Fg letter
•
0 likes•319 views
1. Faithful+Gould is submitting an application to AI Futtaim Carillion LLC for an extension of time of 90 days to complete tunnel monitoring works for the Deira Waterfront Development project. 2. The application includes a letter from AI Futtaim Carillion as well as appendices providing a brief history of the project, a timeline of delay events, cost details, and supporting documentation for each delay event. 3. Faithful+Gould argues they are entitled to the extension and have provided sufficient details of delays outside their control, their efforts to mitigate delays, and their timely responses to delaying events.
Report
Share
Report
Share
Download to read offline
Recommended
Medjdoub[2]
Medjdoub Behilil has over 20 years of experience in logistics and material management roles. He has worked for several oil and gas companies, including Weatherford, Sonatrach-BHPBilliton, Halliburton, Brown & Root - Condor, and Bechtel. His experience includes inventory management, purchasing, expediting orders, and warehouse supervision. He is proficient in several production systems such as JDE, Maisy, GSAP, DataStream7i, and SAP.
Key to a successful EGTL Site
The document discusses the key factors that contributed to the success of the Escravos Gas to Liquids Project in Nigeria. It describes the project scope which involved general civil works including management, civil works, piling, buildings, and wharf construction. Some of the factors for success included maintaining a consistent project management team, implementing strict controlling procedures, establishing a quality management system, and prioritizing health, safety and environmental standards. The document aims to record lessons learned that can help ensure success for similar future projects.
Good job
Our FlightWorks team accomplished several important tasks over the past few weeks. They brought two Beech 1900 aircraft home from Afghanistan in a carefully coordinated effort. They also worked feverishly to complete required inspections for one of the aircraft, saving the company additional expenses. Additionally, the team implemented a new integration between systems that eliminates over 1,200 transactions needing re-entry each month, allowing the accounting department to focus on more valuable work and improve service delivery.
ADA 7
El documento habla sobre diferentes tipos de software dañino como hoaxes, spam, gusanos, spyware, adware, troyanos y bombas lógicas. Define cada uno brevemente, describiendo sus características y cómo funcionan para infectar computadoras o recolectar información de usuarios sin su consentimiento.
Final Interaction Map
The document describes a community space called tiny+ that aims to bring people together through shared facilities and activities. It offers communal areas like a lounge, event space for activities and meetings, and hobby rooms of different sizes that members can rent. The event space and hobby rooms allow members to pursue their interests and build skills. The community hubs are project spaces where members vote on uses and work on innovations together. The document gives examples of two members, Carla and Dan, who found the community and support of tiny+ beneficial after moving into tiny houses.
Intro
This document provides an introduction and overview of Section IX of the ASME Boiler and Pressure Vessel Code, which establishes criteria for welding and brazing qualifications and procedures. It discusses the purpose and organization of Section IX, including that it contains requirements for qualifying welding and brazing procedures and personnel. Section IX is organized into two main parts for welding and brazing that each contain articles on general requirements, procedure qualifications, performance qualifications, and data. The document provides high-level descriptions of the contents of each article.
Rio companion 2016 App
Featuring the latest, up-to-date travel guide, GPS maps, lowdown on Olympic venues, restaurant reviews, security and accessibility info and much more, this smartphone app is the perfect companion for the 2016 Olympic and Paralympic Games.
Recommended
Medjdoub[2]
Medjdoub Behilil has over 20 years of experience in logistics and material management roles. He has worked for several oil and gas companies, including Weatherford, Sonatrach-BHPBilliton, Halliburton, Brown & Root - Condor, and Bechtel. His experience includes inventory management, purchasing, expediting orders, and warehouse supervision. He is proficient in several production systems such as JDE, Maisy, GSAP, DataStream7i, and SAP.
Key to a successful EGTL Site
The document discusses the key factors that contributed to the success of the Escravos Gas to Liquids Project in Nigeria. It describes the project scope which involved general civil works including management, civil works, piling, buildings, and wharf construction. Some of the factors for success included maintaining a consistent project management team, implementing strict controlling procedures, establishing a quality management system, and prioritizing health, safety and environmental standards. The document aims to record lessons learned that can help ensure success for similar future projects.
Good job
Our FlightWorks team accomplished several important tasks over the past few weeks. They brought two Beech 1900 aircraft home from Afghanistan in a carefully coordinated effort. They also worked feverishly to complete required inspections for one of the aircraft, saving the company additional expenses. Additionally, the team implemented a new integration between systems that eliminates over 1,200 transactions needing re-entry each month, allowing the accounting department to focus on more valuable work and improve service delivery.
ADA 7
El documento habla sobre diferentes tipos de software dañino como hoaxes, spam, gusanos, spyware, adware, troyanos y bombas lógicas. Define cada uno brevemente, describiendo sus características y cómo funcionan para infectar computadoras o recolectar información de usuarios sin su consentimiento.
Final Interaction Map
The document describes a community space called tiny+ that aims to bring people together through shared facilities and activities. It offers communal areas like a lounge, event space for activities and meetings, and hobby rooms of different sizes that members can rent. The event space and hobby rooms allow members to pursue their interests and build skills. The community hubs are project spaces where members vote on uses and work on innovations together. The document gives examples of two members, Carla and Dan, who found the community and support of tiny+ beneficial after moving into tiny houses.
Intro
This document provides an introduction and overview of Section IX of the ASME Boiler and Pressure Vessel Code, which establishes criteria for welding and brazing qualifications and procedures. It discusses the purpose and organization of Section IX, including that it contains requirements for qualifying welding and brazing procedures and personnel. Section IX is organized into two main parts for welding and brazing that each contain articles on general requirements, procedure qualifications, performance qualifications, and data. The document provides high-level descriptions of the contents of each article.
Rio companion 2016 App
Featuring the latest, up-to-date travel guide, GPS maps, lowdown on Olympic venues, restaurant reviews, security and accessibility info and much more, this smartphone app is the perfect companion for the 2016 Olympic and Paralympic Games.
Antara Dashboard-002.pptx
TCC is working on emergency repair works at several locations for ANTARA including MARBELLA-114, MONACO-38, and CAPRI STREET-44. The upcoming Eid holiday may cause delays to the project timeline. TCC must prepare documentation like a method statement, materials list, and investigation schedule. They have completed works at some locations and are 50% complete at others, addressing issues like water leaks, duct sealing, and flooring repairs.
Draft document for project no ufc85
The vendor, CIC - COMNET INDUSTRIES COMPANY, submitted several documents to Toyo-Vietnam Corporation for the UFC85/Formaldehyde Plant Project, including:
1. A vendor print index and schedule outlining 8 submitted documents for review and approval.
2. Manufacturer catalogs for the instrument fitting and condensate pot items.
3. A time schedule showing the planned manufacturing, inspection, packing and delivery dates from April to July 2015.
4. Inspection and test reports requiring Toyo-Vietnam's approval before fabrication.
Antonio_Sesto
The document is a curriculum vitae for Antonio Sesto. It details his personal information, education, languages, contact information, and extensive work experience as a rotating equipment engineer working on installation, maintenance, and repair of reciprocating compressors for oil and gas companies from 2002 to present. His experience includes projects in Italy, India, Russia, South Africa, South Korea, and the Middle East working for companies like Shell, GE Oil & Gas, Eni, and Total.
Antonio_Sesto
This CV summarizes Antonio Sesto's qualifications and work experience. He has over 15 years of experience as a Rotating Equipment Engineer working on projects around the world for companies like Shell, GE Oil & Gas, and Eni. His areas of expertise include installation, maintenance, troubleshooting, commissioning, and overhaul of reciprocating compressors and other rotating equipment. He is proficient in Italian, English, French, and Spanish.
Aramco Certificate Experience
This document is a response to a request for an extension of approval for a quality control inspector on the Jizan Refinery and Terminal Project in Saudi Arabia. It grants a two month extension of provisional approval for Elias Omer Adam to serve as a QC Civil Inspector for earthworks, conditional on his performance remaining satisfactory. The original approval was for 60 days. The contractor must still provide training on Saudi Aramco standards and inspection procedures. The project quality manager signed off on the extension.
Document of the world bank
The Coal Handling Port Project in Portugal aimed to construct a port facility at Sines to import coal for a nearby power plant. While construction was completed on time in 1987, delays occurred in procuring coal handling equipment due to changes in government plans. The port now handles general cargo in addition to coal. While the facility supports Portugal's energy needs, the project highlights difficulties ensuring government compliance with objectives when other financing is available. Lessons indicate the Bank should be more selective in supporting projects in graduating countries.
10. Overall Implementation Programme
This document contains a project schedule for the Al Ain Water Distribution Network project. It lists activities with original durations, start and finish dates, and budgets. Key activities and milestones include signing agreements by December 2009, advance payment by January 2010, completion of design by June 2011, delivery and installation of pump units from February to October 2011, and completion of the project and issuance of the Final Acceptance Certificate by October 2013. The document provides detailed schedules for project phases like design and engineering, mechanical works, and pipe installation.
2022-01-13-ALALAMEEN 08-WR08.docx
This weekly report summarizes progress on the AL Alamin city bridges project for week 6. Key points include: construction is 78% complete overall and 83% for stressing works; 32 girders were completed this week bringing the total to 64; main material deliveries are on track except for 39 tons of strands still to deliver; project completion is estimated at 30 January 2022 based on current production rate. Risks discussed include potential delays from weather and strand delivery from the sole supplier.
NZ Patent Grant Report
Patent 585590 describes a gas cooking appliance that determines the no flame position of a fuel gas valve by opening the valve to supply gas to a burner, igniting the burner, and slowly closing the valve until the flame is extinguished. The patent was granted on March 8, 2011 to Fisher & Paykel Appliances Limited and describes a method for determining the cutoff point for a gas valve to prevent gas flow without a flame present. The patent has been renewed multiple times with an expiration date of March 26, 2029.
altaf resume work preparation
Mohammed Altaf Hussain is applying for the position of Works Preparation Controller. He has over 12 years of experience in Gulf countries working on various oil and gas projects as a welding system operator and document/data/work preparation controller. He has strong technical skills in MS Office applications and operating systems.
PIER-CV
This document provides a summary of Pier-Angelo Brogneri's qualifications and work experience. It lists his personal details and offshore certifications. The bulk of the document details his work history from February 2013 to July 2009, where he held various roles such as lead diver, deck foreman, air diver, and rigger for companies in locations like South Africa, Norway, Qatar, Tanzania, UAE, Iraq, Ghana, Brunei, and Saudi Arabia. Each role describes the client, area of work, vessel, tasks performed, and references.
New CV Amended
This document is the CV of Albertus Thomas Combrink, which provides personal and professional details. It summarizes his qualifications including NEBOSH IGC, IMCA Diver Medical Technician, and Fast Recovery Craft Licence. It lists over 25 years of diving experience, including 10 years working in offshore oil and gas in construction roles. It details employment history with companies like Hydro-dive, ACE Diving, and Smit Terminals working on projects in Nigeria, Angola, South Africa, and other locations as a lead diver, deck foreman, and supervisor.
Recent NEC3 Case Review and its Application
Recent UK court judgments shed light on the application and interpretation of some of the NEC3 ECC and PSC clauses. Hong Kong has adopted the NEC3 contract for almost a decade. Users should be aroused of their contractual rights and potential pitfalls to avoid disputes.
met 1 pr.pdf
This document is a purchase requisition from Novatex Limited's BOPET (Biaxially Oriented Polyethylene Terephthalate) unit. It includes 10 line items needing replacement parts for various machinery, including stepper motors, sensors, and electrical components. All items are already in stock and will be supplied for free as per previous contracts. The total weight of items is 5.57 kilograms. The requisition was initiated, authorized, and approved by various department heads and managers.
Bayane production manager ilovepdf-compressed
I AM INTERESTED IN ANY MINING INDUSTRY OPEN CAST MINING INTO ALL PROVINCES IN SOUTH AFRICA OR EVEN ABROAD WHERE ITS SAFE FOR ME TO GO WORK THERE.I DON'T HAVE ANY PROBLEM.I WILL APPRECIATE IF THE RECRUITERS CAN UNDERSTAND MY DESCRIPTION MESSAGE.
Power Point BLCC End of year Review
This document provides a summary of HOVENSA's 2011 capital projects construction review. It includes updates on safety performance, capital project schedules and status, the 100 day construction plan, SVF hours and causes, NDE inspection results, and the SAR heater project featured in news media. It also outlines accomplishments like the construction plan and weekly reporting, as well as opportunities like continued safety efforts and improving estimates.
Power Point BLCC End of year Review
This document provides a summary of Hovensa's 2011 capital projects construction review. It includes updates on safety performance, capital project schedules and summaries, the 100 day construction plan, SVF hours and causes, NDE records, and the SAR heater project featured in news media. Accomplishments included developing construction planning tools and community involvement. Opportunities include continued focus on safety, productivity, and lessons learned from project execution.
PIER-CV
This document provides a summary of Pier-Angellino Brogneri's qualifications and work experience. It lists his personal details and offshore certifications. It then outlines his employment history from 2013 to 2007, including positions held as a lead diver, technician, deck foreman, rigger, and air diver for various diving and offshore contractors in locations like South Africa, Norway, Qatar, Tanzania, UAE, Iraq, Ghana, Brunei, and Saudi Arabia. Projects involved tasks like pipe laying, spool piece installation, underwater inspections, and maintenance work. Contact details are provided for each role.
Monthly Progress Report No.13 - September 2011
This monthly progress report summarizes the work completed in September 2011 for the District Cooling Plant project in Rihan Heights. Key updates include:
- Overall project progress was at 98.59% complete, with testing and commissioning at 82.70% complete.
- The forecast completion date has slipped to October 19, 2011 due to delays in access for buildings, approval from authorities, and water connection.
- Invoicing status shows submitted value of AED 64.9 million, certified value of AED 45.1 million, and received value also of AED 45.1 million.
ENP-EI-T-16-0001 - ARAMCO Replor Resume (Islam abd elrhman )
The document is a transmittal from the Yanbu Terminal Projects Division to the Project Manager at Engineering for the Petroleum and Process Industries, attaching resumes for an instrumentation inspector position. Comments note that one applicant, Mr. Islam Abdalrahman Hussain, was conditionally approved for a 3 month probation period based on an interview. The transmittal requests no response and includes the attachment as a soft copy and hard copy.
More Related Content
Similar to Fg letter
Antara Dashboard-002.pptx
TCC is working on emergency repair works at several locations for ANTARA including MARBELLA-114, MONACO-38, and CAPRI STREET-44. The upcoming Eid holiday may cause delays to the project timeline. TCC must prepare documentation like a method statement, materials list, and investigation schedule. They have completed works at some locations and are 50% complete at others, addressing issues like water leaks, duct sealing, and flooring repairs.
Draft document for project no ufc85
The vendor, CIC - COMNET INDUSTRIES COMPANY, submitted several documents to Toyo-Vietnam Corporation for the UFC85/Formaldehyde Plant Project, including:
1. A vendor print index and schedule outlining 8 submitted documents for review and approval.
2. Manufacturer catalogs for the instrument fitting and condensate pot items.
3. A time schedule showing the planned manufacturing, inspection, packing and delivery dates from April to July 2015.
4. Inspection and test reports requiring Toyo-Vietnam's approval before fabrication.
Antonio_Sesto
The document is a curriculum vitae for Antonio Sesto. It details his personal information, education, languages, contact information, and extensive work experience as a rotating equipment engineer working on installation, maintenance, and repair of reciprocating compressors for oil and gas companies from 2002 to present. His experience includes projects in Italy, India, Russia, South Africa, South Korea, and the Middle East working for companies like Shell, GE Oil & Gas, Eni, and Total.
Antonio_Sesto
This CV summarizes Antonio Sesto's qualifications and work experience. He has over 15 years of experience as a Rotating Equipment Engineer working on projects around the world for companies like Shell, GE Oil & Gas, and Eni. His areas of expertise include installation, maintenance, troubleshooting, commissioning, and overhaul of reciprocating compressors and other rotating equipment. He is proficient in Italian, English, French, and Spanish.
Aramco Certificate Experience
This document is a response to a request for an extension of approval for a quality control inspector on the Jizan Refinery and Terminal Project in Saudi Arabia. It grants a two month extension of provisional approval for Elias Omer Adam to serve as a QC Civil Inspector for earthworks, conditional on his performance remaining satisfactory. The original approval was for 60 days. The contractor must still provide training on Saudi Aramco standards and inspection procedures. The project quality manager signed off on the extension.
Document of the world bank
The Coal Handling Port Project in Portugal aimed to construct a port facility at Sines to import coal for a nearby power plant. While construction was completed on time in 1987, delays occurred in procuring coal handling equipment due to changes in government plans. The port now handles general cargo in addition to coal. While the facility supports Portugal's energy needs, the project highlights difficulties ensuring government compliance with objectives when other financing is available. Lessons indicate the Bank should be more selective in supporting projects in graduating countries.
10. Overall Implementation Programme
This document contains a project schedule for the Al Ain Water Distribution Network project. It lists activities with original durations, start and finish dates, and budgets. Key activities and milestones include signing agreements by December 2009, advance payment by January 2010, completion of design by June 2011, delivery and installation of pump units from February to October 2011, and completion of the project and issuance of the Final Acceptance Certificate by October 2013. The document provides detailed schedules for project phases like design and engineering, mechanical works, and pipe installation.
2022-01-13-ALALAMEEN 08-WR08.docx
This weekly report summarizes progress on the AL Alamin city bridges project for week 6. Key points include: construction is 78% complete overall and 83% for stressing works; 32 girders were completed this week bringing the total to 64; main material deliveries are on track except for 39 tons of strands still to deliver; project completion is estimated at 30 January 2022 based on current production rate. Risks discussed include potential delays from weather and strand delivery from the sole supplier.
NZ Patent Grant Report
Patent 585590 describes a gas cooking appliance that determines the no flame position of a fuel gas valve by opening the valve to supply gas to a burner, igniting the burner, and slowly closing the valve until the flame is extinguished. The patent was granted on March 8, 2011 to Fisher & Paykel Appliances Limited and describes a method for determining the cutoff point for a gas valve to prevent gas flow without a flame present. The patent has been renewed multiple times with an expiration date of March 26, 2029.
altaf resume work preparation
Mohammed Altaf Hussain is applying for the position of Works Preparation Controller. He has over 12 years of experience in Gulf countries working on various oil and gas projects as a welding system operator and document/data/work preparation controller. He has strong technical skills in MS Office applications and operating systems.
PIER-CV
This document provides a summary of Pier-Angelo Brogneri's qualifications and work experience. It lists his personal details and offshore certifications. The bulk of the document details his work history from February 2013 to July 2009, where he held various roles such as lead diver, deck foreman, air diver, and rigger for companies in locations like South Africa, Norway, Qatar, Tanzania, UAE, Iraq, Ghana, Brunei, and Saudi Arabia. Each role describes the client, area of work, vessel, tasks performed, and references.
New CV Amended
This document is the CV of Albertus Thomas Combrink, which provides personal and professional details. It summarizes his qualifications including NEBOSH IGC, IMCA Diver Medical Technician, and Fast Recovery Craft Licence. It lists over 25 years of diving experience, including 10 years working in offshore oil and gas in construction roles. It details employment history with companies like Hydro-dive, ACE Diving, and Smit Terminals working on projects in Nigeria, Angola, South Africa, and other locations as a lead diver, deck foreman, and supervisor.
Recent NEC3 Case Review and its Application
Recent UK court judgments shed light on the application and interpretation of some of the NEC3 ECC and PSC clauses. Hong Kong has adopted the NEC3 contract for almost a decade. Users should be aroused of their contractual rights and potential pitfalls to avoid disputes.
met 1 pr.pdf
This document is a purchase requisition from Novatex Limited's BOPET (Biaxially Oriented Polyethylene Terephthalate) unit. It includes 10 line items needing replacement parts for various machinery, including stepper motors, sensors, and electrical components. All items are already in stock and will be supplied for free as per previous contracts. The total weight of items is 5.57 kilograms. The requisition was initiated, authorized, and approved by various department heads and managers.
Bayane production manager ilovepdf-compressed
I AM INTERESTED IN ANY MINING INDUSTRY OPEN CAST MINING INTO ALL PROVINCES IN SOUTH AFRICA OR EVEN ABROAD WHERE ITS SAFE FOR ME TO GO WORK THERE.I DON'T HAVE ANY PROBLEM.I WILL APPRECIATE IF THE RECRUITERS CAN UNDERSTAND MY DESCRIPTION MESSAGE.
Power Point BLCC End of year Review
This document provides a summary of HOVENSA's 2011 capital projects construction review. It includes updates on safety performance, capital project schedules and status, the 100 day construction plan, SVF hours and causes, NDE inspection results, and the SAR heater project featured in news media. It also outlines accomplishments like the construction plan and weekly reporting, as well as opportunities like continued safety efforts and improving estimates.
Power Point BLCC End of year Review
This document provides a summary of Hovensa's 2011 capital projects construction review. It includes updates on safety performance, capital project schedules and summaries, the 100 day construction plan, SVF hours and causes, NDE records, and the SAR heater project featured in news media. Accomplishments included developing construction planning tools and community involvement. Opportunities include continued focus on safety, productivity, and lessons learned from project execution.
PIER-CV
This document provides a summary of Pier-Angellino Brogneri's qualifications and work experience. It lists his personal details and offshore certifications. It then outlines his employment history from 2013 to 2007, including positions held as a lead diver, technician, deck foreman, rigger, and air diver for various diving and offshore contractors in locations like South Africa, Norway, Qatar, Tanzania, UAE, Iraq, Ghana, Brunei, and Saudi Arabia. Projects involved tasks like pipe laying, spool piece installation, underwater inspections, and maintenance work. Contact details are provided for each role.
Monthly Progress Report No.13 - September 2011
This monthly progress report summarizes the work completed in September 2011 for the District Cooling Plant project in Rihan Heights. Key updates include:
- Overall project progress was at 98.59% complete, with testing and commissioning at 82.70% complete.
- The forecast completion date has slipped to October 19, 2011 due to delays in access for buildings, approval from authorities, and water connection.
- Invoicing status shows submitted value of AED 64.9 million, certified value of AED 45.1 million, and received value also of AED 45.1 million.
ENP-EI-T-16-0001 - ARAMCO Replor Resume (Islam abd elrhman )
The document is a transmittal from the Yanbu Terminal Projects Division to the Project Manager at Engineering for the Petroleum and Process Industries, attaching resumes for an instrumentation inspector position. Comments note that one applicant, Mr. Islam Abdalrahman Hussain, was conditionally approved for a 3 month probation period based on an interview. The transmittal requests no response and includes the attachment as a soft copy and hard copy.
Similar to Fg letter (20)
ENP-EI-T-16-0001 - ARAMCO Replor Resume (Islam abd elrhman )
ENP-EI-T-16-0001 - ARAMCO Replor Resume (Islam abd elrhman )
Fg letter
- 1. To: Date: FAITHFUL {t.- "1!!9Y.bE PO Box 33788 Dubal Unitecl Alllb EmilatM Tel. +971 4 405 9100 Fax. +9714 405 9101 Email: ln!n.mellfyould.com inlo.meOigould.com:����+V t. t.•oa.•1 �lla +W i.t•a ..,•. :.JUt. -����GL.;n 1.11� '('(VA'� Luay Azzam Company: NEA 12 February 2015 Ref. No. 5129118 5.1 T00063 Subject: AFC EOT APPLICATION-AC 594/01-TUNNEL MONITORING WORKS We enclose the undernoted documents. Please acknowledge receipt by completing the form, photocopying and returning to us. Item Document/Reference/Description P/CD No. of No. Copies 1 AFC Letter Ref. No. AFC-FGD-AC594-L-00088 A4 size Subject: Extended Time in which to complete the paper 1 works dated 29 January 2015 2 Summary of Particulars Brief History Appendix 1 - Delay Notification A4-size 1 Appendix 2- Delay Events & Time Line binder Appendix 3 - Programme 1 CD Appendix 4- Cost Details 3 Appendix 5- Event Supporting Documentation A4-size binder 1 (File 1 of 3) 4 Appendix 5- Event Supporting Documentation A4-size binder 1 (File 2 of 3) 5 Appendix 5- Event Supporting Documentation A4-size (File 3 of 3) binder 1 Remarks: For review and recommendation. {{flll. SCoPe crz SGe.l.Ac.t? !"J.7G.1 5 .::; .z� 5.29 <"3c7 ' ' :.:::W't"������:E;S ..Date: ....�...........l.J'..�t,.t$..10.!.)......... Signed: Date: FOR PA'fE Fll Doc. No : 31F-COMIGEN28 Rev.02 MIDDI.E EASTAND INDIA UNITED IONGOOM EUROPE ASIA PACIFIC FGOULD.COM FalthMtGould Dubal Bnmch IsalradingnameH FalthMtGould Umitecl,amembarof!heATIJNSGroup. Dubal llranch ReglstrallonNo. 599!102 Aegls!etedollice;W- Greve, A&hloyRoad, Epsom, Su!11lY, KT18SfNI,Unitecll<lngdom. Aegistere<11n EngfsndNo.2236832
- 2. (,....."·"'> u:.�.al.s -a .!'.h n II ·� � Jll·fidluim C:carillion Ref: AFC/FGD/AC594/L/00088 Faithfui+Gould P. 0. Box: 33786, Dubai, United Arab Emirates Tel: +971 4 4059100 Fax: +971 4 4059101 Attention Project Subject Dear Sir, : Mr. Brian Fisher- Project Director : Deira Waterfront Development Plot 11 - Building A- Carpark : Extended Time in Which to complete the works L.L.C 291h January 2015 Please find enclosed further particulars, referenced AC 594 I 01, in connection with the Tunnel Monitoring works. We consider that we are entitled to an extension of 90 days and that sufficient details have been provided herein to enable an award to be made. It is readily apparent that we have kept you informed of delay, acted to mitigate delay and not faltered in reacting to each and every delaying event quickly and in the best interests of all parties. The delay imposes a significant financial burden upon us and we request and look forward to receipt of your award in the near future. Yours Faithfully, For AI Futtaim Si !ruction Director Cc.: Mr. Fadi Sayegh- Snr. Project Manager, AE7 Mr lshfaq Ali- Project Director- DWD AI Futtaim Carillion Ll.C. P.O. Box 1811 Phone: 04 3331200 Fax: 04 3331018 !SO 9001, 14001 & OHSAS 18001 registered Page 1 of1 Dubai United Arab Emirates E-mail: afc@afcarillion.ae www.afcarillion.ae www.carillionplc.com