This document provides an overview of TDS provisions under the Delhi VAT for works contracts. It discusses who is liable to deduct TDS as a contractee or contractor, the value on which TDS should be deducted, applicable rates, procedures for payment and filing of returns. Key points covered are determining what constitutes a works contract, exclusions from TDS, deducting TDS on material value only and not advances, and penalties for non-compliance. The document emphasizes being careful in applying TDS only to works contracts and taking necessary precautions to avoid costs of non-compliance.
This document discusses GST implications for works contracts and real estate transactions in India. Some key points:
- Works contracts are treated as supply of services under GST. Rates are 18% generally, but some specified contracts are 12%. Labour contracts are 18% except for certain exemptions.
- For builders selling flats/villas, the activity is treated as supply of service if any amount is received before completion. Rate is 18% with 1/3 deduction for land.
- For landlord share of construction, it is a works contract with the non-monetary consideration of land. Valuation methods are discussed and rate would be 18%.
- Plot sales are not taxable generally but development
The document discusses provisions around place of supply under the Integrated Goods and Services Tax (IGST) Act. It explains that IGST is levied on inter-state supplies of goods or services. It outlines the key provisions to determine whether a supply is inter-state or intra-state, including looking at the location of the supplier and place of supply. It also summarizes the relevant sections that govern place of supply of goods (Section 10), imports/exports of goods (Section 11), and place of supply of services (Section 12).
Refunds under GST & Impact of GST Audit on Statutory/ Tax AuditsGST Law India
The following presentation enumerates how to claim refund under GST and also auditing mechanism such as auditing by a chartered accountant, taxing authorities and special audit under GST. The presentation also details out the treatment of zero rated supplies and deemed export.
Supply under GST (goods and services tax)Aashi90100
This document provides definitions and explanations of key terms under the Goods and Services Tax (GST) in India such as goods, services, taxable person, supplier, recipient, location of supply, and place of business. It explains concepts like input service distributor, usual place of residence, principal place of business, and fixed establishment. The document aims to outline the scope and coverage of entities, transactions, and locations that would be subject to GST in India.
The document discusses various transitional provisions under GST relating to carry forward of credits from existing tax laws to GST. It addresses questions around treatment of closing balances, stock credits, capital goods credits, input tax credits for inputs in transit, and treatment of registered persons engaged in both taxable and exempted activities. Key provisions covered include migration of existing taxpayers to GST, availment of input tax credit on closing balances as per last returns, deemed credit for inputs in stock, and carry forward of unavailed capital goods credit. Conditions, timelines and clarifications relating to these transitional measures are also provided.
This document provides an overview of the scope of taxation of services under the new service tax regime in India. It discusses key aspects such as the definition of "service", exclusions and inclinations, charge of service tax, declared services, and bundled services. The presentation covers topics like the meaning of service, consideration, persons, activities that constitute a service, negative list of services, exemptions, and taxability of various services and transactions.
Case Laws on Construction and Works contractsandesh mundra
A compilation of various Judgments of Service Tax and VAT on relevant issues in works contract and construction sector is made. Stands of High court is highlighted on complex issues arising in Constructions and taxation of works contract. A brief description of matter, appellant and petitioner's contemplation and order passed by authorities is also included to add more value.
The document provides an overview of the framework of GST laws in India. It discusses key concepts such as the types of GST (CGST, SGST, IGST), taxes subsumed under GST, exclusions from GST, laws governing GST, and the GST council. It also explains important aspects like the administration of GST, levy and collection of tax, the concept of supply which is the taxable event, and import of services under GST.
This document discusses GST implications for works contracts and real estate transactions in India. Some key points:
- Works contracts are treated as supply of services under GST. Rates are 18% generally, but some specified contracts are 12%. Labour contracts are 18% except for certain exemptions.
- For builders selling flats/villas, the activity is treated as supply of service if any amount is received before completion. Rate is 18% with 1/3 deduction for land.
- For landlord share of construction, it is a works contract with the non-monetary consideration of land. Valuation methods are discussed and rate would be 18%.
- Plot sales are not taxable generally but development
The document discusses provisions around place of supply under the Integrated Goods and Services Tax (IGST) Act. It explains that IGST is levied on inter-state supplies of goods or services. It outlines the key provisions to determine whether a supply is inter-state or intra-state, including looking at the location of the supplier and place of supply. It also summarizes the relevant sections that govern place of supply of goods (Section 10), imports/exports of goods (Section 11), and place of supply of services (Section 12).
Refunds under GST & Impact of GST Audit on Statutory/ Tax AuditsGST Law India
The following presentation enumerates how to claim refund under GST and also auditing mechanism such as auditing by a chartered accountant, taxing authorities and special audit under GST. The presentation also details out the treatment of zero rated supplies and deemed export.
Supply under GST (goods and services tax)Aashi90100
This document provides definitions and explanations of key terms under the Goods and Services Tax (GST) in India such as goods, services, taxable person, supplier, recipient, location of supply, and place of business. It explains concepts like input service distributor, usual place of residence, principal place of business, and fixed establishment. The document aims to outline the scope and coverage of entities, transactions, and locations that would be subject to GST in India.
The document discusses various transitional provisions under GST relating to carry forward of credits from existing tax laws to GST. It addresses questions around treatment of closing balances, stock credits, capital goods credits, input tax credits for inputs in transit, and treatment of registered persons engaged in both taxable and exempted activities. Key provisions covered include migration of existing taxpayers to GST, availment of input tax credit on closing balances as per last returns, deemed credit for inputs in stock, and carry forward of unavailed capital goods credit. Conditions, timelines and clarifications relating to these transitional measures are also provided.
This document provides an overview of the scope of taxation of services under the new service tax regime in India. It discusses key aspects such as the definition of "service", exclusions and inclinations, charge of service tax, declared services, and bundled services. The presentation covers topics like the meaning of service, consideration, persons, activities that constitute a service, negative list of services, exemptions, and taxability of various services and transactions.
Case Laws on Construction and Works contractsandesh mundra
A compilation of various Judgments of Service Tax and VAT on relevant issues in works contract and construction sector is made. Stands of High court is highlighted on complex issues arising in Constructions and taxation of works contract. A brief description of matter, appellant and petitioner's contemplation and order passed by authorities is also included to add more value.
The document provides an overview of the framework of GST laws in India. It discusses key concepts such as the types of GST (CGST, SGST, IGST), taxes subsumed under GST, exclusions from GST, laws governing GST, and the GST council. It also explains important aspects like the administration of GST, levy and collection of tax, the concept of supply which is the taxable event, and import of services under GST.
Taxpert Professionals || Presentation on Goods and Services TaxTAXPERT PROFESSIONALS
This document provides an overview of the framework and key aspects of the Goods and Services Tax (GST) that was implemented in India in 2017. It discusses the present indirect tax structure, taxes that will be subsumed under GST, the proposed GST rate structure, and key concepts like taxable supply, time and place of supply, input tax credit, returns and compliance requirements. It also covers transitional provisions and highlights aspects businesses need to consider to prepare for GST, such as registration requirements, determining the place of supply, and increased compliance. Taxpert Professionals can help businesses with impact analysis, implementation support, and ongoing assistance to navigate GST requirements.
The document provides an overview of export refunds under GST. It discusses key concepts like zero rated supplies, which include exports and supplies to SEZ. It outlines the different types of export refunds available under GST such as export of goods/services upon payment of IGST or under bond/LUT. The document then analyzes section 54 of the CGST Act regarding refund procedures. It discusses refund eligibility for zero rated supplies and supplies with an inverted tax structure. Key points like time limits for refund claims and restrictions are also summarized.
This document provides an overview of understanding financial statements for the purposes of an audit. It discusses reviewing periods of up to 5 years, focusing on key accounting concepts like money measurement and going concern. Trial balances and balance sheets are examined in detail, including accounts, classifications, movements, and balances. Specific items like reverse charge mechanisms, reimbursements, and netting are highlighted. The tax audit report is also reviewed for depreciation, credit balances, and prior period adjustments. Other areas of focus include ratios, foreign transactions, and demands under other laws.
This presentation discusses the intricacies involved and the modifications in the taxation of works contract in various VAT Regimes. It highlights the critical issues to be asked when a project company enters into any state for its operations.
This presentation enumerates a detailed study on the need of GST, concept, benefit, constitutional provisions and amendments, important definitions and how goods and services will be taxed under GST and how to take refund of tax paid through ITC.
The document discusses the valuation of supply under the Goods and Services Tax (GST) in India. It explains that as per Section 15(1), the value of supply between unrelated persons where price is the sole consideration is the transaction value. It also discusses various inclusions and exclusions in determining the value of supply such as taxes, interest, subsidies, discounts etc. The valuation methods explained are transaction value for unrelated persons, open market value for related persons, and cost plus 10% or reasonable value determined consistently with Section 15 for other cases. The document provides examples to illustrate these valuation principles.
This document summarizes key judgements related to indirect taxes in the Indian construction sector. It discusses two Supreme Court cases - Bharat Sanchar Nigam Ltd. v. Union of India regarding the tax treatment of telecom products with both goods and service components, and State of Andhra Pradesh v. Kone Elevators (India) Ltd regarding whether an elevator installation contract constitutes a works contract or supply of goods. It also discusses factors to consider regarding incidental installation services and interstate works contracts. Overall, the document analyzes how different transactions involving both goods and services have been treated for indirect tax purposes.
The document provides an overview of key aspects of the Integrated Goods and Services Tax (IGST) Act in India, including:
1. IGST will be levied on inter-state supplies of goods and services to maintain integrity of the input tax credit chain across states while keeping the regime simple.
2. Key features of IGST include it being levied and collected by the central government on inter-state supplies to effectively tax such transactions.
3. The IGST Act outlines provisions regarding registration, returns, payments, refunds, audits and dispute resolution that broadly mirror equivalent sections in the Central GST (CGST) Act.
The document discusses various transitional provisions under GST relating to input tax credit (ITC). Section 140 provides for ITC on taxes paid under previous laws including CENVAT credit carried forward and unavailed credit on capital goods. It also allows credit of eligible duties on inputs held in stock or contained in final products on the appointed GST date. Certain conditions must be satisfied for claiming this ITC. If conditions are not met, deemed credit will be allowed at a prescribed rate subject to specified limitations and safeguards. Precautions for availing ITC and deemed credit provisions are also summarized.
Specified Domestic Transactions under Transfer PricingMitesh Katira
- The document discusses specified domestic transactions (SDT) under Indian tax law, which were introduced to align domestic transfer pricing with international standards.
- SDT provisions allow tax authorities to make adjustments if payments between related parties or tax holiday-eligible transactions are not at arm's length prices.
- Taxpayers must maintain documentation and obtain audit certificates to demonstrate compliance with SDT rules. Non-compliance can result in penalties.
- The definition and computation of arm's length price is analyzed, along with applicable documentation requirements and assessment procedures for SDTs. Key cases and issues are also discussed.
Section 7 defines the scope of supply under GST. It includes all forms of supply of goods or services for consideration, import of services, activities specified in Schedule I without consideration, and activities in Schedule II. Certain activities specified in Schedule III are excluded from supply. The government may specify if certain transactions are to be treated as supply of goods or services. Schedule I lists activities without consideration as supply. Schedule II specifies what constitutes supply of goods or services. Section 8 deals with composite and mixed supplies, treating them as supply of the principal or highest taxed goods or services.
Composition Scheme Registration Invoicing Returns Payment of Tax under GST.GST Law India
The following presentation focuses on Composition Scheme under GST, how Registration under composition scheme is to be done, invoicing, filing of returns and how is to be paid under this scheme.
CA Ravi R Thakker & Co. provides various finance, taxation, valuation, legal and compliance services to clients in Gujarat and Maharashtra. They analyze client needs carefully and provide customized solutions. Taxation of real estate transactions can be complex, but the introduction of GST provided more clarity on construction activities. There are various types of real estate transactions including joint ventures between landowners and developers, and different types of projects like affordable housing and residential/commercial. The document then outlines sample transaction flows under GST for different real estate project types including when the developer owns the land and when they enter a joint venture.
This document discusses various aspects of CGST/SGST levy and collection under Section 9 of the CGST Act, including:
1. Rates not exceeding 20% apply to intra-state supplies except alcoholic liquor for human consumption.
2. Petrol and its by-products shall be levied with effect from the date notified by the government based on council recommendations.
3. For mixed and composite supplies, the highest tax rate among the goods or services in the combination is applied to calculate tax liability for mixed supplies, while the rate applicable to the principal supply is applied for composite supplies.
Decoding term 'consideration' in GST Bill 2017Amit Kumar
Analysis of term consideration in GST BILL 2017 and the term consideration define in sec 2(31) of CGST Bill. There is ambiguity in relation to security deposit forfeited for non performance of contract.
OBJECTIVES:
Definition
Position under Service Tax and VAT
Position under GST
Composite supply
Taxability of Works contract
Provisions relating to Input tax credit
Supreme Court Judgement - L&T / K Raheja (VAT on Builders)sandesh mundra
This presentation takes one through the details of recent Supreme Court Judgement in the case of Larsen & Toubro, which was a review of K Raheja Judgement. The judgement has a severe impact on the tax aspects of builders and real estate developers. It redefines the definition of works contract and levy of VAT on sale of flats and commercial premises
The document outlines Goods and Services Tax transition provisions, including allowing existing taxpayers to provisionally register for GST and carry forward input tax credits from prior taxes, as well as provisions for works contracts, stock transfers, and price revisions between the prior and GST tax regimes. It also addresses issues around determining the eligible carried forward amounts based on admissibility under both prior and GST laws.
The document discusses various topics related to fire insurance claims and coverage. It outlines the types of claims an insurance company expects, including those from fire, natural disasters, accidents, theft, and more. It also describes common areas of coverage in fire insurance policies like structures, personal property, loss of use. The document provides details on coverage exclusions, insurable interest, the duty of utmost good faith, underinsurance, and business interruption insurance.
Taxpert Professionals || Presentation on Goods and Services TaxTAXPERT PROFESSIONALS
This document provides an overview of the framework and key aspects of the Goods and Services Tax (GST) that was implemented in India in 2017. It discusses the present indirect tax structure, taxes that will be subsumed under GST, the proposed GST rate structure, and key concepts like taxable supply, time and place of supply, input tax credit, returns and compliance requirements. It also covers transitional provisions and highlights aspects businesses need to consider to prepare for GST, such as registration requirements, determining the place of supply, and increased compliance. Taxpert Professionals can help businesses with impact analysis, implementation support, and ongoing assistance to navigate GST requirements.
The document provides an overview of export refunds under GST. It discusses key concepts like zero rated supplies, which include exports and supplies to SEZ. It outlines the different types of export refunds available under GST such as export of goods/services upon payment of IGST or under bond/LUT. The document then analyzes section 54 of the CGST Act regarding refund procedures. It discusses refund eligibility for zero rated supplies and supplies with an inverted tax structure. Key points like time limits for refund claims and restrictions are also summarized.
This document provides an overview of understanding financial statements for the purposes of an audit. It discusses reviewing periods of up to 5 years, focusing on key accounting concepts like money measurement and going concern. Trial balances and balance sheets are examined in detail, including accounts, classifications, movements, and balances. Specific items like reverse charge mechanisms, reimbursements, and netting are highlighted. The tax audit report is also reviewed for depreciation, credit balances, and prior period adjustments. Other areas of focus include ratios, foreign transactions, and demands under other laws.
This presentation discusses the intricacies involved and the modifications in the taxation of works contract in various VAT Regimes. It highlights the critical issues to be asked when a project company enters into any state for its operations.
This presentation enumerates a detailed study on the need of GST, concept, benefit, constitutional provisions and amendments, important definitions and how goods and services will be taxed under GST and how to take refund of tax paid through ITC.
The document discusses the valuation of supply under the Goods and Services Tax (GST) in India. It explains that as per Section 15(1), the value of supply between unrelated persons where price is the sole consideration is the transaction value. It also discusses various inclusions and exclusions in determining the value of supply such as taxes, interest, subsidies, discounts etc. The valuation methods explained are transaction value for unrelated persons, open market value for related persons, and cost plus 10% or reasonable value determined consistently with Section 15 for other cases. The document provides examples to illustrate these valuation principles.
This document summarizes key judgements related to indirect taxes in the Indian construction sector. It discusses two Supreme Court cases - Bharat Sanchar Nigam Ltd. v. Union of India regarding the tax treatment of telecom products with both goods and service components, and State of Andhra Pradesh v. Kone Elevators (India) Ltd regarding whether an elevator installation contract constitutes a works contract or supply of goods. It also discusses factors to consider regarding incidental installation services and interstate works contracts. Overall, the document analyzes how different transactions involving both goods and services have been treated for indirect tax purposes.
The document provides an overview of key aspects of the Integrated Goods and Services Tax (IGST) Act in India, including:
1. IGST will be levied on inter-state supplies of goods and services to maintain integrity of the input tax credit chain across states while keeping the regime simple.
2. Key features of IGST include it being levied and collected by the central government on inter-state supplies to effectively tax such transactions.
3. The IGST Act outlines provisions regarding registration, returns, payments, refunds, audits and dispute resolution that broadly mirror equivalent sections in the Central GST (CGST) Act.
The document discusses various transitional provisions under GST relating to input tax credit (ITC). Section 140 provides for ITC on taxes paid under previous laws including CENVAT credit carried forward and unavailed credit on capital goods. It also allows credit of eligible duties on inputs held in stock or contained in final products on the appointed GST date. Certain conditions must be satisfied for claiming this ITC. If conditions are not met, deemed credit will be allowed at a prescribed rate subject to specified limitations and safeguards. Precautions for availing ITC and deemed credit provisions are also summarized.
Specified Domestic Transactions under Transfer PricingMitesh Katira
- The document discusses specified domestic transactions (SDT) under Indian tax law, which were introduced to align domestic transfer pricing with international standards.
- SDT provisions allow tax authorities to make adjustments if payments between related parties or tax holiday-eligible transactions are not at arm's length prices.
- Taxpayers must maintain documentation and obtain audit certificates to demonstrate compliance with SDT rules. Non-compliance can result in penalties.
- The definition and computation of arm's length price is analyzed, along with applicable documentation requirements and assessment procedures for SDTs. Key cases and issues are also discussed.
Section 7 defines the scope of supply under GST. It includes all forms of supply of goods or services for consideration, import of services, activities specified in Schedule I without consideration, and activities in Schedule II. Certain activities specified in Schedule III are excluded from supply. The government may specify if certain transactions are to be treated as supply of goods or services. Schedule I lists activities without consideration as supply. Schedule II specifies what constitutes supply of goods or services. Section 8 deals with composite and mixed supplies, treating them as supply of the principal or highest taxed goods or services.
Composition Scheme Registration Invoicing Returns Payment of Tax under GST.GST Law India
The following presentation focuses on Composition Scheme under GST, how Registration under composition scheme is to be done, invoicing, filing of returns and how is to be paid under this scheme.
CA Ravi R Thakker & Co. provides various finance, taxation, valuation, legal and compliance services to clients in Gujarat and Maharashtra. They analyze client needs carefully and provide customized solutions. Taxation of real estate transactions can be complex, but the introduction of GST provided more clarity on construction activities. There are various types of real estate transactions including joint ventures between landowners and developers, and different types of projects like affordable housing and residential/commercial. The document then outlines sample transaction flows under GST for different real estate project types including when the developer owns the land and when they enter a joint venture.
This document discusses various aspects of CGST/SGST levy and collection under Section 9 of the CGST Act, including:
1. Rates not exceeding 20% apply to intra-state supplies except alcoholic liquor for human consumption.
2. Petrol and its by-products shall be levied with effect from the date notified by the government based on council recommendations.
3. For mixed and composite supplies, the highest tax rate among the goods or services in the combination is applied to calculate tax liability for mixed supplies, while the rate applicable to the principal supply is applied for composite supplies.
Decoding term 'consideration' in GST Bill 2017Amit Kumar
Analysis of term consideration in GST BILL 2017 and the term consideration define in sec 2(31) of CGST Bill. There is ambiguity in relation to security deposit forfeited for non performance of contract.
OBJECTIVES:
Definition
Position under Service Tax and VAT
Position under GST
Composite supply
Taxability of Works contract
Provisions relating to Input tax credit
Supreme Court Judgement - L&T / K Raheja (VAT on Builders)sandesh mundra
This presentation takes one through the details of recent Supreme Court Judgement in the case of Larsen & Toubro, which was a review of K Raheja Judgement. The judgement has a severe impact on the tax aspects of builders and real estate developers. It redefines the definition of works contract and levy of VAT on sale of flats and commercial premises
The document outlines Goods and Services Tax transition provisions, including allowing existing taxpayers to provisionally register for GST and carry forward input tax credits from prior taxes, as well as provisions for works contracts, stock transfers, and price revisions between the prior and GST tax regimes. It also addresses issues around determining the eligible carried forward amounts based on admissibility under both prior and GST laws.
The document discusses various topics related to fire insurance claims and coverage. It outlines the types of claims an insurance company expects, including those from fire, natural disasters, accidents, theft, and more. It also describes common areas of coverage in fire insurance policies like structures, personal property, loss of use. The document provides details on coverage exclusions, insurable interest, the duty of utmost good faith, underinsurance, and business interruption insurance.
The Google I/O 2013 keynote this year did not include big product announcements like 2012 did with Google Glass or a new Nexus tablet, rather it was more catered to showing off it's new updates and offerings. Here are the highlights from the 2013 keynote.
The Supreme Court of India ruled in favor of the insured party in a case regarding an insurance claim for sugar bags destroyed by fire while stored at a port. The Court found that the insurance policy, which covered risks until delivery to the final destination in India, was still in effect since the goods had not yet reached their ultimate destinations after arriving at the initial port. The intent of extending coverage and paying an additional premium was to provide coverage for the entire transport of the goods within India.
The document discusses the benefits of exercise for mental health. Regular physical activity can help reduce anxiety and depression and improve mood and cognitive functioning. Exercise causes chemical changes in the brain that may help protect against mental illness and improve symptoms.
Real estate construction GST impact-great compilation by CA Shiv AshishShakir Shaikh
1) Construction and real estate contracts related to immovable property like buildings and civil structures are considered works contracts and treated as services under GST.
2) EMIs or advance payments for under-construction homes will attract GST, but supply of land and buildings where payment is received only after completion will be exempt from GST.
3) The tax rate for most construction and real estate contracts is estimated to be 18%, and transitional provisions have been made to allow credit for taxes already paid on stocks and contracts.
GST on Real Estate & Construction SectorLijo Philip
- Construction, building, and maintenance contracts are considered works contracts and treated as services for GST purposes.
- Under-construction projects will be taxed as services if consideration is received before completion, otherwise land and completed buildings are outside GST scope.
- Tax rates are estimated at 18% CGST+SGST or IGST for works contracts, with input tax credit available only for subcontractors that pay tax.
This document summarizes the two main methods for taxing works contracts under the Rajasthan VAT Act: the exemption fees method and the VAT method. The exemption fees method allows contractors to pay tax as a percentage of the contract value in exchange for foregoing input tax credits. The VAT method calculates taxable turnover by deducting labor and other costs from the gross contract value, then contractors can claim input tax credits and pay the net tax amount. Contractors must choose which method to use based on their individual circumstances and need for input tax credits on goods purchased.
Evolution of Works Contract under VAT and ServiceAnmol Gupta
A works contract is a single indivisible contract that involves both the sale of goods and the provision of services necessary to fulfill the contract. Works contracts were first addressed by courts in cases involving State of Madras vs. Gannon Dunkerley & Co. and Gannon Dunkerley and Co. vs. State of Rajasthan. The document then discusses the definition of works contracts under various acts and laws, and how works contracts are taxed under sales tax and service tax laws. Value added tax is applied only to the value of goods involved in the works contract, which must be determined by deducting labor, services, and other charges from the total contract value.
Works contract is a deemed sale which involves the transfer of property in goods (whether as goods or in any other form) involved in the execution of the works contract. The concept of taxation of goods transferred during the execution of works contract has been a matter of great litigation over the period.
I am trying to sum up the regularly followed methods and procedures while determining the taxation of works contracts in the hands of contractor.
TDS is a new concept in Sales Tax laws of the State. Many dealers and even sales tax practitioners do not deal in TDS under sales tax. It the most untouched area in the State Vat.
This share will provide you a brief description of TDS Concepts under DVAT Act.
Optitax's presentation on 'has gst stabilised, yes and no' 3 feb 18Nilesh Mahajan
This presentation includes following topics:
1. Major changes in GST from it’s implementation
2. Budgetary changes under Indirect Taxes
3. Grey areas under GST - Clarity required
4. E-way bill implementation
5. GST compliance - Our request
The document discusses GST implications for works contracts and real estate transactions in India. Some key points:
- Works contracts are treated as supply of services under GST and taxed at 18%, with some works contracts taxed at 12%. Labour contracts are generally taxed at 18%.
- Builders must pay GST on sale of flats/villas if any amount is received prior to completion certificate. The rate is 18% with a 1/3 deduction for land value.
- Landlord share of construction is treated as supply of service by the builder and taxed at 18%. Valuation methods include open market value or cost.
- Landlords must also pay GST if amounts are received
The document provides a taxation update with the following key information:
1. It summarizes recent notifications and circulars from the government regarding inverted duty refunds, transitional credit claims, and changes replacing the National Anti-Profiteering Authority with the Competition Commission of India.
2. It outlines recent case laws around who qualifies as an intermediary under GST, whether a lessee can transfer the right to use goods, and eligibility for IGST exemption on EPCG imports.
3. It summarizes advance rulings regarding availability of ITC for CSR expenses, applicability of GST on recovery of diesel costs for DG set rentals, and GST liability under reverse charge for suppliers of
This document provides an overview of the Goods and Services Tax (GST) in India. It defines GST as a comprehensive tax on the manufacture, sale, and consumption of goods and services applied at the national level. The document discusses the need for GST to replace existing multiple tax structures and integrate various taxes to allow for full input tax credits. It outlines the justification for GST at both the central and state levels. The document also covers the key features and benefits of GST, including the types of taxes subsumed under GST, registration requirements, taxable supplies, input tax credits, and returns.
This document provides an overview of service tax on work contracts under Indian law. It defines what constitutes a work contract and declared services. A work contract is a single contract for material and labor to carry out works like construction, installation, etc. It discusses how work contracts are taxed, with the labor portion taxed under service tax and the goods portion taxed under VAT/Sales tax. There is a reverse charge mechanism for service tax on certain work contracts. The place of provision of service for work contracts is where the immovable property is located.
This ppt is a comprehensive presentation on various aspects for the entities working in the construction domain. Starting from Tendering to Budgeting and going on to indirect tax aspects like VAT and service Tax.
1) The document discusses whether GST can be charged on liquidated damages, which are predetermined damages paid for failure to perform contractual obligations.
2) The Maharashtra Authority for Advance Ruling ruled that liquidated damages are considered a separate supply of services under GST law, namely "agreeing to tolerate an act".
3) The ruling determined that GST at 18% is applicable to liquidated damages as a separate supply and the time of supply is when the delay is established between parties, not when the delay initially occurs.
ICDS III provides guidance for accounting of revenue and expenses for construction contracts. It requires using the percentage of completion method to recognize revenue and expenses over time based on the stage of completion. Revenue includes the initial contract amount and approved variations/claims/incentives if probable and reliably measurable. Expenses include direct costs, allocated borrowing costs and overheads. Early stage contracts limit revenue to costs until 25% completion. The standard applies prospectively from FY 2015-16. Transitional provisions apply for ongoing contracts as of April 1, 2015.
Indirect Tax_Latest Judicial Precedents_ October 2016Ashish Chaudhary
The document provides a summary of 10 indirect tax judicial precedents from October 2016.
1. Subscription money collected from shareholders for membership to a club was considered consideration for taxable services and liable to service tax, even if part was treated as share capital.
2. A job worker was not eligible for service tax exemption when the principal manufacturer availed central excise exemption on manufacture, as per the terms of the exemption notification.
3. Construction of a pipeline within a factory could not be considered construction of a building or civil structure, so credit for the related work contract service was admissible.
This document discusses international transactions and transfer pricing regulations in India. It begins by introducing international transactions and defines them as transactions between two or more associated enterprises, where at least one enterprise is non-resident. It then discusses what constitutes a "transaction" and provides examples. It also discusses deemed international transactions where transactions between a resident enterprise and third party are deemed international transactions if there is a prior agreement between the third party and an associated non-resident enterprise. The document concludes by summarizing a key case related to deemed international transactions between two resident Indian companies.
Presentation on Industry 2020: Emerging GST Issues due to COVID-19Taxmann
Topics Covered in this Webinar:
1. ITC on invoices not uploaded by vendors – Amendment in Rule 36(4)
2. Refund/Adjustment of GST already paid on bad debts, and discounts
3. ITC implications if goods are destroyed/disposed off.
4. Eligibility of ITC on masks and sanitizers
Important Topics Covered in the Webinar:
1. How to claim ITC on Invoices of February to
August 2020?
2.Whether full ITC can be availed on invoices
pertaining to period 09.10.2019 to 03.04.2020 on
which no ITC was previously availed?
3. Whether remaining ITC can be claimed in any of
the subsequent months GSTR 3B’s where partial
ITC (10/20%) was availed previously as per Rule
36(4)?
This document provides an overview of key concepts related to the Goods and Services Tax (GST) regime in India, including the concept of supply, nature of supply, GST rates and exemptions, input tax credit, returns, documentation, and tax deducted at source. It defines supply, explains the dual GST structure of CGST and SGST/IGST, and clarifies whether transactions constitute intra-state or inter-state supply. Schedules are referenced that specify activities treated as supply and clarify supply of goods versus services. The time of supply is also summarized based on the type of transaction.
Summary of changes in vat deduction at source sandra & associatesKhalid Iftekhar
Every year Bangladesh Government brings changes in the VAT law. In 2019, Bangladesh Government brought a new law called Value Added Tax and Supplementary Duty 2012.
This snapshot reflects the differences between the two laws in respect to withholding VAT regime. I hope the users will find this helpful
Summary of changes in vat deduction at source sandra & associates
Sv tds 250513
1. WELCOME
WORKSHOP On TDS
dated the 25th
May 2013 at New Delhi
RaKeSH GaRG, FCaRaKeSH GaRG, FCa
S S a R & aSSOCIaTeSS S a R & aSSOCIaTeS
2. RaKeSHGaRG,FC
2
DVAT-TDS – An OverviewDVAT-TDS – An Overview
TDS COMPLIANCES - STEPS
To establish, whether it is a works contract. TDS to be
deducted on all WCT including AMC, repair, Furnishing, etc. –
All types of works contracts – Big or small
If, Yes; Value on which TDS would be deducted ……>…..>
Time of deduction of TDS –
If TDS under VAT and Income Tax is deducted at the same time,
there will be least confusion.
Deposit of TDS in Govt. Treasury/Bank
Issue of TDS Certificate
Filing of TDS Return
3. RaKeSHGaRG,FC
3
Deduction of DVAT by Contractee
Sec. 36(1) - Any person, not being an individual or a Hindu
undivided family, who is responsible for making payment to any
dealer (hereinafter in this section referred to as “the contractor”)
for discharge of any liability on account of valuable consideration
payable for the transfer of property in goods (whether as goods
or in some other form) in pursuance of a works contract, for value
exceeding twenty thousand rupees …, shall, at the time of credit
of such sum to the account of the contractor or at the time of
payment thereof in cash or by any other mode, whichever is
earlier, deduct tax thereon at the rate of [four] percent. [6% - if
the deductee is unregistered under DVAT]
DVAT – TDS - PROVISIONSDVAT – TDS - PROVISIONS
4. RaKeSHGaRG,FC
4
Deduction of DVAT by Contractor
Sec.36(1A) - Any contractor responsible for making any payment
or discharge of any liability to any sub-contractor, in pursuance of
a contract with the sub-contractor, for value exceeding twenty
thousand rupees ….., for the transfer of property in goods
(whether as goods or in some other form) involved in the
execution, whether wholly or in part, of the works contract
undertaken by the contractor, shall, at the time of such payment
or discharge, in cash or by cheque or draft or any other mode,
deduct an amount equal to [four] percent of such payment or
discharge, purporting to be part of full amount of the tax payable
under this Act. [6% - if the deductee is unregistered under DVAT]
DVAT – TDS - PROVISIONSDVAT – TDS - PROVISIONS
5. RaKeSHGaRG,FC
5
Applicable only to the works contracts ------
Not applicable to pure labour jobs or service contracts, which
do not involve any material
Not applicable to the contracts where material is not
transferred to the contractee, such as, pest control
Not applicable to composite contracts, which are not works
contracts, such as,
Event management, Conventions
House-keeping
Applicability of DVAT-TDSApplicability of DVAT-TDS
6. RaKeSHGaRG,FC
6
Divisible only through fiction of law (as against the terms of
the contract).
Property in the goods is transferred while executing works as
per theory of accretion (Immoble.) or accession (moble.)
Every Composite Contract is not Works Contract, e.g.,
housekeeping contract.
Taxable to the extent of material involved.
Merely job work, e.g., job of blasting, leveling, etc., which
does’t involve any material or transfer of property in goods, is
not taxable in VAT.
No standard formula. Depends upon facts.
What is Works ContractWhat is Works Contract
7. RakeshGaRG,FC
7
Specification theory has been ruled out by the Courts for
determination of any transaction as WCT except in special
circumstances, to illustrate: -
Supply of lifts has been held as a sale transaction by the SC in
Kone Elevators [(2005)140 STC 22];
Supply of ship held as sale by SC in Hindustan Shipyard [(2000)
119 STC 533];
Hindustan Shipyard vs. Rail. Coach Construction;
Supply of printed corrugated boxes by Delhi HC in CIT vs. Dabur
India 198 CTR 375 and supply of printed labels by Maharashtra
HC - held as sale for the purpose of sec. 194C of I.T. Act.
Sale vs. Works ContractSale vs. Works Contract
8. RakeshGaRG,FC
8
A Risky Proposition – Not to deduct TDS as if there are 2 contractsA Risky Proposition – Not to deduct TDS as if there are 2 contracts
Ideally there must be two separate contracts;
As per other terms also, property in the goods must be tfd.
from contractor to contractee before start of execution –
Richardson (1968) 21 STC 245 (SC);
Goods must be supplied free by contractee to contractor for
execution of works; and to be properly documented;
Goods must be reflected in the stock of contractee; and
Care should be taken in drafting of contracts. States VAT
Deptts. have similar provisions/powers to annul the
agreement, if prejudicial to the interest of the Revenue.
Supply + Labour From Same PersonSupply + Labour From Same Person
9. RakeshGaRG,FC
9
Computation of Value, subject to TDSComputation of Value, subject to TDS
Ideally TDS should be deducted only on the material value;
Labour & Service Charges and Inter-State Sales to be excluded
Nathpa Jhakri JT. Venture vs. State of H.P. (2000) 118 STC 306 (SC);
followed the case of Steel Authority of India Ltd. vs. State of Orissa
(2000) 118 STC 297 (SC); State of Chhattisgarh vs. VTP Constructions
(2007) 12 VST 14 (SC)
Amount of Tax (DVAT) and Service Tax to be excluded
If the invoice does not give the bifurcation of goods and
labour, TDS to be deducted on the total value
Value on which TDS to be deductedValue on which TDS to be deducted
10. RakeshGaRG,FC
10
Computation of Value, subject to TDSComputation of Value, subject to TDS
After due consideration of the rival stands, we find that the
proposal made on behalf of the petitioners as an alternative to
striking down statutory provisions being in consonance with
the judgments of the S.C. has to be accepted. This is so as the
States propose to do their duty of providing an appropriate
mechanism to give effect to the law laid down by the Supreme
Court. Accordingly, we hold that impugned provisions for
deduction of tax at source will apply only to the taxable
turnover, i.e., after deducting service component and turnover
relating to sales outside State, in the course of inter-State sales
or in the course of import. Larsen & Toubro Ltd. vs. State of Haryana
(2011 ) 37 VST 428 (P&H)
Value on which TDS to be deductedValue on which TDS to be deducted
11. RakeshGaRG,FC
11
Computation of Value, subject to TDSComputation of Value, subject to TDS
The petitioners, being works contractors, entered into
separate agreement with Railways for supply of boulders in
connection with construction of bridge in Assam. The boulders
were to be procured from various sites in the State of
Arunachal Pradesh and the same was in the knowledge of
Railways. It was held that supply of boulders from Arunachal
Pradesh to Assam was an inter-State sale and the turnover in
relation thereto was to be excluded while deducting tax (VAT)
at source by Railways. [Rock International vs. State of Assam
(2007) 11 VST 111 (Gau)]
Value on which TDS to be deductedValue on which TDS to be deducted
12. RakeshGaRG,FC
12
Computation of Value, subject to TDS –Advance PaymentComputation of Value, subject to TDS –Advance Payment
Tax cannot be deducted by the contractee on the advance
payments made to the contractor. [CTT vs. New Holland
Traders India (P) Ltd (2009) 22 VST 444 (All)]
Provision of TDS does not apply to all payments; but applies
only to those payments, which are for the discharge of any
liability on account of valuable consideration payable for
transfer of property in goods. [Delhi Electric Supply
Undertaking vs. CST (2006) 146 STC 72 (All)]
No TDS on mobilization advance against bank guarantee,
repayable with interest. [Hindustan Construction Company Ltd.
vs. State of Haryana (1998) 109 STC 660 (P&H)]
Value on which TDS to be deductedValue on which TDS to be deducted
13. RakeshGaRG,FC
13
Contractee: Every person, other than an individual and Hindu
undivided family, responsible for making any payment to any
contractor for discharge of any liability on account of valuable
consideration payable for the transfer of property in goods
(whether as goods or in some other form) in pursuance of a
works contract.
Contractor : Every contractor, whether an individual or H.U.F.
or otherwise, responsible for making any payment to any sub-
contractor for discharge of any liability on account of valuable
consideration payable for the transfer of property in goods
(whether as goods or in some other form) in pursuance of a
works contract.
Who is liable to deduct TDSWho is liable to deduct TDS
14. RakeshGaRG,FC
14
Contractee: At the time of credit of such sum to the account of
contractor or at the time of payment thereof in cash or by any
other mode, whichever is earlier, on account of valuable
consideration payable for the transfer of property in goods.
Contractor: At the time of such payment or discharge, in cash
or by cheque or by draft or any other mode to the sub-
contractor for transfer of property in goods.
When to deduct TDSWhen to deduct TDS
15. RakeshGaRG,FC
15
Under DVAT, TDS Rates are very high. In a chain of sub-
contracts, it might be 4% + 4% + so on
Powers to issue lower deduction of TDS vests with the
Commissioner only
Circumstances:
(i) Where any works contract involves both transfer of
property in goods and labour and service, and
commissioner is satisfied that the deduction of tax on a part
of the sum in respect of the works contract is justified; and
(ii) Where any works contract involves only labour and
service and the commissioner is satisfied that no deduction
of tax is justified.
Lower TDS CertificateLower TDS Certificate
16. RakeshGaRG,FC
16
RATE OF TDSRATE OF TDS
RATE OF TDS
From
1.2.11 to
15.1.13
From
16.1.13 to
31.3.13
From
1.4.13
If contractor or sub-contractor, as
the case may be, to whom
payment is made, -
- is registered under DVAT Act 2% 4% 4%
- is not registered under DVAT Act 4% 4% 6%
17. RakeshGaRG,FC
17
Pay TDS within 15 days of the end of the month in which tax
was deducted – (pay Electronically - other than Govt.
deductor)
Issue TDS Certificate in DVAT-43 in quadruplicate:
Two copies to the deductee (One will be attached with
DVAT Return)
One copy to be filed by deductor with quarterly TDS return
One copy to be retained by deductor
Credit for TDS can be claimed only when TDS certificate is
received by the contractor along with Challan
Payment of TDS & TDS CertificatesPayment of TDS & TDS Certificates
18. RakeshGaRG,FC
18
Penalty for non-deduction of TDS or non-payment
A sum not exceeding twice the amount deductible, besides
the tax deductible but not so deducted and, if deducted,
not so deposited into Govt. Treasury.
Interest for non-deduction of TDS or non-payment
Liable for simple interest at the rate of 15% per annum on
the amount deductible under this section but not so
deducted, and if deducted, not so deposited.
Interest shall be calculated from the date on which such
amount was deductible to the date on which such amount
is actually deposited.
Payment of TDS & TDS CertificatesPayment of TDS & TDS Certificates
19. RakeshGaRG,FC
19
Apply for TAN within 7 days from the date when tax was
deductible in DVAT-45
File Quarterly TDS Return within 28 days from end of quarter
in Form DVAT-48
Preserve TDS return for 7 years
Penalty for late application of TAN or late filing of TDS
Return: A sum of Rs. 200/- per day from the day on which
requirement arose until the failure is rectified; Maximum -
Rs. 20,000/-
TAN and TDS ReturnTAN and TDS Return
20. RakeshGaRG,FC
20
Be careful in determining the nature of activity – TDS
is deductible in works contract only
Compare the rate of WCT vs. Sale before awarding an
contract to minimize the impact
Since rate of TDS are high – Non-compliance of
provisions would be a costly proposition.
Otherwise, also penalty provisions are strict.
Be careful, and Take care.
Precautions – To SummarizePrecautions – To Summarize
21. ThaNk YOU
Rakesh GaRG, FCaRakesh GaRG, FCa
s s a R & assOCIaTess s a R & assOCIaTes
Ph: (011) 65960912-13, 9810216270Ph: (011) 65960912-13, 9810216270