Clarification of gst 220917
•
0 likes•20 views
This office memorandum from the Director General of CPWD provides clarification on applying GST to ongoing construction agreements. For contractors who were awarded work or submitted tenders before July 1, 2017 when GST took effect, an interim relief of 6% of the gross bill amount will be provided upon submission of an undertaking. This undertaking states that the contractor will refund any excess payment received that is not actually owed after review of the approved GST compensation statement. The memorandum was distributed to senior leadership for information purposes.
Report
Share
Report
Share
Download to read offline
Recommended
Retail price block 'a' mist avenue
This document outlines several payment plans for a real estate development project including a down payment plan, construction link plan, and flexi payment plan. The down payment plan requires 10% payment at booking and 89% within 15 days of booking. The construction link plan has payments due at various construction milestones from booking until completion. The flexi payment plan provides a 10% discount on the basic sale price. Other charges like parking and maintenance fees are also outlined.
GST on works contract
This document discusses work contracts and estimating taxes in the pre-GST and GST eras. It provides details on how GST is calculated at 18% for work contracts in Prasar Bharat. Contractors will pay GST and file returns, while departments can claim input tax credit. The contractor must ensure taxes are considered in estimates and submit invoices according to CGST rules.
Payments provisions in CPWD CONTRACT
The document outlines policies for payments to contractors, including:
1) Contractors must submit bills that are then checked by engineers before payment. Final bills are based on tender value and interest is owed for delayed payments.
2) Contractors must notify completion within 10 days and receive completion certificates within 30 days. Final bills must be submitted within 1 month of completion.
3) Payments can be made directly to banks if requested. Deductions will be made for taxes, VAT, and cess. Advance payments require security and permits while mobilization advances over 2 crores require bank guarantees.
Office 3499 bsp tower 1 & 3
The document outlines various payment plans and prices for units in Tower 1 and 3 of a residential development. It provides details of the basic sale price (BSP) and installment amounts and due dates for four payment plans: a down payment plan (BSP Rs. 3499/sqft), 12% monthly return plan (BSP Rs. 4899/sqft), construction link plan (BSP Rs. 4699/sqft), and flexi payment plan (BSP Rs. 4099/sqft). It also lists other charges such as parking, service tax, and interest free maintenance security.
Agreement 2003 format 01 nikunj bangalore
This agreement is between an outsourcing company (First Party) and a business process outsourcing vendor (Second Party). The Second Party will provide 5 seats worth of work for 11 months, as outlined in Schedule A. Schedule A details the registration fees, number of forms to be processed, number of systems, and duration of the contract. Schedule B outlines the required accuracy parameters and payment structure based on accuracy levels. It also describes the process for reworking data that does not meet the required accuracy levels.
Conditions of CPWD contract in INDIA
The document outlines various clauses related to conditions of contract for construction projects. It defines key terms like contract, work, contractor, engineer-in-charge. It describes payment terms like performance guarantee, security deposit, running bills, final bill payments. It specifies responsibilities of contractor regarding labor laws, welfare, taxes. It also covers measurement and valuation of work, specifications, defects liability period, tools/plants to be provided, advances and their recovery.
4. job work under gst
The document discusses various aspects of job work under GST including:
- The definition of job work as any treatment or process undertaken on goods belonging to another registered person.
- Input tax credit provisions for inputs and capital goods sent for job work.
- The procedure for sending inputs/capital goods to a job worker without payment of tax and bringing them back after job work.
- Transactional provisions for inputs/goods sent to a job worker before the GST appointed date.
- Requirements for maintaining proper accounts and reconciling supplies between the principal and job worker.
Corporate hights 5599 tower 4 (1)
This document outlines the payment plans and pricing for units in the Corporate Height Tower 4 development. There are three payment plans offered: a one-time down payment plan with a basic sale price of Rs. 5599 per square foot, a 12% monthly return plan with a basic sale price of Rs. 7199 per square foot, and a construction link plan priced at Rs. 6999 per square foot. The construction link plan involves 10% payments at various construction milestones. Additional charges include other charges of Rs. 250 per square foot, car parking prices starting at Rs. 500,000, and interest free maintenance security of Rs. 250 per square foot. Terms and conditions including price changes apply.
Recommended
Retail price block 'a' mist avenue
This document outlines several payment plans for a real estate development project including a down payment plan, construction link plan, and flexi payment plan. The down payment plan requires 10% payment at booking and 89% within 15 days of booking. The construction link plan has payments due at various construction milestones from booking until completion. The flexi payment plan provides a 10% discount on the basic sale price. Other charges like parking and maintenance fees are also outlined.
GST on works contract
This document discusses work contracts and estimating taxes in the pre-GST and GST eras. It provides details on how GST is calculated at 18% for work contracts in Prasar Bharat. Contractors will pay GST and file returns, while departments can claim input tax credit. The contractor must ensure taxes are considered in estimates and submit invoices according to CGST rules.
Payments provisions in CPWD CONTRACT
The document outlines policies for payments to contractors, including:
1) Contractors must submit bills that are then checked by engineers before payment. Final bills are based on tender value and interest is owed for delayed payments.
2) Contractors must notify completion within 10 days and receive completion certificates within 30 days. Final bills must be submitted within 1 month of completion.
3) Payments can be made directly to banks if requested. Deductions will be made for taxes, VAT, and cess. Advance payments require security and permits while mobilization advances over 2 crores require bank guarantees.
Office 3499 bsp tower 1 & 3
The document outlines various payment plans and prices for units in Tower 1 and 3 of a residential development. It provides details of the basic sale price (BSP) and installment amounts and due dates for four payment plans: a down payment plan (BSP Rs. 3499/sqft), 12% monthly return plan (BSP Rs. 4899/sqft), construction link plan (BSP Rs. 4699/sqft), and flexi payment plan (BSP Rs. 4099/sqft). It also lists other charges such as parking, service tax, and interest free maintenance security.
Agreement 2003 format 01 nikunj bangalore
This agreement is between an outsourcing company (First Party) and a business process outsourcing vendor (Second Party). The Second Party will provide 5 seats worth of work for 11 months, as outlined in Schedule A. Schedule A details the registration fees, number of forms to be processed, number of systems, and duration of the contract. Schedule B outlines the required accuracy parameters and payment structure based on accuracy levels. It also describes the process for reworking data that does not meet the required accuracy levels.
Conditions of CPWD contract in INDIA
The document outlines various clauses related to conditions of contract for construction projects. It defines key terms like contract, work, contractor, engineer-in-charge. It describes payment terms like performance guarantee, security deposit, running bills, final bill payments. It specifies responsibilities of contractor regarding labor laws, welfare, taxes. It also covers measurement and valuation of work, specifications, defects liability period, tools/plants to be provided, advances and their recovery.
4. job work under gst
The document discusses various aspects of job work under GST including:
- The definition of job work as any treatment or process undertaken on goods belonging to another registered person.
- Input tax credit provisions for inputs and capital goods sent for job work.
- The procedure for sending inputs/capital goods to a job worker without payment of tax and bringing them back after job work.
- Transactional provisions for inputs/goods sent to a job worker before the GST appointed date.
- Requirements for maintaining proper accounts and reconciling supplies between the principal and job worker.
Corporate hights 5599 tower 4 (1)
This document outlines the payment plans and pricing for units in the Corporate Height Tower 4 development. There are three payment plans offered: a one-time down payment plan with a basic sale price of Rs. 5599 per square foot, a 12% monthly return plan with a basic sale price of Rs. 7199 per square foot, and a construction link plan priced at Rs. 6999 per square foot. The construction link plan involves 10% payments at various construction milestones. Additional charges include other charges of Rs. 250 per square foot, car parking prices starting at Rs. 500,000, and interest free maintenance security of Rs. 250 per square foot. Terms and conditions including price changes apply.
7 Tenaris Hydril
Julius S. Baga was employed by Hydril Canadian Company Ltd. from October 28, 2013 to March 13, 2015 as a Premium Threading Operator. He earned $25.00 per hour in this permanent full-time position, which involved studying job orders, setting up and operating machinery, measuring parts, and performing routine maintenance. The confirmation letter also states that Baga is no longer employed by the company.
9.epp
The document appears to be a quiz containing 15 multiple choice questions related to engineering qualifications, project management procedures, procurement regulations, and worker health and safety acts in Nepal. It provides multiple choice options for each question along with the correct answers listed at the end.
Solvay adv acc.case 1 a. l.t. contract.company abc
This document provides information about a 3-year construction contract Company ABC obtained in 2007 to build 2 boilers for 90,606. It gives initial cost estimates and details actual costs incurred each year, along with progress billings and a request to calculate revenue and expense recognition under IAS 11 for years 2007-2009 based on percentage of completion.
Checklist for CT3 Exemption
The document outlines the process and documentation required for importing capital goods into a Software Technology Park of India (STPI) unit while claiming excise duty exemption. It details obtaining: 1) Form CT3 certificate from customs after providing documents like valid STPI status proof, legal agreement, bonded warehouse license, capital goods balance sheet; 2) A request letter and proforma invoice to STPI who issues the CT3 along with attested invoice; 3) Required customs formalities after receiving CT3 like furnishing documents and entering goods details in registers; 4) Verification of imported goods by customs officials and updating registers to avail excise exemption.
Latest Amendments In Service Tax After Budget 2009
Recent amendments expanded the scope of services subject to service tax to include transport of goods by rail, coastal and inland water transport, legal consultancy, and cosmetic surgery. Exemptions were provided for some financial services and export promotion councils. The document also outlines changes to cenvat credit rules and increases to refund claim time limits.
Check list for import of capital goods from STPI
The document outlines the process and documentation required for importing capital goods into an STPI unit in India. It lists documents needed like valid STPI and bonded warehouse licenses. It describes submitting a request letter and proforma invoice to STPI for import approval, then clearing customs with the approval and other documents. After customs, the unit must bond the goods with STPI by filling forms, having STPI inspect, and getting a re-warehousing certificate issued.
GST-Framework.pdf
The document contains questions and answers related to various GST concepts and provisions. Some key points addressed are:
- Discount provided at the time of supply is allowed under GST and should not be included in the value of supply.
- Input tax credit can only be availed after receipt of goods or services, not in advance.
- A practicing consultant providing services outside their state of registration does not need additional registration if there is no fixed place of business in the other state.
- Gold attracts 3% GST along with other duties due to its high value, increasing the overall tax rate from the previous 2%.
- Reversal of input tax credit is required for exempt supplies and free supplies provided under schemes
Wct a detailed guide
Works contract is a deemed sale which involves the transfer of property in goods (whether as goods or in any other form) involved in the execution of the works contract. The concept of taxation of goods transferred during the execution of works contract has been a matter of great litigation over the period.
I am trying to sum up the regularly followed methods and procedures while determining the taxation of works contracts in the hands of contractor.
Gst on remunaration to directors.
The document discusses whether remuneration paid to directors by a company is subject to GST under the reverse charge mechanism. It notes that while some advance rulings have found remuneration to be taxable under reverse charge, these rulings did not consider whether directors are employees of the company. The document argues that remuneration paid to directors would not be subject to reverse charge GST since it arises from an employer-employee relationship as defined in Schedule III of the GST Act and was not taxed under similar provisions in the previous service tax regime.
Wct
This document summarizes the two main methods for taxing works contracts under the Rajasthan VAT Act: the exemption fees method and the VAT method. The exemption fees method allows contractors to pay tax as a percentage of the contract value in exchange for foregoing input tax credits. The VAT method calculates taxable turnover by deducting labor and other costs from the gross contract value, then contractors can claim input tax credits and pay the net tax amount. Contractors must choose which method to use based on their individual circumstances and need for input tax credits on goods purchased.
Appliacbility Issues & Solutions under GST by CA. VInay Bhushan
This document discusses various applicability issues and solutions for manufacturers, traders, job workers, works contractors, and service providers under the Goods and Services Tax (GST) regime in India.
It provides definitions and discusses the taxability of job workers, manufacturers, and works contractors. For job workers, it explains the transitional provisions that allow goods sent for job work before GST to be brought back within six months without tax if a declaration is filed. For manufacturers, it compares the excise and GST regimes.
The document also discusses composition schemes for manufacturers and service providers, input tax credit provisions, and transitional benefits for works contractors to carry forward excise credits in GST returns. Key differences between the present and
Acquisory news-bytes-14th-15th-june-2017
Corporate Updates
SEBI
Recording of Non Disposal Undertaking (NDU)in the Depository System
Interest and Dividend information reporting in case of Custodial Accounts-Rule 114G(1)(e) of the Income Tax Rules, 1962
Non-compliance with certain provisions of SEBI (Issue of Capital and Disclosure Requirements) Regulations, 2009
MCA
MCA comes out with further exemptions to Private Companies and notifies the amendment to the principal notification dated 5th June, 2015
MCA comes out with further exemptions to Government Companies and notifies the amendment to the principal notification dated 5th June, 2015
TAXATION
CBDT provides clarification on Reduced Liability of Tax on complex, building, flat etc. under GST
Company Website:
www.acquisory.com
Recent Amendments in Service Tax
The petitioners challenged the levy of service tax on construction of residential complexes, arguing that it amounts to taxation of immovable property, which is not within the legislative competence of Parliament. The Revenue argued that construction involves various taxable services. The court held that while construction involves both goods and services, the dominant nature is transfer of immovable property and hence service tax cannot be levied. It ruled the levy was beyond Parliament's legislative competence.
2021 budget indirect tax
The document summarizes key proposed changes to India's Goods and Services Tax (GST) and customs duties according to the FY 2021-22 Union Budget. Some key points include: 1) Mandatory GST audits by chartered accountants have been removed and replaced by annual return filing with self-certification; 2) Conditions for claiming input tax credit have been tightened to require invoices be reported in GSTR-2B; 3) Penalties for e-way bill violations have been increased. Customs duty rates have been changed for various products and an new Agriculture Infrastructure Development Cess has been introduced on certain goods.
Presentation- Hardik Batra.pptx
ABSTRACT
Chemical is right at the core of advance industrial systems, which is why it has attained a serious concern for disaster management. Chemical disasters are often traumatic in impact on humans usually resulting in casualties along with damage to nature and property. Unlike natural disasters, preventive and regulatory measures assume greater significance when we talk about chemical disasters. India too, has witnessed several chemical disasters in the past 50 years, highlighting the need for safeguards against such events. This paper’s focus lies on two of the most dangerous gas leaks India has witnessed until this date, i.e. the Bhopal Gas Leak and the Vizag Gas Leak. The author discusses in detail what went wrong prior to and during the Bhopal Gas leak, which is followed by an explanation on how the safety initiatives have evolved after the 1984 incident. In the next section, the author tries to decode the Vizag leak of 2020 with emphasis on how the company could bypass the safety norms in place. The author then discusses the gap in the present framework governing Chemical Disasters (including gas leaks) and proposes certain measures that could be implemented for effective management of such disasters.
Direct Tax Amendments Applicable From 1st April 2017
As Financial Year is ending, tax proposals in the Budget 2017 have now become law. This Budget focused on rewarding honest taxpayers, taxing the rich and bringing to task economic offenders. Here we are listing some of the major changes in direct taxation that would apply from April 2017.
Union budget 2017 Impact
This document summarizes key changes from the Indian Budget 2017 relating to direct taxes, indirect taxes, and other financial measures. For individuals, the document outlines changes such as reduced income tax rates, increased deduction limits, and simplified income tax returns. For corporates and professionals, it discusses changes like the corporate tax rate and presumptive taxation. The document also summarizes changes to capital gains tax, TDS/TCS provisions, and introduces new penalties for non-compliance. Regarding indirect taxes, it notes that the Goods and Services Tax is expected to be implemented soon and replaces existing service tax and excise duty laws.
Treatment of Input Tax Credit on Works Contract Under GST by Aakash Tiwari
Treatment of Input Tax Credit on Works Contract Under GST published on Jmvd legal updates dated 09.07.2020
Lunawat Bulletin - July 2017
Lunawat Bulletin - July 2017 is published and is now available at http://lunawat.com/Uploaded_Files/Attachments/F_3738.pdf
Interest liability under gst
The document discusses interest liability under the GST Act. Section 50 deals with interest payable for delayed tax payments. Per the section and various court judgments, interest is typically levied on the net tax amount owed after considering available input tax credits. However, a recent Telangana High Court judgment dismissed a writ petition and held that interest should be calculated on the full gross tax liability until returns are filed to claim credits. Stakeholders now face uncertainty as amendments aligning the law with the intent of compensating the government for delayed net amounts have not been enacted.
Basics of GST
Goods and Services Tax (GST) is a comprehensive indirect tax on the supply of goods and services throughout India that replaced multiple taxes levied by the central and state governments. GST is composed of Central GST and State GST and is levied on all stages of supply of goods and services. Registered businesses can claim input tax credit, reducing the overall tax burden. GST was implemented on July 1, 2017 and aims to create a single, unified Indian market.
Sceheme of Levy of MAT & Relevant Case laws
The document provides an overview of Minimum Alternate Tax (MAT) under Section 115JB of the Indian Income Tax Act, including:
- MAT was introduced to tax companies that report large profits but pay little tax using deductions and exemptions.
- MAT is the higher of tax calculated under normal tax provisions or 18.5% of book profits (profits reported in financial statements).
- Book profits are adjusted by adding back deductions claimed and removing certain incomes to calculate MAT payable.
- Any MAT paid can be carried forward as a tax credit for future years when normal tax exceeds MAT payable.
More Related Content
What's hot
7 Tenaris Hydril
Julius S. Baga was employed by Hydril Canadian Company Ltd. from October 28, 2013 to March 13, 2015 as a Premium Threading Operator. He earned $25.00 per hour in this permanent full-time position, which involved studying job orders, setting up and operating machinery, measuring parts, and performing routine maintenance. The confirmation letter also states that Baga is no longer employed by the company.
9.epp
The document appears to be a quiz containing 15 multiple choice questions related to engineering qualifications, project management procedures, procurement regulations, and worker health and safety acts in Nepal. It provides multiple choice options for each question along with the correct answers listed at the end.
Solvay adv acc.case 1 a. l.t. contract.company abc
This document provides information about a 3-year construction contract Company ABC obtained in 2007 to build 2 boilers for 90,606. It gives initial cost estimates and details actual costs incurred each year, along with progress billings and a request to calculate revenue and expense recognition under IAS 11 for years 2007-2009 based on percentage of completion.
Checklist for CT3 Exemption
The document outlines the process and documentation required for importing capital goods into a Software Technology Park of India (STPI) unit while claiming excise duty exemption. It details obtaining: 1) Form CT3 certificate from customs after providing documents like valid STPI status proof, legal agreement, bonded warehouse license, capital goods balance sheet; 2) A request letter and proforma invoice to STPI who issues the CT3 along with attested invoice; 3) Required customs formalities after receiving CT3 like furnishing documents and entering goods details in registers; 4) Verification of imported goods by customs officials and updating registers to avail excise exemption.
Latest Amendments In Service Tax After Budget 2009
Recent amendments expanded the scope of services subject to service tax to include transport of goods by rail, coastal and inland water transport, legal consultancy, and cosmetic surgery. Exemptions were provided for some financial services and export promotion councils. The document also outlines changes to cenvat credit rules and increases to refund claim time limits.
Check list for import of capital goods from STPI
The document outlines the process and documentation required for importing capital goods into an STPI unit in India. It lists documents needed like valid STPI and bonded warehouse licenses. It describes submitting a request letter and proforma invoice to STPI for import approval, then clearing customs with the approval and other documents. After customs, the unit must bond the goods with STPI by filling forms, having STPI inspect, and getting a re-warehousing certificate issued.
What's hot (6)
Solvay adv acc.case 1 a. l.t. contract.company abc
Solvay adv acc.case 1 a. l.t. contract.company abc
Latest Amendments In Service Tax After Budget 2009
Latest Amendments In Service Tax After Budget 2009
Similar to Clarification of gst 220917
GST-Framework.pdf
The document contains questions and answers related to various GST concepts and provisions. Some key points addressed are:
- Discount provided at the time of supply is allowed under GST and should not be included in the value of supply.
- Input tax credit can only be availed after receipt of goods or services, not in advance.
- A practicing consultant providing services outside their state of registration does not need additional registration if there is no fixed place of business in the other state.
- Gold attracts 3% GST along with other duties due to its high value, increasing the overall tax rate from the previous 2%.
- Reversal of input tax credit is required for exempt supplies and free supplies provided under schemes
Wct a detailed guide
Works contract is a deemed sale which involves the transfer of property in goods (whether as goods or in any other form) involved in the execution of the works contract. The concept of taxation of goods transferred during the execution of works contract has been a matter of great litigation over the period.
I am trying to sum up the regularly followed methods and procedures while determining the taxation of works contracts in the hands of contractor.
Gst on remunaration to directors.
The document discusses whether remuneration paid to directors by a company is subject to GST under the reverse charge mechanism. It notes that while some advance rulings have found remuneration to be taxable under reverse charge, these rulings did not consider whether directors are employees of the company. The document argues that remuneration paid to directors would not be subject to reverse charge GST since it arises from an employer-employee relationship as defined in Schedule III of the GST Act and was not taxed under similar provisions in the previous service tax regime.
Wct
This document summarizes the two main methods for taxing works contracts under the Rajasthan VAT Act: the exemption fees method and the VAT method. The exemption fees method allows contractors to pay tax as a percentage of the contract value in exchange for foregoing input tax credits. The VAT method calculates taxable turnover by deducting labor and other costs from the gross contract value, then contractors can claim input tax credits and pay the net tax amount. Contractors must choose which method to use based on their individual circumstances and need for input tax credits on goods purchased.
Appliacbility Issues & Solutions under GST by CA. VInay Bhushan
This document discusses various applicability issues and solutions for manufacturers, traders, job workers, works contractors, and service providers under the Goods and Services Tax (GST) regime in India.
It provides definitions and discusses the taxability of job workers, manufacturers, and works contractors. For job workers, it explains the transitional provisions that allow goods sent for job work before GST to be brought back within six months without tax if a declaration is filed. For manufacturers, it compares the excise and GST regimes.
The document also discusses composition schemes for manufacturers and service providers, input tax credit provisions, and transitional benefits for works contractors to carry forward excise credits in GST returns. Key differences between the present and
Acquisory news-bytes-14th-15th-june-2017
Corporate Updates
SEBI
Recording of Non Disposal Undertaking (NDU)in the Depository System
Interest and Dividend information reporting in case of Custodial Accounts-Rule 114G(1)(e) of the Income Tax Rules, 1962
Non-compliance with certain provisions of SEBI (Issue of Capital and Disclosure Requirements) Regulations, 2009
MCA
MCA comes out with further exemptions to Private Companies and notifies the amendment to the principal notification dated 5th June, 2015
MCA comes out with further exemptions to Government Companies and notifies the amendment to the principal notification dated 5th June, 2015
TAXATION
CBDT provides clarification on Reduced Liability of Tax on complex, building, flat etc. under GST
Company Website:
www.acquisory.com
Recent Amendments in Service Tax
The petitioners challenged the levy of service tax on construction of residential complexes, arguing that it amounts to taxation of immovable property, which is not within the legislative competence of Parliament. The Revenue argued that construction involves various taxable services. The court held that while construction involves both goods and services, the dominant nature is transfer of immovable property and hence service tax cannot be levied. It ruled the levy was beyond Parliament's legislative competence.
2021 budget indirect tax
The document summarizes key proposed changes to India's Goods and Services Tax (GST) and customs duties according to the FY 2021-22 Union Budget. Some key points include: 1) Mandatory GST audits by chartered accountants have been removed and replaced by annual return filing with self-certification; 2) Conditions for claiming input tax credit have been tightened to require invoices be reported in GSTR-2B; 3) Penalties for e-way bill violations have been increased. Customs duty rates have been changed for various products and an new Agriculture Infrastructure Development Cess has been introduced on certain goods.
Presentation- Hardik Batra.pptx
ABSTRACT
Chemical is right at the core of advance industrial systems, which is why it has attained a serious concern for disaster management. Chemical disasters are often traumatic in impact on humans usually resulting in casualties along with damage to nature and property. Unlike natural disasters, preventive and regulatory measures assume greater significance when we talk about chemical disasters. India too, has witnessed several chemical disasters in the past 50 years, highlighting the need for safeguards against such events. This paper’s focus lies on two of the most dangerous gas leaks India has witnessed until this date, i.e. the Bhopal Gas Leak and the Vizag Gas Leak. The author discusses in detail what went wrong prior to and during the Bhopal Gas leak, which is followed by an explanation on how the safety initiatives have evolved after the 1984 incident. In the next section, the author tries to decode the Vizag leak of 2020 with emphasis on how the company could bypass the safety norms in place. The author then discusses the gap in the present framework governing Chemical Disasters (including gas leaks) and proposes certain measures that could be implemented for effective management of such disasters.
Direct Tax Amendments Applicable From 1st April 2017
As Financial Year is ending, tax proposals in the Budget 2017 have now become law. This Budget focused on rewarding honest taxpayers, taxing the rich and bringing to task economic offenders. Here we are listing some of the major changes in direct taxation that would apply from April 2017.
Union budget 2017 Impact
This document summarizes key changes from the Indian Budget 2017 relating to direct taxes, indirect taxes, and other financial measures. For individuals, the document outlines changes such as reduced income tax rates, increased deduction limits, and simplified income tax returns. For corporates and professionals, it discusses changes like the corporate tax rate and presumptive taxation. The document also summarizes changes to capital gains tax, TDS/TCS provisions, and introduces new penalties for non-compliance. Regarding indirect taxes, it notes that the Goods and Services Tax is expected to be implemented soon and replaces existing service tax and excise duty laws.
Treatment of Input Tax Credit on Works Contract Under GST by Aakash Tiwari
Treatment of Input Tax Credit on Works Contract Under GST published on Jmvd legal updates dated 09.07.2020
Lunawat Bulletin - July 2017
Lunawat Bulletin - July 2017 is published and is now available at http://lunawat.com/Uploaded_Files/Attachments/F_3738.pdf
Interest liability under gst
The document discusses interest liability under the GST Act. Section 50 deals with interest payable for delayed tax payments. Per the section and various court judgments, interest is typically levied on the net tax amount owed after considering available input tax credits. However, a recent Telangana High Court judgment dismissed a writ petition and held that interest should be calculated on the full gross tax liability until returns are filed to claim credits. Stakeholders now face uncertainty as amendments aligning the law with the intent of compensating the government for delayed net amounts have not been enacted.
Basics of GST
Goods and Services Tax (GST) is a comprehensive indirect tax on the supply of goods and services throughout India that replaced multiple taxes levied by the central and state governments. GST is composed of Central GST and State GST and is levied on all stages of supply of goods and services. Registered businesses can claim input tax credit, reducing the overall tax burden. GST was implemented on July 1, 2017 and aims to create a single, unified Indian market.
Sceheme of Levy of MAT & Relevant Case laws
The document provides an overview of Minimum Alternate Tax (MAT) under Section 115JB of the Indian Income Tax Act, including:
- MAT was introduced to tax companies that report large profits but pay little tax using deductions and exemptions.
- MAT is the higher of tax calculated under normal tax provisions or 18.5% of book profits (profits reported in financial statements).
- Book profits are adjusted by adding back deductions claimed and removing certain incomes to calculate MAT payable.
- Any MAT paid can be carried forward as a tax credit for future years when normal tax exceeds MAT payable.
Construction - Accounting and Tax Aspects
This is a presentation covering accounting, Direct and Indirect Tax Aspects of the Construction Sector.
Recent changes in GST
A brief on recent changes in GST post 22nd and 23rd meetings of the GST Council. Please note that this is purely for educational/guidance purposes, and holds no legal validity
Lunawat bulletin september 2017
Lunawat Bulletin - September 2017 has been published and is available at http://lunawat.com/Uploaded_Files/Attachments/F_3787.pdf
Regards
Snr gst update
Recently Karnataka AAR has given a ruling in the matter of “Mr. Anil Kumar Agrawal” holding that salary paid to executive director is not liable to GST as it is covered under schedule III of CGST Act, 2017, thus not to be considered for computing aggregate turnover for registration. This ruling has effectively put aside the confusion of applicability of GST under RCM on director’s remuneration ruled by Rajasthan AAR in the matter of “Clay Craft India Private Limited”. Brief facts and findings of the present ruling are analysed in this update.
#gst #gstupdate #gstupdate #update #snr #krestonsnr
Similar to Clarification of gst 220917 (20)
Appliacbility Issues & Solutions under GST by CA. VInay Bhushan
Appliacbility Issues & Solutions under GST by CA. VInay Bhushan
Direct Tax Amendments Applicable From 1st April 2017
Direct Tax Amendments Applicable From 1st April 2017
Treatment of Input Tax Credit on Works Contract Under GST by Aakash Tiwari
Treatment of Input Tax Credit on Works Contract Under GST by Aakash Tiwari
Recently uploaded
About Potato, The scientific name of the plant is Solanum tuberosum (L).
The potato is a starchy root vegetable native to the Americas that is consumed as a staple food in many parts of the world. Potatoes are tubers of the plant Solanum tuberosum, a perennial in the nightshade family Solanaceae. Wild potato species can be found from the southern United States to southern Chile
Synopsis (short abstract) In December 2023, the UN General Assembly proclaimed 30 May as the International Day of Potato.
原版制作(DPU毕业证书)德保罗大学毕业证Offer一模一样
学校原件一模一样【微信：741003700 】《(DPU毕业证书)德保罗大学毕业证》【微信：741003700 】学位证，留信认证（真实可查，永久存档）原件一模一样纸张工艺/offer、雅思、外壳等材料/诚信可靠,可直接看成品样本，帮您解决无法毕业带来的各种难题！外壳，原版制作，诚信可靠，可直接看成品样本。行业标杆！精益求精，诚心合作，真诚制作！多年品质 ,按需精细制作，24小时接单,全套进口原装设备。十五年致力于帮助留学生解决难题，包您满意。
本公司拥有海外各大学样板无数，能完美还原。
1:1完美还原海外各大学毕业材料上的工艺：水印，阴影底纹，钢印LOGO烫金烫银，LOGO烫金烫银复合重叠。文字图案浮雕、激光镭射、紫外荧光、温感、复印防伪等防伪工艺。材料咨询办理、认证咨询办理请加学历顾问Q/微741003700
【主营项目】
一.毕业证【q微741003700】成绩单、使馆认证、教育部认证、雅思托福成绩单、学生卡等！
二.真实使馆公证(即留学回国人员证明,不成功不收费)
三.真实教育部学历学位认证（教育部存档！教育部留服网站永久可查）
四.办理各国各大学文凭(一对一专业服务,可全程监控跟踪进度)
如果您处于以下几种情况：
◇在校期间，因各种原因未能顺利毕业……拿不到官方毕业证【q/微741003700】
◇面对父母的压力，希望尽快拿到；
◇不清楚认证流程以及材料该如何准备；
◇回国时间很长，忘记办理；
◇回国马上就要找工作，办给用人单位看；
◇企事业单位必须要求办理的
◇需要报考公务员、购买免税车、落转户口
◇申请留学生创业基金
留信网认证的作用:
1:该专业认证可证明留学生真实身份
2:同时对留学生所学专业登记给予评定
3:国家专业人才认证中心颁发入库证书
4:这个认证书并且可以归档倒地方
5:凡事获得留信网入网的信息将会逐步更新到个人身份内，将在公安局网内查询个人身份证信息后，同步读取人才网入库信息
6:个人职称评审加20分
7:个人信誉贷款加10分
8:在国家人才网主办的国家网络招聘大会中纳入资料，供国家高端企业选择人才
A Guide to AI for Smarter Nonprofits - Dr. Cori Faklaris, UNC Charlotte
A Guide to AI for Smarter Nonprofits - Dr. Cori Faklaris, UNC CharlotteUniversity of North Carolina at Charlotte
Working with data is a challenge for many organizations. Nonprofits in particular may need to collect and analyze sensitive, incomplete, and/or biased historical data about people. In this talk, Dr. Cori Faklaris of UNC Charlotte provides an overview of current AI capabilities and weaknesses to consider when integrating current AI technologies into the data workflow. The talk is organized around three takeaways: (1) For better or sometimes worse, AI provides you with “infinite interns.” (2) Give people permission & guardrails to learn what works with these “interns” and what doesn’t. (3) Create a roadmap for adding in more AI to assist nonprofit work, along with strategies for bias mitigation.
Texas Water Development Board Updates June 2024
Presented at June 6-7 Texas Alliance of Groundwater Districts Business Meeting
CBO’s Outlook for U.S. Fertility Rates: 2024 to 2054
Presentation by Molly Dahl, CBO's Long-Term Analysis Unit Chief, at a conference organized by the National Bureau of Economic Research.
原版制作(英国Southampton毕业证书)南安普顿大学毕业证录取通知书一模一样
学校原件一模一样【微信：741003700 】《(英国Southampton毕业证书)南安普顿大学毕业证》【微信：741003700 】学位证，留信认证（真实可查，永久存档）原件一模一样纸张工艺/offer、雅思、外壳等材料/诚信可靠,可直接看成品样本，帮您解决无法毕业带来的各种难题！外壳，原版制作，诚信可靠，可直接看成品样本。行业标杆！精益求精，诚心合作，真诚制作！多年品质 ,按需精细制作，24小时接单,全套进口原装设备。十五年致力于帮助留学生解决难题，包您满意。
本公司拥有海外各大学样板无数，能完美还原。
1:1完美还原海外各大学毕业材料上的工艺：水印，阴影底纹，钢印LOGO烫金烫银，LOGO烫金烫银复合重叠。文字图案浮雕、激光镭射、紫外荧光、温感、复印防伪等防伪工艺。材料咨询办理、认证咨询办理请加学历顾问Q/微741003700
【主营项目】
一.毕业证【q微741003700】成绩单、使馆认证、教育部认证、雅思托福成绩单、学生卡等！
二.真实使馆公证(即留学回国人员证明,不成功不收费)
三.真实教育部学历学位认证（教育部存档！教育部留服网站永久可查）
四.办理各国各大学文凭(一对一专业服务,可全程监控跟踪进度)
如果您处于以下几种情况：
◇在校期间，因各种原因未能顺利毕业……拿不到官方毕业证【q/微741003700】
◇面对父母的压力，希望尽快拿到；
◇不清楚认证流程以及材料该如何准备；
◇回国时间很长，忘记办理；
◇回国马上就要找工作，办给用人单位看；
◇企事业单位必须要求办理的
◇需要报考公务员、购买免税车、落转户口
◇申请留学生创业基金
留信网认证的作用:
1:该专业认证可证明留学生真实身份
2:同时对留学生所学专业登记给予评定
3:国家专业人才认证中心颁发入库证书
4:这个认证书并且可以归档倒地方
5:凡事获得留信网入网的信息将会逐步更新到个人身份内，将在公安局网内查询个人身份证信息后，同步读取人才网入库信息
6:个人职称评审加20分
7:个人信誉贷款加10分
8:在国家人才网主办的国家网络招聘大会中纳入资料，供国家高端企业选择人才
Donate to charity during this holiday season
For people who have money and are philanthropic, there are infinite opportunities to gift a needy person or child a Merry Christmas. Even if you are living on a shoestring budget, you will be surprised at how much you can do.
Donate Us
https://serudsindia.org/how-to-donate-to-charity-during-this-holiday-season/
#charityforchildren, #donateforchildren, #donateclothesforchildren, #donatebooksforchildren, #donatetoysforchildren, #sponsorforchildren, #sponsorclothesforchildren, #sponsorbooksforchildren, #sponsortoysforchildren, #seruds, #kurnool
A guide to the International day of Potatoes 2024 - May 30th
Food and Agricultural Organization (FAO)
加急办理华威大学毕业证硕士文凭证书原版一模一样
原版一模一样【微信：741003700 】【华威大学毕业证硕士文凭证书】【微信：741003700 】学位证，留信认证（真实可查，永久存档）offer、雅思、外壳等材料/诚信可靠,可直接看成品样本，帮您解决无法毕业带来的各种难题！外壳，原版制作，诚信可靠，可直接看成品样本。行业标杆！精益求精，诚心合作，真诚制作！多年品质 ,按需精细制作，24小时接单,全套进口原装设备。十五年致力于帮助留学生解决难题，包您满意。
本公司拥有海外各大学样板无数，能完美还原海外各大学 Bachelor Diploma degree, Master Degree Diploma
1:1完美还原海外各大学毕业材料上的工艺：水印，阴影底纹，钢印LOGO烫金烫银，LOGO烫金烫银复合重叠。文字图案浮雕、激光镭射、紫外荧光、温感、复印防伪等防伪工艺。材料咨询办理、认证咨询办理请加学历顾问Q/微741003700
留信网认证的作用:
1:该专业认证可证明留学生真实身份
2:同时对留学生所学专业登记给予评定
3:国家专业人才认证中心颁发入库证书
4:这个认证书并且可以归档倒地方
5:凡事获得留信网入网的信息将会逐步更新到个人身份内，将在公安局网内查询个人身份证信息后，同步读取人才网入库信息
6:个人职称评审加20分
7:个人信誉贷款加10分
8:在国家人才网主办的国家网络招聘大会中纳入资料，供国家高端企业选择人才
2024: The FAR - Federal Acquisition Regulations, Part 41
Jennifer Schaus and Associates hosts a complimentary webinar series on The FAR in 2024. Join the webinars on Wednesdays and Fridays at noon, eastern.
Recordings are on YouTube and the company website.
https://www.youtube.com/@jenniferschaus/videos
RFP for Reno's Community Assistance Center
Property appraisals completed in May for downtown Reno’s Community Assistance and Triage Centers (CAC) reveal that repairing the buildings to bring them back into service would cost an estimated $10.1 million—nearly four times the amount previously reported by city staff.
2024: The FAR - Federal Acquisition Regulations, Part 40
Jennifer Schaus and Associates hosts a complimentary webinar series on The FAR in 2024. Join the webinars on Wednesdays and Fridays at noon, eastern.
Recordings are on YouTube and the company website.
https://www.youtube.com/@jenniferschaus/videos
在线办理美国乔治华盛顿大学毕业证（gwu毕业证书）学历学位证书原版一模一样
原版一模一样【微信：741003700 】【美国乔治华盛顿大学毕业证（gwu毕业证书）学历学位证书】【微信：741003700 】学位证，留信认证（真实可查，永久存档）offer、雅思、外壳等材料/诚信可靠,可直接看成品样本，帮您解决无法毕业带来的各种难题！外壳，原版制作，诚信可靠，可直接看成品样本。行业标杆！精益求精，诚心合作，真诚制作！多年品质 ,按需精细制作，24小时接单,全套进口原装设备。十五年致力于帮助留学生解决难题，包您满意。
本公司拥有海外各大学样板无数，能完美还原海外各大学 Bachelor Diploma degree, Master Degree Diploma
1:1完美还原海外各大学毕业材料上的工艺：水印，阴影底纹，钢印LOGO烫金烫银，LOGO烫金烫银复合重叠。文字图案浮雕、激光镭射、紫外荧光、温感、复印防伪等防伪工艺。材料咨询办理、认证咨询办理请加学历顾问Q/微741003700
留信网认证的作用:
1:该专业认证可证明留学生真实身份
2:同时对留学生所学专业登记给予评定
3:国家专业人才认证中心颁发入库证书
4:这个认证书并且可以归档倒地方
5:凡事获得留信网入网的信息将会逐步更新到个人身份内，将在公安局网内查询个人身份证信息后，同步读取人才网入库信息
6:个人职称评审加20分
7:个人信誉贷款加10分
8:在国家人才网主办的国家网络招聘大会中纳入资料，供国家高端企业选择人才
Border towns and spaces of (in)visibility.pdf
This report explores the significance of border towns and spaces for strengthening responses to young people on the move. In particular it explores the linkages of young people to local service centres with the aim of further developing service, protection, and support strategies for migrant children in border areas across the region. The report is based on a small-scale fieldwork study in the border towns of Chipata and Katete in Zambia conducted in July 2023. Border towns and spaces provide a rich source of information about issues related to the informal or irregular movement of young people across borders, including smuggling and trafficking. They can help build a picture of the nature and scope of the type of movement young migrants undertake and also the forms of protection available to them. Border towns and spaces also provide a lens through which we can better understand the vulnerabilities of young people on the move and, critically, the strategies they use to navigate challenges and access support.
The findings in this report highlight some of the key factors shaping the experiences and vulnerabilities of young people on the move – particularly their proximity to border spaces and how this affects the risks that they face. The report describes strategies that young people on the move employ to remain below the radar of visibility to state and non-state actors due to fear of arrest, detention, and deportation while also trying to keep themselves safe and access support in border towns. These strategies of (in)visibility provide a way to protect themselves yet at the same time also heighten some of the risks young people face as their vulnerabilities are not always recognised by those who could offer support.
In this report we show that the realities and challenges of life and migration in this region and in Zambia need to be better understood for support to be strengthened and tuned to meet the specific needs of young people on the move. This includes understanding the role of state and non-state stakeholders, the impact of laws and policies and, critically, the experiences of the young people themselves. We provide recommendations for immediate action, recommendations for programming to support young people on the move in the two towns that would reduce risk for young people in this area, and recommendations for longer term policy advocacy.
World Food Safety Day 2024- Communication-toolkit.
Food safety, prepare for the unexpected - So what can be done in order to be ready to address food safety, food Consumers, food producers and manufacturers, food transporters, food businesses, food retailers can ...
Bangladesh studies presentation on Liberation War 1971 Indepence-of-Banglades...
Bangladesh studies presentation on Liberation War 1971
AHMR volume 10 number 1 January-April 2024
AHMR is an interdisciplinary peer-reviewed online journal created to encourage and facilitate the study of all aspects (socio-economic, political, legislative and developmental) of Human Mobility in Africa. Through the publication of original research, policy discussions and evidence research papers AHMR provides a comprehensive forum devoted exclusively to the analysis of contemporaneous trends, migration patterns and some of the most important migration-related issues.
Recently uploaded (20)
About Potato, The scientific name of the plant is Solanum tuberosum (L).
About Potato, The scientific name of the plant is Solanum tuberosum (L).
A Guide to AI for Smarter Nonprofits - Dr. Cori Faklaris, UNC Charlotte
A Guide to AI for Smarter Nonprofits - Dr. Cori Faklaris, UNC Charlotte
CBO’s Outlook for U.S. Fertility Rates: 2024 to 2054
CBO’s Outlook for U.S. Fertility Rates: 2024 to 2054
A guide to the International day of Potatoes 2024 - May 30th
A guide to the International day of Potatoes 2024 - May 30th
2024: The FAR - Federal Acquisition Regulations, Part 41
2024: The FAR - Federal Acquisition Regulations, Part 41
2024: The FAR - Federal Acquisition Regulations, Part 40
2024: The FAR - Federal Acquisition Regulations, Part 40
World Food Safety Day 2024- Communication-toolkit.
World Food Safety Day 2024- Communication-toolkit.
Bangladesh studies presentation on Liberation War 1971 Indepence-of-Banglades...
Bangladesh studies presentation on Liberation War 1971 Indepence-of-Banglades...
Clarification of gst 220917
- 1. . 'f-c ~ e=. ~ l r;-::_-:.-. ,I • i t '"'"-·-- OFFICE MEMORANDUM SE/TAS/'i"S"704' ISSUED BY AUTHORTY OF DIRECTOR GENERAL, CPWO NIRMAN BHAWAN, NEW DELHI DATED : 22 .09.2017 Sub:- Clarification of GST Regarding Due to imposition of Goods and Services Tax (GST} with effect from 01.07.2017 and after considering the various representation made by the Builder Associations of different regions with a view to mitigate the problems faced by contractors in the ongoing agreements, it has been decided to adopt the following guidelines. S.No. Work Position 1. Interim relief payable to the contractor on account impact of GST on the work awarded/tender processed before the date of commencement of GST with effect from 01.07.2017. Action to be taken GST rate being 18 %, the interim relief @ 6% of the ssiongross amount of the bill will be payable on submi of undertaking in the prescribed format as below: "!/We hereby undertake to refund to Engine Charge,excess amount if any, paid to me/us er-in- which on ofotherwise was not payable to me/ usafter sancti GST Compensation Statement. " - AA,y>,7 $1Superintending Engineer (TAS) File No. 1~6/ GsT/PP /SE(TAS)/CPWD/2017-18/ 2-oi dated 22/09/2017 Copy to:- 1. All the SDGs, all the ADGs, All the CEs CPWD/ E-in-C (PWD) GNCTD through CPWD web site for information please. Superintending Engineer (TAS)