This document outlines the tender process for the construction of a 4-story commercial building. It includes 9 sections covering instructions, conditions, forms, specifications and drawings. Requirements include experience with similar projects of at least 1.2 crore BDT, an annual turnover of 1 crore BDT, and liquid assets of 80 lacs BDT. The tender submission deadline is November 12th, 2015. The opening will be on November 17th at the Executive Engineer's office. The performance security required is 10% of the contract price. The intended completion date for the project is November 5th, 2017.
Presentation tries to give an overview and brief about tendering used in the building works for the benefit of students of architecture. Additions and alterations can be made to make it a better one. It is based on the book of Professional practice by Krishnamurthy and Ravindra
The present topic describes the defination, types, content of typical tender notice, step by step procedure, 3-bid and 2-bid system of tenders, earnest money deposit, security deposit, unbalanced tender.
Contracts and Tenders
When two or more persons have common intention communicated to each other to create same obligation between them there is said to be an agreement. An agreement which is enforceable by law is a Contract.
A Tenders is called upon for executing certain specified work, or supplying specified materials; subjected to certain terms and conditions like rates, time limit, etc. It is an offer in written form: Legally speaking, it is an offer to receive an offer for the work, within the specified financial limits.
Check for more presentations at - www.archistudent.net
Presentation tries to give an overview and brief about tendering used in the building works for the benefit of students of architecture. Additions and alterations can be made to make it a better one. It is based on the book of Professional practice by Krishnamurthy and Ravindra
The present topic describes the defination, types, content of typical tender notice, step by step procedure, 3-bid and 2-bid system of tenders, earnest money deposit, security deposit, unbalanced tender.
Contracts and Tenders
When two or more persons have common intention communicated to each other to create same obligation between them there is said to be an agreement. An agreement which is enforceable by law is a Contract.
A Tenders is called upon for executing certain specified work, or supplying specified materials; subjected to certain terms and conditions like rates, time limit, etc. It is an offer in written form: Legally speaking, it is an offer to receive an offer for the work, within the specified financial limits.
Check for more presentations at - www.archistudent.net
Presentation is trying to define the intent , content, methods and scope of arbitration and tendering and its implications for the architectural practice.
Types of Contract in Construction ManagementShahin MB
Types of Contract in Construction Management
Lump Sum Contract
Cost plus Fixed fee
Cost plus bid fee contract
Guaranteed Maximum
Negotiated
Unit price Contract
Design build
turn key contract
This presentation includes:
1. What is tender and types of tender?
2. What is contract and types of contracts?
3. Process of inviting tender and awarding contract.
4. Important definitions:- EMD, SD, Bill of quantities, Quotation, etc.
Tender Process | A Complete Procurement GuideTender Process
All about Tenders and its Process | Here you will get all the information regarding tenders (Procurement) like what is tender, what is its process, types of tender, how to search tenders, what to do and what not to do in tendering, how to search tenders and more.... you can check our website for more details which is : http://tenderprocess.weebly.com/
Presentation is trying to define the intent , content, methods and scope of arbitration and tendering and its implications for the architectural practice.
Types of Contract in Construction ManagementShahin MB
Types of Contract in Construction Management
Lump Sum Contract
Cost plus Fixed fee
Cost plus bid fee contract
Guaranteed Maximum
Negotiated
Unit price Contract
Design build
turn key contract
This presentation includes:
1. What is tender and types of tender?
2. What is contract and types of contracts?
3. Process of inviting tender and awarding contract.
4. Important definitions:- EMD, SD, Bill of quantities, Quotation, etc.
Tender Process | A Complete Procurement GuideTender Process
All about Tenders and its Process | Here you will get all the information regarding tenders (Procurement) like what is tender, what is its process, types of tender, how to search tenders, what to do and what not to do in tendering, how to search tenders and more.... you can check our website for more details which is : http://tenderprocess.weebly.com/
Arbitration Dispute Cross Arguments: Asia NGPipeline -Substance of EPC contra...César del Riego y Fuentes
Case study: ARBITRATION DISPUTE CROSS ARGUMENTS- PROJECTS that EPC CONTRACTS ARE NOT INTENDED TO- case study: Central Asia Natural Gas Pipeline megaproject Claimant/Respondant Argumentation. Study of the Substance of the EPC contract and main features preventing them from being used in certain projects. The huge assumptions of the Contractor (including site ground and unforeseeable events) makes EPC contracts not (supposedly) intended for variations and should be scope closed. Unfortunatelly the usual think is that the Contractors do engage in EPC contracts that will certainly lead to huge liquidated damages and eventIually trigger the bid/performance bonds with no/very limit resource to the contractor. Intensive ground/Underground. Flagship projects not previous experience. Drawings approval by the employer. No/uneffective procedure to Interim Payments upon milestones completion. Foreseeable intensive variations.
CE 444 Contracts and SpecificationsAssignment 7 - Conduct a 95MaximaSheffield592
CE 444 Contracts and Specifications
Assignment 7 - Conduct a 95% Design Review
Due Date: 11:59 pm (Central Time) 23 March
Points: 15
BACKGROUND: You are a newly hired engineer within the Corps of Engineers. As your first assignment, your boss hands you the attached document (95% Design Review 030222) and says, “We want to put this contract out for solicitation in two weeks. Go through it and see if you find any errors or omissions that need correcting. Unless you find something critical, it’ll go out ‘as-is.’ Put any comments you have on the excel spreadsheet. Good luck…”
PROJECT BACKGROUND: Nine road closures have been constructed in the City of East Grand Forks, MN, since 1998. These road closures are installed during severe flooding to prevent floodwaters from inundating the City. However, since installation, a number of the sill plates have become loose; a few have cracks; some sound hollow, and may have voids in the concrete beneath the sill plate. The City wants to ensure the voids beneath the plates are filled in order to ensure optimum performance and reduce maintenance issues. A small contract is about to be advertised to correct these problems. (Pictures are attached for reference.)
PERTINENT INFORMATION: East Grand Forks is located in Polk County, Minnesota, at the confluence of the Red and Red Lake Rivers. This is a real-time assignment – you are reviewing this in March 2022 for immediate advertisement. Flood season generally occurs between late March – late April. Four of the last fourteen years, the Demers Ave, North and South River Road and 4th Street closures have been installed to prevent flooding. All of the other closures have been installed at least once in the last ten years. Current flood predictions from the NWS indicate flooding may be similar to 2009 – in that year, all closures were installed and two of three bridges across the Red River were closed.
ASSIGNMENT DOCUMENTS: The assignment documents include the solicitation document (SF 1442), the Scope of Work, project sketches/designs and referenced specifications. I have removed the Federal Acquisition Register clauses because they add another 100 pages without adding content to the assignment. I have also provided a sample comment spreadsheet. This explanation document includes photos and a map of East Grand Forks, MN.
ASSIGNMENT: Review the Document titled “95% Design Review” and note comments on an excel spreadsheet. I’ve provided an example spreadsheet and an example comment. Conduct a design review and identify issues. Provide a minimum of 15 comments of value. No more than one comment may refer to spelling, grammar or spacing of the contract document.
PICTURES:
Demers Road Closure under assembly
Construction of the extension walls which
tie into the sill plate (note anchor baskets
Demers Ave sill plate in both the extension walls and within the
sill plates.)
C ...
9. GENERAL:
THE PROCURING ENTITY: Executive
Engineer,PWD E/M,Division-V.
TITLE OF WORK: Construction of 4 Storied
Commercial Building.
SINGLE LOT.
OPEN TENDER METHOD.
11. QUALIFICATION CRITERIA:
A satisfactory completion of similar works of at
least Tk. 1 crore 20 lacs under single number of
contract.
Required average annual construction turnover :
Tk. 1 crore over the last 1 year.
Minimum amount of liquid asset : Tk 80 lacs.
12. TENDER PREPERATION:
Additional Documents-
Professional and Technical Qualification
Financial Resources
Equipment and Physical Facilities
Specific Experience
Tender Validity Period 80 days.
Tender Security : Taka 4 lacs.
13. TENDER SUBMISSION:
Deadline : 10 am,12th November,2015
TENDER OPENING:
Address: Office of the Executive Engineer,PWD E/M Division-V,12-
storied Govt. Office Building (11th floor), Segunbagicha, Dhaka.
Time And Date: 10 am,17th November,2015
CONTRACT AWARD:
Performance Security : 10% of Contract
Price.
18. Possession of the
Site
20th December,2015
Starting date
5 January,2016
Intended
Completion
Date
5 November,2017
Programme for
the Works
within 7 days
19. Defects Liability Period 12 months
Proportion of payments be retained
Liquidated Damages 0.07 percent off the
Contract price
Contract value of the works not
completed is 16%
Place for arbitration (Dhaka)
24. Outline of the ‘Bill of Quantities’
Main parts of ‘Bill of Quantities’
I. Item No-100: Earth Work
II. Item No-200. RCC Works
III. Item No-300: Reinforcements
IV. Item No-400: Brick soling, CC, DPC
V. Item No-500: Brickwork, Plastering & Floor finish
VI. Item No-600: Door and Window Materials
26. Features of BOQ
-grouped into sections
-simple and brief
-computed net from the Drawings
-no allowance should be made for bulking,
shrinkage, or waste; quantities should be
rounded up or down
27. Considerations for BOQ
Earth Work:
RCC Work:
Reinforcements:
Brick soling, CC, DPC :
Brickwork, Plastering & Floor finish:
Door and Window Materials:
28. First Class Bricks must be used in both BFS
and 5” Brick Wall
60 Grade( 400MPa) Deformed Bar from any
Renowned Bangladeshi Manufacturer should
be used.
Only Bangladeshi paints can be used for
painting works.
The Mosaic floor finish must consist of Marble
Chips of Indian Origin. Chips from other
countries must not be used. Also, 100% white
cement must be used.
29. Mahogany Wood for Door Frame and
Chapalish wood for Door Shutters must be
used.
Window frames must be made with Aluminum
of S.S. color
Tinted Glass(Greenish) from renowned
manufacturer should be used.
30.
31. General Specifications
- Dismantling & Removal of Existing Structures
- Mobilization and Preparation of Site
-Security
-Disposal and Pollution
-Surveys and Setting Out
-Programme and Progress Reports and Return
-Health and Safety
32.
33.
34.
35.
36. - Quantities should be computed net from the
Drawings
-The actual Drawings, including site plans,
should be attached to this section or annexed in
a separate folder.