This document discusses different methods for analyzing construction delays. It begins with an overview of forensic schedule analysis and definitions. It then examines the main delay analysis methodologies: as-planned vs as-built, impacted as-planned, time impact analysis, and as-built but for. For each methodology, it outlines the approach, strengths, and weaknesses. It emphasizes that the most suitable methodology depends on the specific project factors and available information. It recommends following industry guidance and notes that facts should take precedence over theoretical analyses. The document aims to provide an unbiased overview of delay analysis options to help practitioners choose the right approach.
Construction Delay Analysis, SimplifiedMichael Pink
Learn how to perform a delay analysis in the construction industry. Capture and study your impacts to determine why a project was late. Use this proven method to ensure that you get paid for delays caused by others.
Quantify Construction Damages related to Delay, disruption, and inefficienciesMichael Pink
Learn how to quantify damages related to delay, disruption and inefficiencies on Construction projects. Convert your delays and impacts into cost claims with this proven process.
Favorite Delay Analysis Methodologies Town Hall SEIChris Carson
Presentation from a Town Hall session to discuss favorite forensic schedule analysis methodologies, based on the Forensic Analysis Recommended Practice from AACE International. The Best Practices and Guidelines for Schedule Impact Analysis project is discussing methods.
On 23 May 2012, McLachlan Lister's Anamaria Popescu made a presentation on "Extensions of Time - Avoiding the Traps or Taking Advantage of Them" in conjunction with well-known Australian law firm Holding Redlich
APM webinar hosted by the Greater Bay Area Branch on 21 June 2023.
Speakers: Dennis Wong and Anel Idriz
The Greater Area Bay Branch invited Dennis Wong and Anel Idriz to share their professional project management experience on this Webinar- “Delay Analysis from a technical and legal perspective” on 21 June 2023.
Dennis has a wide experience of various forms of commercial dispute resolution including mediation, arbitration, litigation, and adjudication. In particular, he specialises in resolving complex contractual and construction disputes. Anel's experience is diverse across the construction industry including private residential buildings, leisure, commercial office, large mixed‐use developments, hospitals, education, casinos, heavy civil engineering, highways, and railways.
The webinar targeted to price an Insight into delay analysis and provide a legal update on extension of time/ liquidate damages. The speakers has covered:
Introduction to Planning and Programming
The Role of a Programming and Delay Expert
Understanding Delay Analysis
Accepted Methods of Delay Analysis
Selecting a Method for the Analysis
What Records are important to be maintained for a robust Analysis
Latest cases on the extension of time / liquidated damages
https://youtu.be/l1ChOBpoLwk
https://www.apm.org.uk/news/delay-analysis-from-a-technical-and-legal-perspective-webinar/
Construction Delay Analysis, SimplifiedMichael Pink
Learn how to perform a delay analysis in the construction industry. Capture and study your impacts to determine why a project was late. Use this proven method to ensure that you get paid for delays caused by others.
Quantify Construction Damages related to Delay, disruption, and inefficienciesMichael Pink
Learn how to quantify damages related to delay, disruption and inefficiencies on Construction projects. Convert your delays and impacts into cost claims with this proven process.
Favorite Delay Analysis Methodologies Town Hall SEIChris Carson
Presentation from a Town Hall session to discuss favorite forensic schedule analysis methodologies, based on the Forensic Analysis Recommended Practice from AACE International. The Best Practices and Guidelines for Schedule Impact Analysis project is discussing methods.
On 23 May 2012, McLachlan Lister's Anamaria Popescu made a presentation on "Extensions of Time - Avoiding the Traps or Taking Advantage of Them" in conjunction with well-known Australian law firm Holding Redlich
APM webinar hosted by the Greater Bay Area Branch on 21 June 2023.
Speakers: Dennis Wong and Anel Idriz
The Greater Area Bay Branch invited Dennis Wong and Anel Idriz to share their professional project management experience on this Webinar- “Delay Analysis from a technical and legal perspective” on 21 June 2023.
Dennis has a wide experience of various forms of commercial dispute resolution including mediation, arbitration, litigation, and adjudication. In particular, he specialises in resolving complex contractual and construction disputes. Anel's experience is diverse across the construction industry including private residential buildings, leisure, commercial office, large mixed‐use developments, hospitals, education, casinos, heavy civil engineering, highways, and railways.
The webinar targeted to price an Insight into delay analysis and provide a legal update on extension of time/ liquidate damages. The speakers has covered:
Introduction to Planning and Programming
The Role of a Programming and Delay Expert
Understanding Delay Analysis
Accepted Methods of Delay Analysis
Selecting a Method for the Analysis
What Records are important to be maintained for a robust Analysis
Latest cases on the extension of time / liquidated damages
https://youtu.be/l1ChOBpoLwk
https://www.apm.org.uk/news/delay-analysis-from-a-technical-and-legal-perspective-webinar/
McLachlan Lister provides a range of management consulting and project management services. These are offered either discretely or as an integrated service - you control the depth of our relationship:
Training Slides of Extension of Time (EOT) & Related Costs in Construction, in fullfillment of Delay Claim Expert.
Some Key-Points:
- Contentious Issues in Delay Analysis
- The SLC Protocol
For further information regarding the course, please contact:
info@asia-masters.com
www.asia-masters.com
Project Controls Expo 09 Nov 2011, London - DELAY AND FORENSIC ANALYSIS By Ro...Project Controls Expo
Delay in Construction Contracts: • On-going phenomenon
• Introduction of Critical Path Method (‘CPM’) • Prospective or retrospective analysis
• Observational or modelled
• Dynamic or Static
• Common Methodologies
Construction Contracts Management based on UK common law using more than 40 cases of law with references from the UK, USA regulations, and international rules plus some examples from standard forms of construction contracts such as JCT, NEC & FIDIC.
إدارة القيمة المكتسبة مفيدة ومخادعة في التحكم في المشروعات
فيديو دورة الأساسيات: http://prof.planner.teachable.com/p/evm-basics/
دورة المستوى المتقدم: http://www.slideshare.net/MohamedMaged8/contracts-classification
للمزيد: https://www.facebook.com/groups/prof.cost.engineers/
A case study of Delay Analysis of construction project: Al Kut Olympic Stadiu...Gaurav Verma
These slides present a case study of Delay Analysis in Construction of "AL KUT OLYMPIC STADIUM". After going through these slides you will gotta know the following things:
1. What are construction delays?
2. Types of Construction Delays.
3. Effects of Construction Delays.
4. Location of "Al Kut Olympic Stadium".
5. Scope of study.
6. Objectives of study.
7. Research Methodology.
8. Result Analysis.
In the present day corporate environment, where there is cut-throat competition, the need for efficient time management and timely completion of projects is essential for organizations to stay competitive. Even due to the growing need for time management in construction projects, many are failing to be finished on time. This can be detrimental for any hiring company since infrastructure development project delays can lead to increase in costs and process halt for organizations. These are real life scenarios which are bound to take place in the professional life of any and every project manager. A project manager will only be considered efficient and competent when he or she knows how to manage the allotted time, and to carry out operations and activities in a manner that further reduces this time period. In order to prepare project managers for such circumstances, it is crucial for them to understand Extension of Time and delay analysis.
Course link: https://planningengineer.net/courses/claims-management-and-delays-analysis-online-workshop/
Welcome to WIPAC Monthly the magazine brought to you by the LinkedIn Group Water Industry Process Automation & Control.
In this month's edition, along with this month's industry news to celebrate the 13 years since the group was created we have articles including
A case study of the used of Advanced Process Control at the Wastewater Treatment works at Lleida in Spain
A look back on an article on smart wastewater networks in order to see how the industry has measured up in the interim around the adoption of Digital Transformation in the Water Industry.
Democratizing Fuzzing at Scale by Abhishek Aryaabh.arya
Presented at NUS: Fuzzing and Software Security Summer School 2024
This keynote talks about the democratization of fuzzing at scale, highlighting the collaboration between open source communities, academia, and industry to advance the field of fuzzing. It delves into the history of fuzzing, the development of scalable fuzzing platforms, and the empowerment of community-driven research. The talk will further discuss recent advancements leveraging AI/ML and offer insights into the future evolution of the fuzzing landscape.
McLachlan Lister provides a range of management consulting and project management services. These are offered either discretely or as an integrated service - you control the depth of our relationship:
Training Slides of Extension of Time (EOT) & Related Costs in Construction, in fullfillment of Delay Claim Expert.
Some Key-Points:
- Contentious Issues in Delay Analysis
- The SLC Protocol
For further information regarding the course, please contact:
info@asia-masters.com
www.asia-masters.com
Project Controls Expo 09 Nov 2011, London - DELAY AND FORENSIC ANALYSIS By Ro...Project Controls Expo
Delay in Construction Contracts: • On-going phenomenon
• Introduction of Critical Path Method (‘CPM’) • Prospective or retrospective analysis
• Observational or modelled
• Dynamic or Static
• Common Methodologies
Construction Contracts Management based on UK common law using more than 40 cases of law with references from the UK, USA regulations, and international rules plus some examples from standard forms of construction contracts such as JCT, NEC & FIDIC.
إدارة القيمة المكتسبة مفيدة ومخادعة في التحكم في المشروعات
فيديو دورة الأساسيات: http://prof.planner.teachable.com/p/evm-basics/
دورة المستوى المتقدم: http://www.slideshare.net/MohamedMaged8/contracts-classification
للمزيد: https://www.facebook.com/groups/prof.cost.engineers/
A case study of Delay Analysis of construction project: Al Kut Olympic Stadiu...Gaurav Verma
These slides present a case study of Delay Analysis in Construction of "AL KUT OLYMPIC STADIUM". After going through these slides you will gotta know the following things:
1. What are construction delays?
2. Types of Construction Delays.
3. Effects of Construction Delays.
4. Location of "Al Kut Olympic Stadium".
5. Scope of study.
6. Objectives of study.
7. Research Methodology.
8. Result Analysis.
In the present day corporate environment, where there is cut-throat competition, the need for efficient time management and timely completion of projects is essential for organizations to stay competitive. Even due to the growing need for time management in construction projects, many are failing to be finished on time. This can be detrimental for any hiring company since infrastructure development project delays can lead to increase in costs and process halt for organizations. These are real life scenarios which are bound to take place in the professional life of any and every project manager. A project manager will only be considered efficient and competent when he or she knows how to manage the allotted time, and to carry out operations and activities in a manner that further reduces this time period. In order to prepare project managers for such circumstances, it is crucial for them to understand Extension of Time and delay analysis.
Course link: https://planningengineer.net/courses/claims-management-and-delays-analysis-online-workshop/
Welcome to WIPAC Monthly the magazine brought to you by the LinkedIn Group Water Industry Process Automation & Control.
In this month's edition, along with this month's industry news to celebrate the 13 years since the group was created we have articles including
A case study of the used of Advanced Process Control at the Wastewater Treatment works at Lleida in Spain
A look back on an article on smart wastewater networks in order to see how the industry has measured up in the interim around the adoption of Digital Transformation in the Water Industry.
Democratizing Fuzzing at Scale by Abhishek Aryaabh.arya
Presented at NUS: Fuzzing and Software Security Summer School 2024
This keynote talks about the democratization of fuzzing at scale, highlighting the collaboration between open source communities, academia, and industry to advance the field of fuzzing. It delves into the history of fuzzing, the development of scalable fuzzing platforms, and the empowerment of community-driven research. The talk will further discuss recent advancements leveraging AI/ML and offer insights into the future evolution of the fuzzing landscape.
Cosmetic shop management system project report.pdfKamal Acharya
Buying new cosmetic products is difficult. It can even be scary for those who have sensitive skin and are prone to skin trouble. The information needed to alleviate this problem is on the back of each product, but it's thought to interpret those ingredient lists unless you have a background in chemistry.
Instead of buying and hoping for the best, we can use data science to help us predict which products may be good fits for us. It includes various function programs to do the above mentioned tasks.
Data file handling has been effectively used in the program.
The automated cosmetic shop management system should deal with the automation of general workflow and administration process of the shop. The main processes of the system focus on customer's request where the system is able to search the most appropriate products and deliver it to the customers. It should help the employees to quickly identify the list of cosmetic product that have reached the minimum quantity and also keep a track of expired date for each cosmetic product. It should help the employees to find the rack number in which the product is placed.It is also Faster and more efficient way.
Explore the innovative world of trenchless pipe repair with our comprehensive guide, "The Benefits and Techniques of Trenchless Pipe Repair." This document delves into the modern methods of repairing underground pipes without the need for extensive excavation, highlighting the numerous advantages and the latest techniques used in the industry.
Learn about the cost savings, reduced environmental impact, and minimal disruption associated with trenchless technology. Discover detailed explanations of popular techniques such as pipe bursting, cured-in-place pipe (CIPP) lining, and directional drilling. Understand how these methods can be applied to various types of infrastructure, from residential plumbing to large-scale municipal systems.
Ideal for homeowners, contractors, engineers, and anyone interested in modern plumbing solutions, this guide provides valuable insights into why trenchless pipe repair is becoming the preferred choice for pipe rehabilitation. Stay informed about the latest advancements and best practices in the field.
Saudi Arabia stands as a titan in the global energy landscape, renowned for its abundant oil and gas resources. It's the largest exporter of petroleum and holds some of the world's most significant reserves. Let's delve into the top 10 oil and gas projects shaping Saudi Arabia's energy future in 2024.
COLLEGE BUS MANAGEMENT SYSTEM PROJECT REPORT.pdfKamal Acharya
The College Bus Management system is completely developed by Visual Basic .NET Version. The application is connect with most secured database language MS SQL Server. The application is develop by using best combination of front-end and back-end languages. The application is totally design like flat user interface. This flat user interface is more attractive user interface in 2017. The application is gives more important to the system functionality. The application is to manage the student’s details, driver’s details, bus details, bus route details, bus fees details and more. The application has only one unit for admin. The admin can manage the entire application. The admin can login into the application by using username and password of the admin. The application is develop for big and small colleges. It is more user friendly for non-computer person. Even they can easily learn how to manage the application within hours. The application is more secure by the admin. The system will give an effective output for the VB.Net and SQL Server given as input to the system. The compiled java program given as input to the system, after scanning the program will generate different reports. The application generates the report for users. The admin can view and download the report of the data. The application deliver the excel format reports. Because, excel formatted reports is very easy to understand the income and expense of the college bus. This application is mainly develop for windows operating system users. In 2017, 73% of people enterprises are using windows operating system. So the application will easily install for all the windows operating system users. The application-developed size is very low. The application consumes very low space in disk. Therefore, the user can allocate very minimum local disk space for this application.
NO1 Uk best vashikaran specialist in delhi vashikaran baba near me online vas...Amil Baba Dawood bangali
Contact with Dawood Bhai Just call on +92322-6382012 and we'll help you. We'll solve all your problems within 12 to 24 hours and with 101% guarantee and with astrology systematic. If you want to take any personal or professional advice then also you can call us on +92322-6382012 , ONLINE LOVE PROBLEM & Other all types of Daily Life Problem's.Then CALL or WHATSAPP us on +92322-6382012 and Get all these problems solutions here by Amil Baba DAWOOD BANGALI
#vashikaranspecialist #astrologer #palmistry #amliyaat #taweez #manpasandshadi #horoscope #spiritual #lovelife #lovespell #marriagespell#aamilbabainpakistan #amilbabainkarachi #powerfullblackmagicspell #kalajadumantarspecialist #realamilbaba #AmilbabainPakistan #astrologerincanada #astrologerindubai #lovespellsmaster #kalajaduspecialist #lovespellsthatwork #aamilbabainlahore#blackmagicformarriage #aamilbaba #kalajadu #kalailam #taweez #wazifaexpert #jadumantar #vashikaranspecialist #astrologer #palmistry #amliyaat #taweez #manpasandshadi #horoscope #spiritual #lovelife #lovespell #marriagespell#aamilbabainpakistan #amilbabainkarachi #powerfullblackmagicspell #kalajadumantarspecialist #realamilbaba #AmilbabainPakistan #astrologerincanada #astrologerindubai #lovespellsmaster #kalajaduspecialist #lovespellsthatwork #aamilbabainlahore #blackmagicforlove #blackmagicformarriage #aamilbaba #kalajadu #kalailam #taweez #wazifaexpert #jadumantar #vashikaranspecialist #astrologer #palmistry #amliyaat #taweez #manpasandshadi #horoscope #spiritual #lovelife #lovespell #marriagespell#aamilbabainpakistan #amilbabainkarachi #powerfullblackmagicspell #kalajadumantarspecialist #realamilbaba #AmilbabainPakistan #astrologerincanada #astrologerindubai #lovespellsmaster #kalajaduspecialist #lovespellsthatwork #aamilbabainlahore #Amilbabainuk #amilbabainspain #amilbabaindubai #Amilbabainnorway #amilbabainkrachi #amilbabainlahore #amilbabaingujranwalan #amilbabainislamabad
Quality defects in TMT Bars, Possible causes and Potential Solutions.PrashantGoswami42
Maintaining high-quality standards in the production of TMT bars is crucial for ensuring structural integrity in construction. Addressing common defects through careful monitoring, standardized processes, and advanced technology can significantly improve the quality of TMT bars. Continuous training and adherence to quality control measures will also play a pivotal role in minimizing these defects.
Final project report on grocery store management system..pdfKamal Acharya
In today’s fast-changing business environment, it’s extremely important to be able to respond to client needs in the most effective and timely manner. If your customers wish to see your business online and have instant access to your products or services.
Online Grocery Store is an e-commerce website, which retails various grocery products. This project allows viewing various products available enables registered users to purchase desired products instantly using Paytm, UPI payment processor (Instant Pay) and also can place order by using Cash on Delivery (Pay Later) option. This project provides an easy access to Administrators and Managers to view orders placed using Pay Later and Instant Pay options.
In order to develop an e-commerce website, a number of Technologies must be studied and understood. These include multi-tiered architecture, server and client-side scripting techniques, implementation technologies, programming language (such as PHP, HTML, CSS, JavaScript) and MySQL relational databases. This is a project with the objective to develop a basic website where a consumer is provided with a shopping cart website and also to know about the technologies used to develop such a website.
This document will discuss each of the underlying technologies to create and implement an e- commerce website.
4. • FORENSIC SCHEDULE ANALYSIS
• “… refers to the study and investigation of events using CPM or other
recognized schedule calculation methods for potential use in a legal
proceeding.”
• “… the study of how actual events interacted in the context of a
complex model for the purpose of understanding the significance of a
specific deviation or series of deviations from some baseline model and
their role in determining the sequence of tasks within the complex
network.”
(cited: AACE® International Recommended Practice No. 29R‐03 FORENSIC SCHEDULE ANALYSIS TCM Framework)
OVERVIEW – DEFINITION
4
6. APPROACH – DELAY ANALYSIS METHODOLOGIES
6
TWO
Types
FOUR
Categories*
TWO
Types
FOUR
Categories*
* See for example the Society of Construction Law “Protocol on Delay and Disruption”, or Association for the Advancement of Cost Engineering Recommended Practice No.29R-03
“Forensic Schedule Analysis”
• As‐planned versus As‐built
• As‐Built But For
LOOKING BACKLOOKING BACK
Retrospective Analyses
LOOKING FORWARDLOOKING FORWARD
Prospective Analyses
• Time‐Impact Analysis
• Impacted As‐planned
7. • is the most basic method of analysis
• is observational – no changes are made to the programme
• straightforward comparison between the planned vs the actual
performance of the work
• can only be carried out retrospectively (requires as‐built programme/or at
least the overall as‐built completion date)
7
Strengths Weakness
• is very simple and therefore
easy to understand
• can be performed with
rudimentary base data (e.g.
when detail and logic of the as‐
planned programme is unavailable,
and no detailed progress records
other than the overall as‐built
programme are available)
• Static critical path
• fails to fulfil the fundamental
requirement to demonstrate the
causal link between a delay event and
its alleged effect
• does not deal adequately with
concurrent delay
APPROACH – AS‐PLANNED VS AS‐BUILT (APAB)
9. APPROACH – IMPACTED AS‐PLANNED (IAP)
9
• is a prospective methodology
• delay effect is measured by imposing events on a model of the original
programme (Baseline)
• does not rely on any actual progress that has been made
• requires a robust and reliable original programme that reflects the
indented sequence and the Scope of Work
Strengths Weakness
• relatively simple to carry out and
to understand
• No as‐built required (likely choice
when planned programme is available,
no significant changes in the sequence
during the project execution, few
delaying events, and when there is
little or no progress records)
• cannot be used for complex projects
• used to quantify potential delays rather
and actual
• concurrent delays easily overlooked
• assumes that the baseline was
achievable
• does not take actual progress/ resources
into account
• not reliable in dispute resolution
11. APPROACH – TIME IMPACT ANALYSIS (TIA)
11
• prospective and dynamic method – but can be applied retrospectively
• takes account of progress and timing of delay events on the Works
• requires reliable as‐built data to update the programme (hence, if detailed and
regular progress data is not available then this method cannot be used)
• a reliable baseline programme is essential (ideally reflects the execution of the
planned project using sound construction logic)
• often undertaken in time slices (windows)
Strengths Weakness
• has a proven track‐record in
forensic application
• preferred method of the SCL
Protocol
• based on a dynamic and changing
critical path
• demonstrates cause and effect
• time consuming (to determine the factual
background and correct logic associated
with progress records and delay events)
• requires considerable degree of
expertise and technical knowledge
• hence, difficult to communicate, highly
complex
13. APPROACH – AS‐BUILT BUT FOR (ABBF)
13
• retrospective method also known as Collapsed As‐built (CAB)
• relies on a detailed reconstruction of the as‐built programme
• normally restricted to after‐the‐event analyses in forensic work
• does have a limited prospective capability (can be used to demonstrate the effect
of a delay on the completed part of an incomplete project)
• has been proven to be reliable in dispute resolution/ claims
• If done properly can demonstrates effect and cause/ takes account of
concurrence
Strengths Weakness
• greatest strength for forensic work
is that it is fact based (based on as‐
build)
• not reliant upon an as‐planned
programme
• complicated method hence, difficult to
execute and to explain
• difficult to establish a dynamic as‐built
schedule (as complicated to determine and
model logic)
• requires detailed as‐build/ progress
records
25. QUESTIONS
Katrin Enders
Associate Director
Hill International (UK) Ltd
11 Pilgrim Street,
London EC4V 6RN
Office: +44 (0)207 618 1200/ 1262
Mobile: +44 (0)7850722796
www.hillintl.com
25
QUESTIONS PLEASE ?
26. 4900 Employees worldwide
100 Offices in 40 countries
Construction Claims & Consulting Group
Project Management Group
NYSE Global Market
Founded in 1976
Employers/Contractors
Hill International (D) GmbH
Prinzregentenstraße 20‐22
80538 München
Munich@hillintl.com
Düsseldorf, Germany
Graf‐ Adolf‐ Platz 15
40213 Düsseldorf
Duesseldorf@hillintl.com
Hamburg, Germany
Am Kaiserkai 1
20457 Hamburg
Hill International UK
London, Hill International UK, Ltd.
11 Pilgrim St
London,
EC4V 6RN
UK
Tel: +44 (0)20 7618 1200
(9 UK Locations)
SERVICES