1. The document discusses Project Bank Accounts (PBAs), which are bank accounts set up to ensure timely payment to contractors and subcontractors on construction projects.
2. The Welsh Government has implemented a policy requiring PBAs for capital projects over £2 million to address issues like contractors waiting over 100 days to be paid.
3. A cost-benefit analysis found that the benefits of PBAs, like improved cash flow, outweigh the costs for all parties involved in construction projects.
This was a presentation delivered by Dr Jon Broome, chair of the APM Contracts and Procurements specific interest group (SIG), on Tuesday 7th October. The event was organised and hosted by the APM North East branch and was entitled 'Project contracts and how they support collaborative working'. It was held at the Radisson Blu hotel in Durham.
Project Controls Expo, 18th Nov 2014 - "NEC3 Contracts – Managing Risk and Ch...Project Controls Expo
Traditionally many Contractors (and even Employers) see following the contract or being contractual as a very negative. The NEC3 suite of contracts command a different approach and this session will explore the benefits of being contractual, and how it will help both Parties to manage their project and understand exactly where they both are in terms of liability throughout their project. A key aspect of this is approach to the management of regular revised programmes, which compared to other forms of contract have a much higher contractual significance under NEC3.
This was a presentation delivered by Dr Jon Broome, chair of the APM Contracts and Procurements specific interest group (SIG), on Tuesday 7th October. The event was organised and hosted by the APM North East branch and was entitled 'Project contracts and how they support collaborative working'. It was held at the Radisson Blu hotel in Durham.
Project Controls Expo, 18th Nov 2014 - "NEC3 Contracts – Managing Risk and Ch...Project Controls Expo
Traditionally many Contractors (and even Employers) see following the contract or being contractual as a very negative. The NEC3 suite of contracts command a different approach and this session will explore the benefits of being contractual, and how it will help both Parties to manage their project and understand exactly where they both are in terms of liability throughout their project. A key aspect of this is approach to the management of regular revised programmes, which compared to other forms of contract have a much higher contractual significance under NEC3.
APM webinar sponsored by the Thames Valley Branch on 12 August 2021.
The basics of risk allocation within the NEC contracts and the NEC's simple and effective methods for 'early warning'. This is one process in NEC that you need to get working well on your contract. The session gives the basics and some tips for making it work. This session was held on 12 August 2021.
Speaker:
Richard Patterson, NEC4 drafter and Procurement & NEC Specialist at Mott MacDonald
https://youtu.be/OG0dZCrprz0
https://www.apm.org.uk/news/nec-contracts-the-risk-registerearly-warning-register-and-risk-allocation-and-management-webinar/
Contractor’s ability to mitigate damages can be limited if coupled with uncertainty of the duration of the delay. HOOH is recoverable in certain prolonged delay situations and has been granted by courts and amicable settlements for more than half a century. The Contractor may recover the return that he would have achieved on other work had his resources not been detained on the Works due to the delay. The presentation highlights the different formulae used in the calculations and conditions precedent to do so.
an introduction to FIDIC contracts and the other available international modules. Provides and overview of history of FIDIC contracts, documents under FIDIC, types of contract clauses, and contract structure.
Contract Management Best Practices: Tips to Maximize ReimbursementPMMC
Effective contract management systems are critical to maximizing financial performance, minimizing risk, and managing all aspects of payer contracts to get reimbursed accurately.
However, the success of a contract management system is only as strong as your processes. As changes constantly occur – such as government reimbursement methodologies – it’s important to stay ahead of the curve and ensure that your contract management system supports these changes.
In this educational presentation, Kristen Wood, Senior Account Manager - Contract Management at PMMC shares the most pressing issues today related to contract management and how your facility can maximize the use of its contract management vendor.
This presentation covers:
• The impact of registration errors
• Common billing errors (missing modifiers, late charges, etc.)
• Denial monitoring and what to look for
• Upcoming government reimbursement changes (Sequestration, ICD-10, APR-DRG for stat Medicaids) and what to expect
• Managing your A/R days and the importance of reporting
• Payer tactics and how to address them (underpayment trends, silent PPOs, LOS issues)
• False variances and how to conquer calculation challenges
•What is Contract?
•What is Construction Contract?
•Purpose of Construction Contract
•Contract for Bid and Procurement
•Contract for Pricing Arrangement
•Construction Contract Component
•Contract Document List
•Standard Form of Contract in Malaysia
Innovation Loans Competition Briefing: April 2021KTN
Find out more about Innovate UK's Innovation Loans for SME businesses looking to scale and grow. KTN is hosting an applicant briefing webinar on Thursday 20th May.
APM webinar sponsored by the Thames Valley Branch on 12 August 2021.
The basics of risk allocation within the NEC contracts and the NEC's simple and effective methods for 'early warning'. This is one process in NEC that you need to get working well on your contract. The session gives the basics and some tips for making it work. This session was held on 12 August 2021.
Speaker:
Richard Patterson, NEC4 drafter and Procurement & NEC Specialist at Mott MacDonald
https://youtu.be/OG0dZCrprz0
https://www.apm.org.uk/news/nec-contracts-the-risk-registerearly-warning-register-and-risk-allocation-and-management-webinar/
Contractor’s ability to mitigate damages can be limited if coupled with uncertainty of the duration of the delay. HOOH is recoverable in certain prolonged delay situations and has been granted by courts and amicable settlements for more than half a century. The Contractor may recover the return that he would have achieved on other work had his resources not been detained on the Works due to the delay. The presentation highlights the different formulae used in the calculations and conditions precedent to do so.
an introduction to FIDIC contracts and the other available international modules. Provides and overview of history of FIDIC contracts, documents under FIDIC, types of contract clauses, and contract structure.
Contract Management Best Practices: Tips to Maximize ReimbursementPMMC
Effective contract management systems are critical to maximizing financial performance, minimizing risk, and managing all aspects of payer contracts to get reimbursed accurately.
However, the success of a contract management system is only as strong as your processes. As changes constantly occur – such as government reimbursement methodologies – it’s important to stay ahead of the curve and ensure that your contract management system supports these changes.
In this educational presentation, Kristen Wood, Senior Account Manager - Contract Management at PMMC shares the most pressing issues today related to contract management and how your facility can maximize the use of its contract management vendor.
This presentation covers:
• The impact of registration errors
• Common billing errors (missing modifiers, late charges, etc.)
• Denial monitoring and what to look for
• Upcoming government reimbursement changes (Sequestration, ICD-10, APR-DRG for stat Medicaids) and what to expect
• Managing your A/R days and the importance of reporting
• Payer tactics and how to address them (underpayment trends, silent PPOs, LOS issues)
• False variances and how to conquer calculation challenges
•What is Contract?
•What is Construction Contract?
•Purpose of Construction Contract
•Contract for Bid and Procurement
•Contract for Pricing Arrangement
•Construction Contract Component
•Contract Document List
•Standard Form of Contract in Malaysia
Innovation Loans Competition Briefing: April 2021KTN
Find out more about Innovate UK's Innovation Loans for SME businesses looking to scale and grow. KTN is hosting an applicant briefing webinar on Thursday 20th May.
What has the UK Asset Management Industry learned over past 25 years?seamsltd
We reflect on the past 10 years of regulated asset investment planning in the UK from 3 key sectors, Water, Road and Rail. Each highlights a different path taken with positives and negative results. At one end is UK regulated water industry which was one of the earliest, and still may be the largest, user of a strong regulated asset management framework with strong links from prices through to levels of service.We consider how the latest focus on Totex / Output Delivery Incentives will work. More recently the UK government has change its approach to asset management governance on the strategic roads network, an asset base valued as one of the top ten largest in the world. By introduction of a roads regulator and setting a new government owned company does this signal the intention to fully privatise the roads network and could this be a model adopted elsewhere?
The report aims at stimulating thoughts and discussions on Supply Chain Finance topic and it doesn’t intent to give a professional advise to your company, taking into account that each Business has specific requirements and goals.
On the 14th March 2014 the House of Commons committee on public accounts report "Contracting out public services to the private sector" was published, and makes uncomfortable reading for those involved as suppliers or procurers. It might be tempting to say this is the reality of the difficulties of delivering public services, and it might instead be the case that procuring services through contracts performs with great variability across all sectors commercial and public.
A conference was hosted by the APM Value Management SIG that looked at those issues in the face, entertained the notion that the solution is in the hands of project teams, from either side, client or supplier/contractor, and sought to prove that case, with both theory and evidence!
The event included the following speakers:
John Heathcote, APM Value Management SIG Chair
Alan Munro (keynote speaker)
Paul Riley, Head of Capital Projects, Leeds Metropolitan University Estates & Contractor partners BAM
John Phillips, BAM Director
Professor Farzad Khosrowshahi, Head of the School of the Built Environment & Engineering
Project Storyboard: Reducing Cycle Time for Bid Tab Creationby 33%GoLeanSixSigma.com
Think it's impossible to make a significant change in government? Well, it's not easy, but GoLeanSixSigmna.com Black Belt Pamela Kuehling made a real difference from the inside. She overturned countless "honest wrong beliefs" with facts and data by modeling the Lean Six Sigma approach in her work and won over the doubters.
Initially the overall procurement process was the focus, but when that proved to be too big, she scoped it down to a more manageable project that can now be the basis for an expanded improvement. Her improvement was meaningful, but a bigger victory was in bringing critical and logical thinking into an environment often impacted by less scientific influences!
Budget management and transformation - Zi Hao Wong & Yan Chun Lim, SingaporeOECD Governance
This presentation was made by Zi Hao Wong & Yan Chun Lim, Singapore, at the 14th OECD-Asian Senior Budget Officials Meeting held in Bangkok, Thailand, on 13-14 December 2018
Similar to Construction Futures Wales - Project Bank Accounts (20)
Construction Futures Wales & Wales Nuclear Forum - React to Nuclear EventRae Davies
Introduction into the Wales Nuclear Forum and the opportunities within the Welsh Nuclear Energy sector. Overview of current projects and support available
Tata Group Dials Taiwan for Its Chipmaking Ambition in Gujarat’s DholeraAvirahi City Dholera
The Tata Group, a titan of Indian industry, is making waves with its advanced talks with Taiwanese chipmakers Powerchip Semiconductor Manufacturing Corporation (PSMC) and UMC Group. The goal? Establishing a cutting-edge semiconductor fabrication unit (fab) in Dholera, Gujarat. This isn’t just any project; it’s a potential game changer for India’s chipmaking aspirations and a boon for investors seeking promising residential projects in dholera sir.
Visit : https://www.avirahi.com/blog/tata-group-dials-taiwan-for-its-chipmaking-ambition-in-gujarats-dholera/
RMD24 | Debunking the non-endemic revenue myth Marvin Vacquier Droop | First ...BBPMedia1
Marvin neemt je in deze presentatie mee in de voordelen van non-endemic advertising op retail media netwerken. Hij brengt ook de uitdagingen in beeld die de markt op dit moment heeft op het gebied van retail media voor niet-leveranciers.
Retail media wordt gezien als het nieuwe advertising-medium en ook mediabureaus richten massaal retail media-afdelingen op. Merken die niet in de betreffende winkel liggen staan ook nog niet in de rij om op de retail media netwerken te adverteren. Marvin belicht de uitdagingen die er zijn om echt aansluiting te vinden op die markt van non-endemic advertising.
"𝑩𝑬𝑮𝑼𝑵 𝑾𝑰𝑻𝑯 𝑻𝑱 𝑰𝑺 𝑯𝑨𝑳𝑭 𝑫𝑶𝑵𝑬"
𝐓𝐉 𝐂𝐨𝐦𝐬 (𝐓𝐉 𝐂𝐨𝐦𝐦𝐮𝐧𝐢𝐜𝐚𝐭𝐢𝐨𝐧𝐬) is a professional event agency that includes experts in the event-organizing market in Vietnam, Korea, and ASEAN countries. We provide unlimited types of events from Music concerts, Fan meetings, and Culture festivals to Corporate events, Internal company events, Golf tournaments, MICE events, and Exhibitions.
𝐓𝐉 𝐂𝐨𝐦𝐬 provides unlimited package services including such as Event organizing, Event planning, Event production, Manpower, PR marketing, Design 2D/3D, VIP protocols, Interpreter agency, etc.
Sports events - Golf competitions/billiards competitions/company sports events: dynamic and challenging
⭐ 𝐅𝐞𝐚𝐭𝐮𝐫𝐞𝐝 𝐩𝐫𝐨𝐣𝐞𝐜𝐭𝐬:
➢ 2024 BAEKHYUN [Lonsdaleite] IN HO CHI MINH
➢ SUPER JUNIOR-L.S.S. THE SHOW : Th3ee Guys in HO CHI MINH
➢FreenBecky 1st Fan Meeting in Vietnam
➢CHILDREN ART EXHIBITION 2024: BEYOND BARRIERS
➢ WOW K-Music Festival 2023
➢ Winner [CROSS] Tour in HCM
➢ Super Show 9 in HCM with Super Junior
➢ HCMC - Gyeongsangbuk-do Culture and Tourism Festival
➢ Korean Vietnam Partnership - Fair with LG
➢ Korean President visits Samsung Electronics R&D Center
➢ Vietnam Food Expo with Lotte Wellfood
"𝐄𝐯𝐞𝐫𝐲 𝐞𝐯𝐞𝐧𝐭 𝐢𝐬 𝐚 𝐬𝐭𝐨𝐫𝐲, 𝐚 𝐬𝐩𝐞𝐜𝐢𝐚𝐥 𝐣𝐨𝐮𝐫𝐧𝐞𝐲. 𝐖𝐞 𝐚𝐥𝐰𝐚𝐲𝐬 𝐛𝐞𝐥𝐢𝐞𝐯𝐞 𝐭𝐡𝐚𝐭 𝐬𝐡𝐨𝐫𝐭𝐥𝐲 𝐲𝐨𝐮 𝐰𝐢𝐥𝐥 𝐛𝐞 𝐚 𝐩𝐚𝐫𝐭 𝐨𝐟 𝐨𝐮𝐫 𝐬𝐭𝐨𝐫𝐢𝐞𝐬."
Memorandum Of Association Constitution of Company.pptseri bangash
www.seribangash.com
A Memorandum of Association (MOA) is a legal document that outlines the fundamental principles and objectives upon which a company operates. It serves as the company's charter or constitution and defines the scope of its activities. Here's a detailed note on the MOA:
Contents of Memorandum of Association:
Name Clause: This clause states the name of the company, which should end with words like "Limited" or "Ltd." for a public limited company and "Private Limited" or "Pvt. Ltd." for a private limited company.
https://seribangash.com/article-of-association-is-legal-doc-of-company/
Registered Office Clause: It specifies the location where the company's registered office is situated. This office is where all official communications and notices are sent.
Objective Clause: This clause delineates the main objectives for which the company is formed. It's important to define these objectives clearly, as the company cannot undertake activities beyond those mentioned in this clause.
www.seribangash.com
Liability Clause: It outlines the extent of liability of the company's members. In the case of companies limited by shares, the liability of members is limited to the amount unpaid on their shares. For companies limited by guarantee, members' liability is limited to the amount they undertake to contribute if the company is wound up.
https://seribangash.com/promotors-is-person-conceived-formation-company/
Capital Clause: This clause specifies the authorized capital of the company, i.e., the maximum amount of share capital the company is authorized to issue. It also mentions the division of this capital into shares and their respective nominal value.
Association Clause: It simply states that the subscribers wish to form a company and agree to become members of it, in accordance with the terms of the MOA.
Importance of Memorandum of Association:
Legal Requirement: The MOA is a legal requirement for the formation of a company. It must be filed with the Registrar of Companies during the incorporation process.
Constitutional Document: It serves as the company's constitutional document, defining its scope, powers, and limitations.
Protection of Members: It protects the interests of the company's members by clearly defining the objectives and limiting their liability.
External Communication: It provides clarity to external parties, such as investors, creditors, and regulatory authorities, regarding the company's objectives and powers.
https://seribangash.com/difference-public-and-private-company-law/
Binding Authority: The company and its members are bound by the provisions of the MOA. Any action taken beyond its scope may be considered ultra vires (beyond the powers) of the company and therefore void.
Amendment of MOA:
While the MOA lays down the company's fundamental principles, it is not entirely immutable. It can be amended, but only under specific circumstances and in compliance with legal procedures. Amendments typically require shareholder
Affordable Stationery Printing Services in Jaipur | Navpack n PrintNavpack & Print
Looking for professional printing services in Jaipur? Navpack n Print offers high-quality and affordable stationery printing for all your business needs. Stand out with custom stationery designs and fast turnaround times. Contact us today for a quote!
Digital Transformation and IT Strategy Toolkit and TemplatesAurelien Domont, MBA
This Digital Transformation and IT Strategy Toolkit was created by ex-McKinsey, Deloitte and BCG Management Consultants, after more than 5,000 hours of work. It is considered the world's best & most comprehensive Digital Transformation and IT Strategy Toolkit. It includes all the Frameworks, Best Practices & Templates required to successfully undertake the Digital Transformation of your organization and define a robust IT Strategy.
Editable Toolkit to help you reuse our content: 700 Powerpoint slides | 35 Excel sheets | 84 minutes of Video training
This PowerPoint presentation is only a small preview of our Toolkits. For more details, visit www.domontconsulting.com
What are the main advantages of using HR recruiter services.pdfHumanResourceDimensi1
HR recruiter services offer top talents to companies according to their specific needs. They handle all recruitment tasks from job posting to onboarding and help companies concentrate on their business growth. With their expertise and years of experience, they streamline the hiring process and save time and resources for the company.
3.0 Project 2_ Developing My Brand Identity Kit.pptxtanyjahb
A personal brand exploration presentation summarizes an individual's unique qualities and goals, covering strengths, values, passions, and target audience. It helps individuals understand what makes them stand out, their desired image, and how they aim to achieve it.
Kseniya Leshchenko: Shared development support service model as the way to ma...Lviv Startup Club
Kseniya Leshchenko: Shared development support service model as the way to make small projects with small budgets profitable for the company (UA)
Kyiv PMDay 2024 Summer
Website – www.pmday.org
Youtube – https://www.youtube.com/startuplviv
FB – https://www.facebook.com/pmdayconference
Cracking the Workplace Discipline Code Main.pptxWorkforce Group
Cultivating and maintaining discipline within teams is a critical differentiator for successful organisations.
Forward-thinking leaders and business managers understand the impact that discipline has on organisational success. A disciplined workforce operates with clarity, focus, and a shared understanding of expectations, ultimately driving better results, optimising productivity, and facilitating seamless collaboration.
Although discipline is not a one-size-fits-all approach, it can help create a work environment that encourages personal growth and accountability rather than solely relying on punitive measures.
In this deck, you will learn the significance of workplace discipline for organisational success. You’ll also learn
• Four (4) workplace discipline methods you should consider
• The best and most practical approach to implementing workplace discipline.
• Three (3) key tips to maintain a disciplined workplace.
[Note: This is a partial preview. To download this presentation, visit:
https://www.oeconsulting.com.sg/training-presentations]
Sustainability has become an increasingly critical topic as the world recognizes the need to protect our planet and its resources for future generations. Sustainability means meeting our current needs without compromising the ability of future generations to meet theirs. It involves long-term planning and consideration of the consequences of our actions. The goal is to create strategies that ensure the long-term viability of People, Planet, and Profit.
Leading companies such as Nike, Toyota, and Siemens are prioritizing sustainable innovation in their business models, setting an example for others to follow. In this Sustainability training presentation, you will learn key concepts, principles, and practices of sustainability applicable across industries. This training aims to create awareness and educate employees, senior executives, consultants, and other key stakeholders, including investors, policymakers, and supply chain partners, on the importance and implementation of sustainability.
LEARNING OBJECTIVES
1. Develop a comprehensive understanding of the fundamental principles and concepts that form the foundation of sustainability within corporate environments.
2. Explore the sustainability implementation model, focusing on effective measures and reporting strategies to track and communicate sustainability efforts.
3. Identify and define best practices and critical success factors essential for achieving sustainability goals within organizations.
CONTENTS
1. Introduction and Key Concepts of Sustainability
2. Principles and Practices of Sustainability
3. Measures and Reporting in Sustainability
4. Sustainability Implementation & Best Practices
To download the complete presentation, visit: https://www.oeconsulting.com.sg/training-presentations
Personal Brand Statement:
As an Army veteran dedicated to lifelong learning, I bring a disciplined, strategic mindset to my pursuits. I am constantly expanding my knowledge to innovate and lead effectively. My journey is driven by a commitment to excellence, and to make a meaningful impact in the world.
4. Applying Project Bank Accounts (PBA) Policy
in the 21st Century Schools Programme
Brendan Burke
Value Wales – Procurement Policy
Welsh Government
21st Century Schools programme
12th November 2018, Bodelwyddan
19th November 2018, Llanelli
26th November 2018, Cardiff
5. • The Welsh Government is committed to using procurement as a lever
for driving economic, social and environmental benefits and supporting
jobs and growth.
• Public procurement should help promote Wales as a good place for
doing business and should provide mechanisms that allow suppliers of
all sizes to flourish.
• Welsh Government encourages use of Project Bank Accounts (PBAs) as
a means of addressing poor payment practices in public sector supply
chains by facilitating fair and prompt payment.
Policy Drivers?
• PBAs a condition of funding for all Band A and Band B capital funded
projects receiving Investment Panel funding approval after 1 January
2019.
PBA Policy in the 21st Century Schools Programme
6. • A PBA is a bank account that may or may not be interest bearing, set
up under a Trust Deed arrangement that ensures that payments from
the client to the lead contractor and the supply chain are made
promptly.
• This ensures money is not held up as it makes its way down the
supply chain and removes the opportunity for payment abuse e.g.
extended payment terms being applied by the main contractor;
protracted payment procedures being applied.
What are Project Bank Accounts?
7. What are Project Bank Accounts?
• Once monies are paid into the account they are only accessible to
the parties to the trust deed.
• Safeguards supply chain parties in the event of insolvency of main contractor.
8. • What is the problem, why are PBAs needed?
‘Historically, it is has not been unusual for lower tier supply chain
members to have to wait for up to 100 days to receive payment,
which damages their cash flow and can harm their business.’
2012 UK Govt. Cabinet Office PBA Briefing Document
Policy Drivers?
9. • What is the problem, why are PBAs needed?
‘Historically, it is has not been unusual for lower tier supply chain
members to have to wait for up to 100 days to receive payment,
which damages their cash flow and can harm their business.’
2012 UK Govt. Cabinet Office PBA Briefing Document
58% of respondents had experienced payment periods in excess of 30
days where they were main contractors to public sector clients.
72% of respondents reported payment periods in excess of 30 days
where they were sub-contractors on public sector projects.
2017 Specialist Engineering Contractors Group (SEC Group) survey Nov’16 – Jan’17
Policy Drivers?
10. • What is the problem, why are PBAs needed?
‘Historically, it is has not been unusual for lower tier supply chain
members to have to wait for up to 100 days to receive payment,
which damages their cash flow and can harm their business.’
2012 UK Govt. Cabinet Office PBA Briefing Document
58% of respondents had experienced payment periods in excess of 30
days where they were main contractors to public sector clients.
72% of respondents reported payment periods in excess of 30 days
where they were sub-contractors on public sector projects.
2017 Specialist Engineering Contractors Group (SEC Group) survey Nov’16 – Jan’17
Policy Drivers?
‘Around £50bn is “locked up in late payments”, negatively impacting the
UK's small business community’.
2018 Supply Management Daily Aug’18
Research by Hitachi Capital Business Finance
11. 1. PBA Policy effective from 1st Jan 2018 to:
* EXEMPTIONS to the £2m threshold are
a) UNLESS there are compelling reasons not to do so. Where compelling
reasons are identified, a decision report detailing those reasons must be
completed and filed to allow for audit.
b) Projects / Contracts shorter than 6 months
c) If the successful bidder (i.e. tier 1) gives a firm undertaking to self-deliver
and/or to use subcontractors from within the parent company to which the tier
1 also belongs, such that either one or a combination the above conditions
covers over 75% of the main contract award value.
2. All Welsh Government (WG) contracts valued at £2m* or more where:
Main features of the Welsh Government PBA Policy
a) WG is the client (Delivered directly by or on behalf of WG Departments)
b) WG can apply conditions of funding (Part or Grant funded by WG e.g. 21st CS)
12. IN ALL CASES WERE A PBA IS APPLIED Tier 2 or lower tier suppliers will be
engaged as follows:
a) Tier 2 or lower tier suppliers who account for at least 1% of the main contract
award value must join the PBA;
b) Tier 2 or lower tier suppliers who account for less than 1% of the main
contract award value, should be allowed to request to join the PBA.
c) Acceptance of such a request to join the PBA will be subject to the agreement
of the trustees and the main contractor.
Main features of the Welsh Government PBA Policy
13. • The Public Sector will be encouraged to follow PBA policy as fair and
prompt payment ‘good practice’.
• Helps meet Principle 5 of the Code of Practice - Ethical Employment in
Supply Chains, ‘…our organisation will…
5. Ensure that the way in which we work with our suppliers does not
contribute to the use of illegal or unethical employment practices within the
supply chain. We will:
5.2 Ensure that our suppliers are paid on time – within 30 days of receipt
of a valid invoice.
How Does the PBA policy apply to the wider public sector in Wales?
14. ‘…analysis suggested that the benefits of introducing PBAs would outweigh
the costs of doing so.’ *
Cost-Benefit Analysis (CBA) compares the costs and benefits of a proposed
action to a base case or ‘do nothing’ alternative.
Cost Benefit analysis of PBAs
Queensland Dept. of Housing and Public Works (Delloitte, July 2017)
*Analysis of security of payment reform for the building and construction industry – addendum report
Prepared for the Queensland Department of Housing and Public Works (Delloitte July 2017)
15. Cost Benefit analysis of PBAs*
‘…analysis suggested that the benefits of introducing PBAs would outweigh
the costs of doing so.’
Cost-Benefit Analysis (CBA) compares the costs and benefits of a proposed
action to a base case or ‘do nothing’ alternative.
Government
Due to a reduction in project costs from
reduced subcontractor pricing to reflect the
reduced risk of delayed or non-payment.
16. Subcontractors
Due to better cash flow and avoidance of
bridging finance costs; Reduced payment
dispute resolution costs.
Cost Benefit analysis of PBAs*
‘…analysis suggested that the benefits of introducing PBAs would outweigh
the costs of doing so.’
Cost-Benefit Analysis (CBA) compares the costs and benefits of a proposed
action to a base case or ‘do nothing’ alternative.
17. Head Contractors
Due to a reduction in working capital from not
holding monies due to supplier chain members,
but benefits from reduced payment dispute
resolution costs.
Cost Benefit analysis of PBAs*
‘…analysis suggested that the benefits of introducing PBAs would outweigh
the costs of doing so.’
Cost-Benefit Analysis (CBA) compares the costs and benefits of a proposed
action to a base case or ‘do nothing’ alternative.
18. Cost Benefit analysis of PBAs*
‘…analysis suggested that the benefits of introducing PBAs would outweigh
the costs of doing so.’
Cost-Benefit Analysis (CBA) compares the costs and benefits of a proposed
action to a base case or ‘do nothing’ alternative.
Net Benefit to society
Government + Subcontractors – Head contractors
19. Cost Benefit analysis of PBAs*
The cost-benefit analysis identified the following significant benefits and costs
Benefits
• A reduction in project costs through increased certainty of payment. enables
better pricing from subcontractors due to reduced of delayed or non-payment,
which led to a reduction in overall project costs.
• Compared to traditional payment regimes PBAs can deliver savings of around
1% of the contract value.
• An improvement in working capital for subcontractors. This is a result of improving
speed of payment to subcontractors under a PBA scheme. Puts money to work
in the economy previously tied up pending payment.
• Certainty over how much and when payment will be made builds trust between
supply team members and underpins collaborative working to achieve value for
money projects for clients.
Research by the UK Fair Payment Working Group
20. • Better legal compliance for clients inc. the public sector
• Late Payment of Commercial Debts (Interest) Act 1998, allows
businesses of any size including public bodies to charge or be charged
statutory interest on late payment of undisputed invoices within 30 days.
Costs
• A reduction in working capital for Tier 1 / Main contractors.
• Additional costs to the Public sector in on-going administration and
compliance costs - client in acting as trustees for PBAs.
Cost Benefit analysis of PBAs*
Benefits
21. Questions or queries
• Value Wales mailbox: VWPolicy@gov.wales
Guidance documents
• Project Bank Accounts – Procurement Advice Note (PAN) December 2017
• Guidelines for deploying Welsh Government Project Bank Account Policy –
December 2017
Further information
22. Applying Project Bank Accounts (PBA) Policy
in the 21st Century Schools Programme
Brendan Burke
Value Wales – Procurement Policy
Welsh Government
Email:VWPolicy
21st Century Schools programme
12th November 2018, Bodelwyddan
19th November 2018, Llanelli
26th November 2018, Cardiff
24. 24
Process to open a PBAFeatures of a PBA
“Joint Account” between two parties
Held in trust
Ring-fenced funds
Operational Account
Dual control of funds allowable
Electronic access only (no cash or cheques)
Credit Balance Only – no borrowing allowed
Standard account and electronic tariff
packages apply
Requirements to open a PBA
A Trust Deed – we only need proof it exists
PBA application – with a professional witness
to the Trust Deed
Client request
KYC
requirements
Account
Opening
Online Banking
Request via Email or phone
PBA application form
& T& Cs
Key information such as:
legal structure of the business
source and purpose of funds
key signatories
Once all docs returned
and KYC satisfied, an
account number and sort
code are generated
Access to PBA via your
LBG existing online banking
channel
Dual authoriser and/or dual
administrator of the PBA
PROJECT BANK ACCOUNT
Ring-fenced, held in trust
supports fast movement of funds from client to subcontractors
25. KEY REQUIREMENTS AND DEMYSTIFYING USE
25
PBA Myths vs. Reality
1. They are expensive to run
Pricing in line with your existing corporate
tariff (include transaction and account
fees)
2. They are hard to set up
KYC is the key part of the process and
supplying the right info is mostly on client’s
end
3. They are only for large projects
A PBA may be applicable if over certain
value thresholds (£2m+) and/or numerous
subcontractors that require payment
4. They account has to be pre-funded
Money is only paid into the PBA when a
payment is then due to subcontractors, it
should operate at a zero balance
KYC requirements
1. Details of the project
2. Details of the customers and suppliers
3. Principal place of business
4. Financials e.g.: expected annual turnover,
source of first deposit into the Account,
nature of payments
5. ID/KAP form for Authorised Representatives
(usually Directors of the two entities)
6. KYC on each of the PBA account parties to
include structure chart and identification of
directors along with an understanding of the
business
26. 26
Requirement to open a new
physical bank account per
PBA
Difficulty on boarding sub-
sub contractors onto the
PBA
Reporting on KPIs and monitoring
performance is manual and time consuming
TECHNOLOGY AS AN ENABLER
27. IN SUMMARY
27
Lloyds Bank is committed to supporting a strong, transparent and
resilient UK Construction Supply Chain, capable of delivering first
class Infrastructure
Robust Terms and Conditions
Step-in rights ensure the supply chains
will continue to operate effectively
regardless of circumstances
Credit Interest
Linked to Bank of England Base Rate
and paid monthly against balances
in the account
Solid counterpart
Placing funds with a low risk institution
backed by a strong capital position
Future proofing
Thinking beyond current use of PBAS,
looking at seamless integration with
payment & invoicing systems
31. Our Approach to PBAs
• Use of PBAs are compulsory across all contracts awarded in
HE. (‘unless compelling reasons not to do so’).
• HE operate the Single Authority Model
• Use standard NEC3 ECC Option Y clauses in our contracts
• Policy is to pay down to Tier 3 level
• Contractor free to decide upon project bank as long as it
meets minimum requirements
• HE - PBA agreed/signed RACI in place
33. PBA payment
days mechanism
Future Government departments will specify the
following contractual last dates for payment
(from the assessment date) across the supply
chain:
• Employer to tier 1-14 days ( i.e. Tier 1
Contractor Costain)
• Tier 1 to Tier 2 and 3 - 7 days (i.e. Tier 2 P & D,
Tier 3 Safe lanes ) M1 J19-16
34. What are the benefits?
• Protects funds in the event of lead contractor
insolvency
• Visibility/transparency of supply chain-identity, nature
of sub contracts and cash flows down the lower tiers
• Ease of compliance with the Government Fair Payment
Charter principles
• Drive efficiencies
• Reduce cash flow issues down the supply chain (SMEs)
to enable effective delivery of the Roads programme
• Reduce the harm due to late payment practices on
“mental health” wellbeing on SMEs
35. What are the benefits?
• Reduction in disputes within supply chain
• Future investment opportunities for SMEs
• Integrated Supply Chain
• Easier measurement of payment timescales
across supply chain
• Provides security and certainty of payment
and minimise unnecessary costs such as
financing charges
36.
37. Contractors
responsibilities
• The Contractor nominates a preferred PBA bank
supplier
• Set up PBA and notify details to Highways England
• Prepare and sign Deed of Trust and Joining Deeds
and forward to Commercial team
• Notify bank of agreed named supplier details
• Propose PBA named suppliers expectations for HE
consideration
• Prepare monthly assessments and supporting
breakdown
38. Contractors
responsibilities
• Instruct bank to pay in accordance with details
agreed with HE
• Facilitates HE having ‘view only’ access to PBA
• Provide PBA management information
required by HE
• Ensures that 80% of the Sub Contract value
paid directly via PBA
• Comply with agreed PBA processes
39. Success story M4/M5
• Delivery Partner- Balfour Beatty
• One of the earlier scheme to use PBA
• BB signed up 32 suppliers to the PBA,
representing 86 per cent of its supply chain.
• Overcame a number of challenges
• Use of PBA been praised
• Continue to build on the success in other
schemes awarded to BB
40. Feedback Received from
the Supply Chain
“We have been very impressed with the seamless and timely payments. We receive clear
notification of money due on a monthly basis and this assists us greatly with cash flow
forecasting. We believe that Project Bank Accounts have worked well for the supply
chain.”
Supplier A
“The PBA enables us to manage our business more effectively from a cash flow
perspective and enables us to pay our suppliers on a similar basis reducing their cash flow
borrowing and associated costs.”
Supplier B
“The Project Bank Account worked very well and we were very pleased with the way it
was administered. Once an application has been certified payments were always made in
line with the agreed schedule. We were also able to pass on these positive aspects of the
Project Bank Account to our supply chain who also benefited from it.”
Supplier C
41. Success story
M6 J10a to13
• Delivery Partner- Carillion
• Carillion signed up 53 suppliers to the PBA,
representing 96 per cent of its supply chain
over the last 9 months.
• Lesson Learnt meeting took place after
scheme was final account
42. PBA Statics &
Performance
• Latest figures declared £15.0 billion (delivered by
2020)
• Q4 17/18 figures 27% (SMEs)
• Highways England represents 89% of all PBAs in
operation
• Positive feedback received -Praised by SEC Group
• World leaders – best in class in prompt payment
43. HE Progress
• Chaired the Fair Payment Working Group that
sits below GCB
• Working closely with DPs to get Tier 3 signed
up to PBAs
• Production of supplier intelligence
• Routes to Market
• Continue working closely with Cabinet Office
• Audit
44. PBA Dashboards
22%
24%
26%
28%
30%
32%
34%
Percentage
SME % Spend Chart 2013-2016
SME spend
via PBA
Current
Baseline
Governem
ent
Baseline
2020
£0
£5
£10
£15
£20
£25
£30
£35
£40
Millions
PBA Remaining Balances
Total
remaining
balance
per month
45. Communications/
Stakeholder Management
• Advised other departments e.g. Queensland
State Government, Wales and Scotland
• Attended and presented at the Constructing
Excellence Members Forum with Environmental
Agency
• Engagement with Tier 2 supply chain
• Training sessions and awareness of PBA with
main contractors and individual schemes teams
• One to one awareness of the process
• Various press articles
46. Liquidation – case study
• PBA was an untested initiative
• Positive recognition received from Rudi Klein
• Provided advise and support to Network Rail
in implementing PBAs within there
organisation.
• Working with HS2 to help them administer the
use of PBAs
48. Further Reading…
• Review undertaken in June 2015 of
Highways England progress to date
• Report available on SEC website. See
Implementation of PBAs Across Highways
England
• Contains further detail about how PBAs
were set up, performance, efficiency
savings etc.
• Published guidance (2012) on gov.uk by
Cabinet Office
• https://www.gov.uk/government/publicati
ons/project-bank-accounts
Implementation of Project Bank Accounts across Highways England
Abstract
Across the construction industry it has not been unusual for lower tiers of the supply chain to wait up to
100 days to receive payment. Such inefficient payment practices damage supply chain cash flow and
results in additional financing requirements that the client has to ultimately pay. In 2009 the Government
Construction Board decided to introduce Project Bank Accounts (PBAs) as a means to address these
concerns unless there are compelling reasons not to do so. PBAs are designed to ensure security and
certainty of payment to the supply chain down to Tier 3 level and involve making payments through a
specific ring fenced bank account set up for a particular scheme. They also ensure speed of payment
and drive efficiencies that can be passed onto the client as a result of reduced financing requirements.
The paper discusses the reasons for introducing PBAs across Highways England schemes and the
benefits they have brought to both the client and supply chain.
Lloyd Biddell
Cost Intelligence Team Leader
Commercial & Procurement Directorate
Highways England
The Cube
199 Wharfside Street
Birmingham
B1 1RN
United Kingdom
Email: lloyd.biddell@highwaysengland.co.uk
Telephone: 07789 746 119
50. Project Bank
Accounts Event
Thanks for coming!
Please complete your feedback forms and return
to Bethan/Craig before you leave.
We look forward to seeing you in future.
Editor's Notes
Analysis of security of payment reform for the building and construction industry – addendum report - Prepared for the Queensland Department of Housing and Public Works (Delloitte July 2017)