I've learnt from these real projects. Some food for thoughts around digital twin were provided for further discussion.
Building Information Modelling Presentation
The document discusses Building Information Modeling (BIM) and its applications. It provides definitions of BIM from various organizations. It describes how BIM can be used across the project lifecycle from design through construction and operations for applications like 3D modeling, 4D scheduling, 5D cost estimating, sustainability analysis, and facility management. It also discusses BIM management topics like the different levels of BIM implementation and standards.
Data Architecture Strategies: Data Architecture for Digital Transformation
MDM, data quality, data architecture, and more. At the same time, combining these foundational data management approaches with other innovative techniques can help drive organizational change as well as technological transformation. This webinar will provide practical steps for creating a data foundation for effective digital transformation.
nForm Better Intranets | SharePoint 2013 Best Practices
nForm's Better Intranets Conference on June 12, 2014. Presenter Michal Pisarek from Dynamic Owl Consulting shares insight on SharePoint 2013.
John adams viewpoint
The document discusses the benefits of using a common data environment (CDE) with collaborative BIM. It explains that a CDE allows all project data to be captured in a standardized way in a single source of truth that can be accessed by the entire project team. The CDE facilitates open data standards like IFC and COBie that ensure interoperability between teams and into the future for facilities management. The software discussed, Project by Viewpoint, provides a CDE that supports these open BIM standards and workflows to efficiently deliver construction projects.
2024 mega trends for the digital workplace - FINAL.pdf
Slides from Nancy Goebel's talk at ISG's 2024 Future Workplace Summit
2024 Scan to BIM: Ultimate Guide for Point Cloud Modeling
2024 Scan to BIM: Ultimate Guide for Point Cloud ModelingChudasama Outsourcing | AutoCAD Drawing and Drafting Services
The ultimate guide to Scan to BIM, the leading technique for transforming point cloud data into BIM models in 2024, This article emphasizes the procedure of scanning to BIM. It illustrates the idea of converting point clouds to BIM models. It underlines the role of these procedures in the building sector for the generation of 3D models with correct and detailed information about existing structures. The article also emphasizes some of the merits of scanning to BIM, like superior project visualization, clash detection, and correct measurement.Similar to BIM - Building Information Modelling - 2014 Olswang Construction Law Conference (20)
Next generation Polyglot Architectures using Neo4j by Stefan Kolmar
Next generation Polyglot Architectures using Neo4j by Stefan Kolmar
#AU2016 Unlock the "I" in BIM with Data Democratization
#AU2016 Unlock the "I" in BIM with Data Democratization
PLS 2016: How does the BIM process fit with street lighting design and mainte...
PLS 2016: How does the BIM process fit with street lighting design and mainte...
BIM For Free_28May2013_CaseyRutland_BIM for beginners
BIM For Free_28May2013_CaseyRutland_BIM for beginners
BIM For Free_28May2013_CaseyRutland_BIM for beginners
BIM For Free_28May2013_CaseyRutland_BIM for beginners
BIM For Free_28May2013_CaseyRutland_BIM for beginners
BIM For Free_28May2013_CaseyRutland_BIM for beginners
Data Architecture Strategies: Data Architecture for Digital Transformation
Data Architecture Strategies: Data Architecture for Digital Transformation
nForm Better Intranets | SharePoint 2013 Best Practices
nForm Better Intranets | SharePoint 2013 Best Practices
2024 mega trends for the digital workplace - FINAL.pdf
2024 mega trends for the digital workplace - FINAL.pdf
2024 Scan to BIM: Ultimate Guide for Point Cloud Modeling
2024 Scan to BIM: Ultimate Guide for Point Cloud Modeling
More from Francis Ho
COP26: Eating for the Planet
We were asked to give a talk to colleagues as part of a "COP26 fortnight" at Penningtons Manches Cooper LLP on the benefits of a lifestyle eating less meat.
City of London Law Society - Submittal to BEIS on Statutory Retention Deposit...
A supplemental submission from the City of London Law Society's Construction Law Committee sent to the Department for Business, Energy & Industrial Strategy (BEIS) on 3 December 2018 regarding potential proposals to introduce a statutory retention deposit scheme for construction contracts in the United Kingdom.
City of London Law Society - Construction Law Committee - Response to Retenti...
RESPONSE OF THE CITY OF LONDON LAW SOCIETY CONSTRUCTION LAW COMMITTEE TO THE DEPARTMENT FOR BUSINESS, ENERGY & INDUSTRIAL STRATEGY'S CONSULTATION ON THE PRACTICE OF CASH RETENTION UNDER CONSTRUCTION CONTRACTS
How will Brexit impact on Construction?
A seminar at IBC Legal Construction Law Summer School 2016 at Gonville and Cauis College, Cambridge on 8 September 2016
Variations and their Consequences - Olswang Construction Law Masterclass - 5 ...
This document summarizes key aspects of variations in construction contracts, including:
1) What constitutes a variation based on standard contract definitions.
2) Why variation clauses are included in contracts to allow flexibility for changes.
3) Procedures for instructing, valuing, and agreeing to variations.
4) Issues that can arise regarding scope, instructions, notice periods and whether a variation has actually occurred.
5) The impact of anti-oral variation clauses and agency on how variations are authorized.
6) Special considerations for omitting contracted work versus instructing additions.
Construction Insolvency
The document discusses construction insolvencies in the UK construction industry. It notes that the construction sector experiences the most insolvencies, accounting for about a quarter of all UK insolvencies. In the first quarter of 2016, construction industry output decreased by 1.1% compared to the previous quarter. The document also discusses how "Brexit" could impact construction companies through potential loss of EU labor and funding. It outlines some factors that make construction companies prone to insolvency, such as cash flow issues, disputes, and lack of credit. Finally, it provides tips for mitigating insolvency risks through due diligence, documentation, and actions to take if insolvency occurs.
The Management of Complex Contracts
The document summarizes a presentation on managing complex construction projects. It discusses the definition of complex projects as those that are high value, major real estate developments, or engineering/infrastructure projects. It outlines the Chartered Institute of Building's Complex Projects Contract 2013 (CPC 2013), which provides contract terms and conditions for managing complex projects. The CPC 2013 introduces new roles like Project Time Manager and adds provisions for transparency, collaboration, electronic data transfer, and BIM use. Finally, the presentation provides resources for further information on the CPC 2013 and notes that construction knowledge, risk management, and critical path analysis are still essential for complex project management.
Key Developments in Emerging Markets
This document summarizes key points from a construction law summer school discussion on emerging markets. It outlines some of the interactions between civil law and common law systems that can cause conflicts in construction contracts. Cultural and political concerns in emerging markets are also discussed, such as being bound by local dispute resolution forums and public policy requirements. The document also summarizes considerations for working with local contractors, splitting EPC contracts, contract administration expectations, and managing claims in international construction projects in emerging markets.
Using Two-Stage Tendering Effectively
Two stage tendering is commonly used for large or complex projects where it is difficult to get accurate bids from contractors based on incomplete designs. It involves contractors submitting initial bids based on limited information, with one contractor then selected to work with the client during the pre-construction stage to develop a fixed price bid. This allows for early contractor input to improve design and feasibility, while giving the client greater cost certainty. However, it also carries risks of compromising the client's negotiating position or damaged relations if not handled properly. The document provides tips for clients on maintaining control during both stages.
Managing the Risks of Delay in Construction Projects
Delay is a common risk in construction projects with multiple potential causes. Proper notice provisions and documentation are essential to support any delay claims between the employer and contractor. Liquidated damages, termination, and instructions to accelerate works are some of the remedies available to employers for contractor delay, but contractors may challenge these and claim their own remedies for employer-caused delays.
It Pays to Be Right: Payment in Construction Contracts
This document summarizes key principles regarding payment in construction contracts under the Housing Grants, Construction and Regeneration Act 1996 in the UK. It discusses mandatory payment provisions, including requirements for adequate payment mechanisms and notices. It notes that failing to serve valid pay less notices can result in having to pay the notified sum. It also discusses issues like overpayment, making valid interim payment applications, and the need for employers to strictly follow notice requirements in order to later challenge payment amounts.
Adjudication: Tips, Traps and Tactics
The document provides an overview of adjudication procedures in the UK construction industry. It discusses:
- The basics of adjudication, including its compulsory nature, binding interim decisions, and typical process.
- How to effectively "spring ambushes" in adjudication, such as by including all necessary evidence and considering timing carefully. It also discusses how to prevent being ambushed through contract drafting and monitoring for warning signs.
- Key considerations regarding the adjudicator, including expertise, conflicts, and fees. It emphasizes the importance of accurately describing the dispute in the notice of adjudication.
- Challenging the adjudicator's jurisdiction, reserving positions, and identifying and correcting errors in the adjud
Contractual Options for Procuring Major Projects in the UK
This document discusses contractual options for procuring major construction projects in the UK. It outlines several methods used to fund projects, including project finance, equity, sovereign wealth funds, and forward funding. It also discusses framework agreements and two-stage tendering processes. Framework agreements involve establishing umbrella agreements with terms for future works, while two-stage tendering selects a preferred contractor who then works on pre-construction services before providing a final fixed price. The document advises being flexible on projects and considering these procurement strategies in an overheated construction market.
Introductory Note on International Construction Contracts
Olswang LLP is a limited liability partnership in England and Wales that is authorized and regulated by the Solicitors Regulation Authority. The document discusses several key points regarding international construction contracts: (1) common standard form contracts used internationally include FIDIC, ICE, IChemE, CIOB, and NEC contracts; (2) while UK forms can be adapted, it is not recommended as they are too locally specific and international contractors prefer standard international forms; (3) the various FIDIC contracts - Red, Yellow, Silver, Pink, Gold, Blue, White, and subcontract - are introduced along with their key purposes and differences.
Works Insurance and Latent Defects Insurance
The document discusses various types of insurance related to construction projects, including all risks insurance, latent defects insurance, and options for insuring works under JCT contracts. All risks insurance covers physical damage to works and materials, and is often maintained by the contractor. Latent defects insurance provides protection for inherent defects discovered after practical completion up to a specified threshold. While it has advantages over collateral warranties like being freely assignable, there are also gaps in protection if no warranty package is also in place. The document also notes potential issues with Option C of insuring works under JCT contracts and ways to address them.
Third Party Rights and Why They Matter
Third party rights allow non-parties to a contract to enforce certain terms of that contract. They provide an alternative to collateral warranties in construction contracts. Uptake of third party rights has been slow due to familiarity with collateral warranties and concerns over control. However, recent cases indicate third party rights may avoid issues like adjudication that can arise with collateral warranties. Effective drafting and clarity around beneficiaries and their obligations can maximize the benefits of third party rights.
A Practical Guide to the Construction (Design and Management) Regulations 2015
The Construction (Design and Management) Regulations 2015 came into effect in April 2015 and introduced several significant changes from the 2007 regulations. Key changes include:
- Replacing the CDM Coordinator role with a new 'Principal Designer' role to have more influence over design.
- Requiring written construction phase plans for all projects, not just notifiable ones.
- Applying the regulations to domestic clients who can delegate duties to contractors.
- Introducing transitional provisions for projects that began before April 2015.
- Awaiting new, shorter guidance from the HSE to replace the abolished Approved Code of Practice.
Construction Dispute Resolution and Avoidance in a Boom Market
This document discusses construction dispute resolution and avoidance in a booming construction market. It summarizes various dispute resolution methods including (1) adjudication which provides quick, binding interim decisions but may be less suited to complex cases; (2) court proceedings through the specialist Technology and Construction Court which are suited to complex cases but slow and expensive; (3) arbitration which is confidential but can be slow to start; and (4) alternative dispute resolution methods like mediation and dispute boards. It stresses that dispute avoidance through careful contract drafting and project management is the cheapest option.
Letters of Intent
This document discusses types of letters of intent (LOIs) and provides tips for drafting binding LOIs for construction projects. It outlines four types of LOIs from non-binding to fully binding. It advises including key details in binding LOIs like scope, payment terms, standards, and timelines. It also recommends stating what happens if the final contract is not signed and having both parties execute the LOI for it to be binding. The document cautions against treating an LOI as a full contract and delaying the final contract. It also notes the primary standard form used is the City of London Law Society's but it can be awkward and out of date.
Collateral Warranties and Third Party Rights
An introductory level talk on collateral warranties and third party rights under the Contracts (Rights of Third Parties) Act 1999
More from Francis Ho (20)
City of London Law Society - Submittal to BEIS on Statutory Retention Deposit...
City of London Law Society - Submittal to BEIS on Statutory Retention Deposit...
City of London Law Society - Construction Law Committee - Response to Retenti...
City of London Law Society - Construction Law Committee - Response to Retenti...
Variations and their Consequences - Olswang Construction Law Masterclass - 5 ...
Variations and their Consequences - Olswang Construction Law Masterclass - 5 ...
Managing the Risks of Delay in Construction Projects
Managing the Risks of Delay in Construction Projects
It Pays to Be Right: Payment in Construction Contracts
It Pays to Be Right: Payment in Construction Contracts
Contractual Options for Procuring Major Projects in the UK
Contractual Options for Procuring Major Projects in the UK
Introductory Note on International Construction Contracts
Introductory Note on International Construction Contracts
A Practical Guide to the Construction (Design and Management) Regulations 2015
A Practical Guide to the Construction (Design and Management) Regulations 2015
Construction Dispute Resolution and Avoidance in a Boom Market
Construction Dispute Resolution and Avoidance in a Boom Market
Recently uploaded
Stark Builders: Where Quality Meets Craftsmanship!
At Stark Builders our vision is to redefine the renovation experience by combining both stunning design and high quality construction skills. We believe that by delivering both these key aspects together we are able to achieve incredible results for our clients and ensure every project reflects their vision and enhances their lifestyle.
Although we are not all related by blood we have created a team of highly professional and hardworking individuals who share the common goal of delivering beautiful and functional renovated spaces. Our tight nit team are able to work together in a way where we pour our passion into each and every project as we have a love for what we do. Building is our life.
Floople Real Estate Market in the UK - Current Trends and Future Prospects
Housing prices, rental rates, market demand, and investment trends
Why is Revit MEP Outsourcing considered an as good option for construction pr...
Outsourcing MEP modeling services require effective collaboration and coordination amongst multiple engineering trades. The engineers and the designers often change the details of the MEP projects, but the work of Revit MEP drafting services is having the master plan and model of the complete project. To have proper coordination and installation, there is a need to execute the project effectively. Hence, the work of Revit family creation facilitates the MEP engineers.
Sunrise Infra Properties Company Profile Pradeep.pdf
COmpany Profile of SunRise Infra Properties Pvt. Ltd.
SVN Live 6.17.24 Weekly Property Broadcast
The SVN® organization shares a portion of their new weekly listings via their SVN Live® Weekly Property Broadcast. Visit https://svn.com/svn-live/ if you would like to attend our weekly call, which we open up to the brokerage community.
Signature Global TITANIUM SPR | 3.5 & 4.5BHK High rise Apartments in Gurgaon
Signature Global TITANIUM SPR launched a high rise apartments in Gurgaon . In this project Signature Global offers 3.5 & 4.5 BHK high rise Apartment at sector 71 Gurgaon SPR Road. Signature Global Titanium SPR is IGBC Gold certified, a testament to our commitment to sustainability.
Listing Turkey - Piyalepasa Istanbul Catalog
We are working around the clock to transform a long-time dream into reality. As a result, Piyalepasa Istanbul will be the largest privately developed urban regeneration project in Turkey.
THE NEIGHBORHOOD WE HAVE BEEN LONGING FOR IS COMING TO LIFE
The good old days of the Piyalepasa neighborhood are being brought back to life with Piyalepasa Istanbul houses, residences, offices, hotels and a pedestrianized shopping avenue.
The wide streets of this 82.000 square meter development conveniently face the main boulevard in a prime Beyoglu location. “Piyalepaşa İstanbul” stands out as the only project designed to offer a neighborhood lifestyle, complete with its grocers, bagel sellers and greengrocer. Piyalepasa Istanbul has all the values to make it an authentic neighborhood, our very own community.
A NEIGHBORHOOD FULL OF LIFE, IN THE HEART OF THE CITY!
“Piyalepaşa İstanbul” is a “mixed-use” concept containing all the elements for a vibrant social life with houses, residences, offices, hotels and high street shopping.
“Piyalepaşa İstanbul” will take the liveliness of Istanbul into its heart. The elegant sparkle of Nisantasi, the young and colorful Besiktas, the variety and multicultural heritage of Istiklal Street will all be contained within the streets of this neighborhood.
“Piyalepaşa İstanbul” bears traces of the most beautiful examples of Turkish architecture from the Seljuks to the Ottomans and from Anatolia to Rumelia. With its graded facades, wide eaves, bay windows, pools, and interior courtyard systems, it offers a new living space without disrupting the city’s silhouette and neighborhood.
“Piyalepaşa İstanbul” is the new attraction of this splendid city.
TO BE AT THE CENTER OF ISTANBUL… THIS IS REAL LUXURY!
With its proximity to D-100 highway, connecting roads and tunnels, “Piyalepaşa İstanbul” is only minutes away from Kabatas, Besiktas, the Golden Horn and Karakoy.
“Piyalepaşa İstanbul” is close to the prestigious new Istanbul Court House, a major hospital, the Perpa trade center and the city’s most lively neighborhoods. With its shuttle service to Okmeydani Metrobus station, Sishane and the Court House subway stations, “Piyalepaşa İstanbul” will provide you with the most convenient transport connections.
https://listingturkey.com/property/piyalepasa-istanbul/
Anilesh Ahuja Pioneering a Paradigm Shift in Real Estate Success.pptx
Anilesh Ahuja journey is a testament to the power of vision, resilience, and unwavering determination. As a visionary leader, he continues to inspire and empower others to dream big and challenge the status quo. His legacy extends far beyond the realm of real estate, leaving an indelible mark on the industry and the world at large.
Living in an UBER World - June '24 Sales Meeting
June 2024 Lancaster County Sales Meeting for Berkshire Hathaway HomeServices Homesale Realty covering the following topics: 1. VA Suspends Buyer Agent Payment Plan (article), 2. Frequently Used Terms in title, 3. Zillow Showcase Overview, 4. QuickBuy commission promotion, 5. Documenting Cooperative Compensation, 6. NAR's Code of Ethics - Mass Media Solicitations, 7. Is it really cheaper to rent? 8. Do's and Don't's when Terminating the Agreement of Sale, 9. Living in an UBER World
Office Building for Sale - 2810 City View Drive, Madison, WI
36,778 sq. ft. building; Zoning: SE (Suburban Employment): The (SE) District allows numerous commercial site uses; Passenger elevator; Private and common restrooms; Fully sprinkled; Data center with a grounded floor and a specialized HVAC system; 60 KVA back-up generator; Building/pylon signage; Potential to purchase adjacent parcels; Sale Price: $4,413,360
Future of andhra pradesh real estate.pdf
Andhra Pradesh, known for its strategic location on the southeastern coast of India, has emerged as a key player in India’s industrial landscape. Over the decades, the state has witnessed significant growth across various sectors,
Recently uploaded (11)
Stark Builders: Where Quality Meets Craftsmanship!
Stark Builders: Where Quality Meets Craftsmanship!
Floople Real Estate Market in the UK - Current Trends and Future Prospects
Floople Real Estate Market in the UK - Current Trends and Future Prospects
Why is Revit MEP Outsourcing considered an as good option for construction pr...
Why is Revit MEP Outsourcing considered an as good option for construction pr...
Sunrise Infra Properties Company Profile Pradeep.pdf
Sunrise Infra Properties Company Profile Pradeep.pdf
Signature Global TITANIUM SPR | 3.5 & 4.5BHK High rise Apartments in Gurgaon
Signature Global TITANIUM SPR | 3.5 & 4.5BHK High rise Apartments in Gurgaon
Anilesh Ahuja Pioneering a Paradigm Shift in Real Estate Success.pptx
Anilesh Ahuja Pioneering a Paradigm Shift in Real Estate Success.pptx
Office Building for Sale - 2810 City View Drive, Madison, WI
Office Building for Sale - 2810 City View Drive, Madison, WI
BIM - Building Information Modelling - 2014 Olswang Construction Law Conference
- 1. 2014 Construction Law Conference: Building Information Modelling Thursday, 6 February 2014 Sarah Rock, Associate sarah.rock@olswang.com | +44 20 7067 3898 | @sarahrocklaw
- 2. What is BIM? • 3D model • Information rich • Intelligent objects • Parametric data • Data sharing – cloud • Clash detection • Pre-fabrication • Integrated process • Collaborative working #olswangconstruction www.constructiveblog.com
- 3. BIM in use in the UK • Level 2 – independent models linked together • National BIM Report 2013 – 39% of industry currently using BIM • Government Construction Strategy 2011 – intention to use BIM on all projects by 2016 #olswangconstruction www.constructiveblog.com
- 5. Employer’s Information Requirements - Technical • Software platform • Data Exchange Format • Level of Detail #olswangconstruction www.constructiveblog.com
- 6. Employer’s Information Requirements - Management • Standards • Roles and Responsibilities • Security • Clash Detection • Collaboration Process #olswangconstruction www.constructiveblog.com
- 7. Employer’s Information Requirements - Commercial • Data Drops • BIM-specific Competence Assessment #olswangconstruction www.constructiveblog.com
- 8. Information Manager • New role • Can be existing member of project team • Assists with putting EIRs together, setting up and implementing the BIM protocol • Manages the BIM process #olswangconstruction www.constructiveblog.com
- 9. BIM Protocol • Software to be used • Data exchange • Management of Common Data Environment • Data security • File naming #olswangconstruction www.constructiveblog.com
- 10. Facilities Management • Negates requirement for full building asset survey • Assists going forwards with O&M • Visual 3D walkthroughs to locate faults • Laser scanning for pre-existing assets #olswangconstruction www.constructiveblog.com