World Trade Center Noida, World Trade Tower,CALL +919958959555, Commercial Space for offices, World Trade Centre Noida Spiretech world trade centre - Yamuna Expressway,World Trade Center Noida, World Trade Tower,Real Estate, Commercial Space for offices, World Trade Centre Noida ,World Trade Center Noida, World Trade Tower,CALL +919958959555, Commercial Space for offices, World Trade Centre Noida
World trade centre” (wtc call-9958959555-application form
1. YES,
I WANT TO BE AN
A PROJECT BY
FURNISHED
SPACESREQUEST FOR
REGISTRATION
Corporate & Sales Office: 5D, Plaza M6, District Centre, Jasola, New Delhi - 25, Fax: (+91) 11 4051 5601, E: info@spireworld.in
Gurgaon Sales Office: 21-22, Ground Floor, Vipul Agora, M.G. Road, Gurgaon, Haryana, T: (+91) 124 4853500
Site Office: Plot No. TZ-13A, Sector Tech Zone, Greater Noida Industrial Development Area, District Gautam Budh Nagar (UP)
SMS ‘INVEST’ TO 57333 www.spireworld.in
011-4080-4080
2. SECOND APPLICANT (If any, compulsory to fill all the details along with passpor t size photograph)
Name ____________________________________________________________________________________________________________
S/W/D of ________________________________________________________________________________________________________
Corporate & Sales Office: 5D, Plaza M6, District Centre, Jasola, New Delhi - 110 025, T: (+91) 11 4051 5600, (+91) 11 4071 4000, (in case of company, mention name and designation of authorized signatory)
Fax: (+91) 11 4051 5601, E: info@spireworld.in, W: www.spireworld.in
Date of Birth ____________________________________________________Nationality__________________________________________
(in case of company, mention date of incorporation)
Spire Techpark Pvt. Ltd.
Correspondence Address ___________________________________________________________________________________________
5-D, Plaza M-6,
Self attested Self attested
District Centre Jasola, _________________________________________________________________________________Pin ________________________
photograph of photograph of
New Delhi – 110 025
Sole/First Applicant Second Applicant Contact No.: Office________________________________Residence_________________________Mobile _________________________
(if applicable) Fax ____________________________________________Email ____________________________________________________________
Subject: Request for registration for furnished space
Permanent Address _______________________________________________________________________________________________
Dear Sir(s),
_________________________________________________________________________________Pin ________________________
I/We, the undersigned, request you to register me/us for allotment on leasehold basis space (particulars of which are given
Phone No. _______________________________________STD/ISD Code ___________________________________________________
herein-below) in Information Technology Park named ‘SPIRE TEC’ to be constructed & developed by you at Plot No. TZ-13A, Sector
Tech Zone, Greater Noida Industrial Development Area, District Gautam Budh Nagar (Uttar Pradesh) PAN_____________________________Ward/Circle/Range (where assessed) ________________________________________________
Residential Status: Resident Non-Resident Indian Foreign National of Indian Origin Others (Please Specify) __________
My/our particulars are given below:
SOLE/FIRST APPLICANT (Compulsory to fill all the details along with passpor t size photograph) Occupation: Service Self Employed Professional Business Retired Housewife Any Other ____________________
Name ____________________________________________________________________________________________________________ Organisation Name & Address ________________________________________________________________________________________
S/W/D of ________________________________________________________________________________________________________ _________________________________________________________________________________Pin ______________________________
(in case of company, mention name and designation of authorized signatory)
Designation________________________________Contact No.:_________________________ Fax _________________________________
Date of Birth ____________________________________________________Nationality__________________________________________
(in case of company, mention date of incorporation)
Correspondence Address ___________________________________________________________________________________________ PARTICULARS OF BOOKING
_________________________________________________________________________________Pin ________________________ 1. Payment plan opted (tick any one of the following):
Contact No.: Office________________________________Residence_________________________Mobile _________________________ 100% Down Payment with 12% Assured Return Plan 50% - 25% - 25% with 11% Assured Return Plan
Fax ____________________________________________Email ____________________________________________________________ 2. Type & Size (in Super Area) : (tick any one)
Type A: Lockable Space measuring _________ Sq. Ft. [either 325 or 525 or 1000 Sq. ft. only]
Permanent Address _______________________________________________________________________________________________
Type B: Unlockable Undivided Space measuring ________ Sq. Ft. [should be in multiples of 100 sq. ft.]
_________________________________________________________________________________Pin ________________________
3. Particulars of Preferential Location: ___________________________________________________________________________________
Phone No. _______________________________________STD/ISD Code ___________________________________________________
4. Consideration [payable as per payment plan opted]:
PAN________________________________Ward/Circle/Range (where assessed) _____________________________________________
Basic price: Rs. ___________________/- (Rupees ____________________________________________________ Only) Per Square Feet
Residential Status: Resident Non-Resident Indian Foreign National of Indian Origin Others (Please Specify) __________
Preferential Location Charges (PLC) : Rs. ____________/- (Rupees________________________________________ Only) Per Square Feet
5. Registration Amount: Rs. ___________________/- (Rupees____________________________________________________ Only) paid via
Occupation: Service Self Employed Professional Business Retired Housewife Any Other ____________________
cheque/draft/pay order bearing No. ________________ dated _____________ drawn on ____________________________________
Organisation Name & Address ________________________________________________________________________________________
If paid by any other mode, please specify: ______________________________________________________________________________
_________________________________________________________________________________Pin ______________________________
I/We have read & understood your attached payment plan and terms & conditions and undertake to be bound by the same. I/We declare
Designation________________________________Contact No.:_________________________ Fax _________________________________ that the particulars given hereinabove are true and correct to my/our knowledge.
Signature of applicant(s) ____________________________ *1sq. ft. = 0.093 sq. mtr. Signature of applicant(s) ____________________________
Page 1 of 10 Page 2 of 10
3. SECOND APPLICANT (If any, compulsory to fill all the details along with passpor t size photograph)
Name ____________________________________________________________________________________________________________
S/W/D of ________________________________________________________________________________________________________
Corporate & Sales Office: 5D, Plaza M6, District Centre, Jasola, New Delhi - 110 025, T: (+91) 11 4051 5600, (+91) 11 4071 4000, (in case of company, mention name and designation of authorized signatory)
Fax: (+91) 11 4051 5601, E: info@spireworld.in, W: www.spireworld.in
Date of Birth ____________________________________________________Nationality__________________________________________
(in case of company, mention date of incorporation)
Spire Techpark Pvt. Ltd.
Correspondence Address ___________________________________________________________________________________________
5-D, Plaza M-6,
Self attested Self attested
District Centre Jasola, _________________________________________________________________________________Pin ________________________
photograph of photograph of
New Delhi – 110 025
Sole/First Applicant Second Applicant Contact No.: Office________________________________Residence_________________________Mobile _________________________
(if applicable) Fax ____________________________________________Email ____________________________________________________________
Subject: Request for registration for furnished space
Permanent Address _______________________________________________________________________________________________
Dear Sir(s),
_________________________________________________________________________________Pin ________________________
I/We, the undersigned, request you to register me/us for allotment on leasehold basis space (particulars of which are given
Phone No. _______________________________________STD/ISD Code ___________________________________________________
herein-below) in Information Technology Park named ‘SPIRE TEC’ to be constructed & developed by you at Plot No. TZ-13A, Sector
Tech Zone, Greater Noida Industrial Development Area, District Gautam Budh Nagar (Uttar Pradesh) PAN_____________________________Ward/Circle/Range (where assessed) ________________________________________________
Residential Status: Resident Non-Resident Indian Foreign National of Indian Origin Others (Please Specify) __________
My/our particulars are given below:
SOLE/FIRST APPLICANT (Compulsory to fill all the details along with passpor t size photograph) Occupation: Service Self Employed Professional Business Retired Housewife Any Other ____________________
Name ____________________________________________________________________________________________________________ Organisation Name & Address ________________________________________________________________________________________
S/W/D of ________________________________________________________________________________________________________ _________________________________________________________________________________Pin ______________________________
(in case of company, mention name and designation of authorized signatory)
Designation________________________________Contact No.:_________________________ Fax _________________________________
Date of Birth ____________________________________________________Nationality__________________________________________
(in case of company, mention date of incorporation)
Correspondence Address ___________________________________________________________________________________________ PARTICULARS OF BOOKING
_________________________________________________________________________________Pin ________________________ 1. Payment plan opted (tick any one of the following):
Contact No.: Office________________________________Residence_________________________Mobile _________________________ 100% Down Payment with 12% Assured Return Plan 50% - 25% - 25% with 11% Assured Return Plan
Fax ____________________________________________Email ____________________________________________________________ 2. Type & Size (in Super Area) : (tick any one)
Type A: Lockable Space measuring _________ Sq. Ft. [either 325 or 525 or 1000 Sq. ft. only]
Permanent Address _______________________________________________________________________________________________
Type B: Unlockable Undivided Space measuring ________ Sq. Ft. [should be in multiples of 100 sq. ft.]
_________________________________________________________________________________Pin ________________________
3. Particulars of Preferential Location: ___________________________________________________________________________________
Phone No. _______________________________________STD/ISD Code ___________________________________________________
4. Consideration [payable as per payment plan opted]:
PAN________________________________Ward/Circle/Range (where assessed) _____________________________________________
Basic price: Rs. ___________________/- (Rupees ____________________________________________________ Only) Per Square Feet
Residential Status: Resident Non-Resident Indian Foreign National of Indian Origin Others (Please Specify) __________
Preferential Location Charges (PLC) : Rs. ____________/- (Rupees________________________________________ Only) Per Square Feet
5. Registration Amount: Rs. ___________________/- (Rupees____________________________________________________ Only) paid via
Occupation: Service Self Employed Professional Business Retired Housewife Any Other ____________________
cheque/draft/pay order bearing No. ________________ dated _____________ drawn on ____________________________________
Organisation Name & Address ________________________________________________________________________________________
If paid by any other mode, please specify: ______________________________________________________________________________
_________________________________________________________________________________Pin ______________________________
I/We have read & understood your attached payment plan and terms & conditions and undertake to be bound by the same. I/We declare
Designation________________________________Contact No.:_________________________ Fax _________________________________ that the particulars given hereinabove are true and correct to my/our knowledge.
Signature of applicant(s) ____________________________ *1sq. ft. = 0.093 sq. mtr. Signature of applicant(s) ____________________________
Page 1 of 10 Page 2 of 10
4. I/we enclose herewith, copies of following documents for your records and reference (for each applicant)
(i) Proof of residence: Voter’s identity cards/Passport/Driving License/Electricity Bill/Nationalised Bank Statement
PAYMENT PLAN
Please confirm the payment plan you have opted for by signing at the end of relevant plan
(ii) PAN Card(s)
100% DOWN PAYMENT PLAN WITH 12% P.A. ASSURED RETURN
(iii) 2 passport size photographs (in addition to the photographs pasted on registration form)
Basic Price : As applicable Registration Amount : Rs. 21,000/- (Rupees Twenty One Thousand Only)
Additional documents in cases of ar tif icial per sons like companies, socie ties e tc. Preferential Location Charges : As applicable Due date for payment of Consideration (after adjusting registration amount): Within 30
days from date of application for registration
(i) Memorandum and Articles of Association
Note:
(ii) Resolution in favour of signatory passed by Board/Governing body (in original) (1) ‘Date of Booking’ will be the date when complete consideration (alongwith service tax) for applicant’s space is actually received by developer (in case of payment
through cheque/draft, the date when amount is credited in developer’s bank account)
Additional documents in cases of par tner ship f ir ms
(2) Service Tax as applicable shall be payable extra in accordance with law.
(i) Partnership deed (3) Consideration payable by applicant(s) shall include basic price plus Preferential Location Charges (if and as applicable)
(ii) Letter of authority signed by all partners in favour of signatory (4) With effect from the date of booking developer will pay returns @ 12% (Twelve Percent) per annum on the amount of consideration received by developer. Taxes
(including Service Tax) on consideration shall not be included for calculating this return. This return shall be payable on monthly basis by 7th day of succeeding
Ad d i t i o n a l d o c u m e n t s i n c a s e s o f F o r e i g n Na t i o n a l s , P I O & N R I s month after deducting TDS. This return shall be inclusive of all Taxes including Service Tax, if applicable on such returns. This return shall be payable till the date of
offer of possession of space. No returns shall be paid on excess payments, if made.
(i) Passport & document regarding payment through NRE/NRO account. (5) Developer represents that the applicant(s) shall receive for a period of three years, with effect from date of offer of possession of applicant’s space by developer, a
minimum of Rs. 51/- (Rupees Fifty One only) per month per square feet (inclusive of all taxes including Service Tax) of applicant’s space towards rent or otherwise
I/we understand that this application for registration shall be treated as complete only when this form is duly filled and signed by in lieu of providing his space for further sub-lease alongwith his share of common amenities and car parking through the developer. During this period of three
applicant(s) and is supported by all the necessary documents mentioned above. I/we understand that unsigned or incomplete application years, CAM Charges shall be paid by occupant of the space. This condition, i.e. Note 5 shall be applicable only if applicant’s space is sub-leased or used by/through
the developer or developer’s nominee only on the terms settled by developer/developer’s nominee.
can be rejected by developer at its sole discretion. I/we confirm that the registration shall be converted into booking only when I/we
(6) In case of joint applicants amounts mentioned in notes (4) and (5) above shall be payable to applicants in following ratio: -
submit a complete application for registration and make the payment of consideration (alongwith service tax as applicable) in accordance
with opted payment plan and you accept the booking. ______% to Mr./Ms. ___________________________________________________________________________________________________________________________
______% to Mr./Ms. ___________________________________________________________________________________________________________________________
(7) Every space of 500 Square Feet (46.45 Square Meter) will come with power backup of 1 KVA load. Additional power backup load will be payable extra as per then
prevailing rates.
Signatures of sole/first applicant Signatures of second applicant (if any)
(With rubber seal in case of a Company) (With rubber seal in case of a Company)
Preferred payment plan Yes No
Name of Signatory _________________________ Name of Signatory _________________________ Signature of Applicant(s)______________________
Designation _______________________________ Designation _______________________________ 50% DOWN PAYMENT PLAN WITH 11% P.A. ASSURED RETURN
Date: __________ Place: ___________________ Date: __________ Place: ___________________ Basic Price : As applicable Registration Amount : Rs. 21,000/- (Rupees Twenty One Thousand Only)
Preferential Location Charges : As applicable First Installment : 50% of Consideration (including registration amount) within 30 days
from date of registration
Booking : Direct by Company Through Dealer/Broker/Facilitator/Intermediary Second Installment : 25% of Consideration within one year from date of booking
Third Installment : 25% of Consideration within two years from date of booking
Declaration by Dealer/Broker/Facilitator/Intermediary (if any)
Note:
I confirm that the Basic Price for this registration is _______________________________________ per square feet. I further confirm that (1) ‘Date of Booking’ will be the date when 50% of consideration for applicant’s space is actually received by developer (in case of payment through cheque/draft, the
the particulars given hereinabove are as per details given to me by the applicant. I understand that this application shall be treated as date when amount is credited in developer’s bank account)
complete only when this form is duly filed and signed by applicant(s) and is supported by all the necessary documents mentioned above. (2) Service Tax as applicable shall be payable extra in accordance with law.
I understand that unsigned or incomplete form can be rejected by you at your sole discretion. (3) Consideration payable by applicant(s) shall include basic price plus Preferential Location Charges (if and as applicable)
(4) With effect from the date of booking, developer will pay returns @ 11% (Eleven Percent) per annum on the amount of consideration received by developer. With
(i) Name: _____________________________________________________________________________________________________ effect from the date of realization of second and third installment developer will also pay returns @ 11% (Eleven Percent) per annum thereon to applicant(s). In no
case returns on amount of second installment shall begin prior to expiry of one year from the date of booking. In no case returns on amount of third installment
(ii) Comments (if any) ____________________________________________________________________________________________ shall begin prior to expiry of two years from the date of booking. Taxes (including Service Tax) on consideration shall not be included for calculating this return. This
return shall be payable on monthly basis by 7th day of succeeding month after deducting TDS. This return shall be inclusive of all Taxes including Service Tax, if
applicable on such returns. This return shall be payable till the date of offer of possession of space. No returns shall be paid on excess payments, if made.
(5) Developer represents that the applicant(s) shall receive for a period of three years, with effect from date of offer of possession of applicant’s space by developer,
Signatures of Dealer/Broker/Facilitator/Intermediary_____________________________________________
a minimum of Rs. 51/- (Rupees Fifty One only) per month per square feet (inclusive of all taxes including Service Tax) of applicant’s space towards rent or
(With rubber seal in case of a Company) otherwise in lieu of providing his space for further sub-lease alongwith his share of common amenities and car parking through the developer. During this period of
three years, CAM Charges shall be paid by occupant of the space. This condition, i.e. Note 5 shall be applicable only if applicant’s space is sub-leased or used
by/through the developer or developer’s nominee only on the terms settled by developer/developer’s nominee.
For office use only (6) In case of joint applicants amounts mentioned in notes (4) and (5) above shall be payable to applicants in following ratio: -
______% to Mr./Ms. __________________________________________________________________________________________________________________________
Application received on (date) ________________________________
______% to Mr./Ms. ___________________________________________________________________________________________________________________________
Application received by : Sales : ________________________________ CRM : __________________________________________________ (7) Every space of 500 Square Feet (46.45 Square Meter) will come with power backup of 1 KVA load. Additional power backup load will be payable extra as per then
prevailing rates.
Special remarks (if any) _____________________________________________________________________________________________
Preferred payment plan Yes No
_________________________________________________________________________________________________________________
Signature of Applicant(s)______________________
Page 3 of 10 Page 4 of 10
5. I/we enclose herewith, copies of following documents for your records and reference (for each applicant)
(i) Proof of residence: Voter’s identity cards/Passport/Driving License/Electricity Bill/Nationalised Bank Statement
PAYMENT PLAN
Please confirm the payment plan you have opted for by signing at the end of relevant plan
(ii) PAN Card(s)
100% DOWN PAYMENT PLAN WITH 12% P.A. ASSURED RETURN
(iii) 2 passport size photographs (in addition to the photographs pasted on registration form)
Basic Price : As applicable Registration Amount : Rs. 21,000/- (Rupees Twenty One Thousand Only)
Additional documents in cases of ar tif icial per sons like companies, socie ties e tc. Preferential Location Charges : As applicable Due date for payment of Consideration (after adjusting registration amount): Within 30
days from date of application for registration
(i) Memorandum and Articles of Association
Note:
(ii) Resolution in favour of signatory passed by Board/Governing body (in original) (1) ‘Date of Booking’ will be the date when complete consideration (alongwith service tax) for applicant’s space is actually received by developer (in case of payment
through cheque/draft, the date when amount is credited in developer’s bank account)
Additional documents in cases of par tner ship f ir ms
(2) Service Tax as applicable shall be payable extra in accordance with law.
(i) Partnership deed (3) Consideration payable by applicant(s) shall include basic price plus Preferential Location Charges (if and as applicable)
(ii) Letter of authority signed by all partners in favour of signatory (4) With effect from the date of booking developer will pay returns @ 12% (Twelve Percent) per annum on the amount of consideration received by developer. Taxes
(including Service Tax) on consideration shall not be included for calculating this return. This return shall be payable on monthly basis by 7th day of succeeding
Ad d i t i o n a l d o c u m e n t s i n c a s e s o f F o r e i g n Na t i o n a l s , P I O & N R I s month after deducting TDS. This return shall be inclusive of all Taxes including Service Tax, if applicable on such returns. This return shall be payable till the date of
offer of possession of space. No returns shall be paid on excess payments, if made.
(i) Passport & document regarding payment through NRE/NRO account. (5) Developer represents that the applicant(s) shall receive for a period of three years, with effect from date of offer of possession of applicant’s space by developer, a
minimum of Rs. 51/- (Rupees Fifty One only) per month per square feet (inclusive of all taxes including Service Tax) of applicant’s space towards rent or otherwise
I/we understand that this application for registration shall be treated as complete only when this form is duly filled and signed by in lieu of providing his space for further sub-lease alongwith his share of common amenities and car parking through the developer. During this period of three
applicant(s) and is supported by all the necessary documents mentioned above. I/we understand that unsigned or incomplete application years, CAM Charges shall be paid by occupant of the space. This condition, i.e. Note 5 shall be applicable only if applicant’s space is sub-leased or used by/through
the developer or developer’s nominee only on the terms settled by developer/developer’s nominee.
can be rejected by developer at its sole discretion. I/we confirm that the registration shall be converted into booking only when I/we
(6) In case of joint applicants amounts mentioned in notes (4) and (5) above shall be payable to applicants in following ratio: -
submit a complete application for registration and make the payment of consideration (alongwith service tax as applicable) in accordance
with opted payment plan and you accept the booking. ______% to Mr./Ms. ___________________________________________________________________________________________________________________________
______% to Mr./Ms. ___________________________________________________________________________________________________________________________
(7) Every space of 500 Square Feet (46.45 Square Meter) will come with power backup of 1 KVA load. Additional power backup load will be payable extra as per then
prevailing rates.
Signatures of sole/first applicant Signatures of second applicant (if any)
(With rubber seal in case of a Company) (With rubber seal in case of a Company)
Preferred payment plan Yes No
Name of Signatory _________________________ Name of Signatory _________________________ Signature of Applicant(s)______________________
Designation _______________________________ Designation _______________________________ 50% DOWN PAYMENT PLAN WITH 11% P.A. ASSURED RETURN
Date: __________ Place: ___________________ Date: __________ Place: ___________________ Basic Price : As applicable Registration Amount : Rs. 21,000/- (Rupees Twenty One Thousand Only)
Preferential Location Charges : As applicable First Installment : 50% of Consideration (including registration amount) within 30 days
from date of registration
Booking : Direct by Company Through Dealer/Broker/Facilitator/Intermediary Second Installment : 25% of Consideration within one year from date of booking
Third Installment : 25% of Consideration within two years from date of booking
Declaration by Dealer/Broker/Facilitator/Intermediary (if any)
Note:
I confirm that the Basic Price for this registration is _______________________________________ per square feet. I further confirm that (1) ‘Date of Booking’ will be the date when 50% of consideration for applicant’s space is actually received by developer (in case of payment through cheque/draft, the
the particulars given hereinabove are as per details given to me by the applicant. I understand that this application shall be treated as date when amount is credited in developer’s bank account)
complete only when this form is duly filed and signed by applicant(s) and is supported by all the necessary documents mentioned above. (2) Service Tax as applicable shall be payable extra in accordance with law.
I understand that unsigned or incomplete form can be rejected by you at your sole discretion. (3) Consideration payable by applicant(s) shall include basic price plus Preferential Location Charges (if and as applicable)
(4) With effect from the date of booking, developer will pay returns @ 11% (Eleven Percent) per annum on the amount of consideration received by developer. With
(i) Name: _____________________________________________________________________________________________________ effect from the date of realization of second and third installment developer will also pay returns @ 11% (Eleven Percent) per annum thereon to applicant(s). In no
case returns on amount of second installment shall begin prior to expiry of one year from the date of booking. In no case returns on amount of third installment
(ii) Comments (if any) ____________________________________________________________________________________________ shall begin prior to expiry of two years from the date of booking. Taxes (including Service Tax) on consideration shall not be included for calculating this return. This
return shall be payable on monthly basis by 7th day of succeeding month after deducting TDS. This return shall be inclusive of all Taxes including Service Tax, if
applicable on such returns. This return shall be payable till the date of offer of possession of space. No returns shall be paid on excess payments, if made.
(5) Developer represents that the applicant(s) shall receive for a period of three years, with effect from date of offer of possession of applicant’s space by developer,
Signatures of Dealer/Broker/Facilitator/Intermediary_____________________________________________
a minimum of Rs. 51/- (Rupees Fifty One only) per month per square feet (inclusive of all taxes including Service Tax) of applicant’s space towards rent or
(With rubber seal in case of a Company) otherwise in lieu of providing his space for further sub-lease alongwith his share of common amenities and car parking through the developer. During this period of
three years, CAM Charges shall be paid by occupant of the space. This condition, i.e. Note 5 shall be applicable only if applicant’s space is sub-leased or used
by/through the developer or developer’s nominee only on the terms settled by developer/developer’s nominee.
For office use only (6) In case of joint applicants amounts mentioned in notes (4) and (5) above shall be payable to applicants in following ratio: -
______% to Mr./Ms. __________________________________________________________________________________________________________________________
Application received on (date) ________________________________
______% to Mr./Ms. ___________________________________________________________________________________________________________________________
Application received by : Sales : ________________________________ CRM : __________________________________________________ (7) Every space of 500 Square Feet (46.45 Square Meter) will come with power backup of 1 KVA load. Additional power backup load will be payable extra as per then
prevailing rates.
Special remarks (if any) _____________________________________________________________________________________________
Preferred payment plan Yes No
_________________________________________________________________________________________________________________
Signature of Applicant(s)______________________
Page 3 of 10 Page 4 of 10
6.
7. TERMS AND CONDITIONS 19. Applicant(s) understands and agrees that following charges shall always be attached to said space–
Following terms and conditions are attached with application for registration for allotment of furnished space (i.e., said space) on leasehold basis in Information Technology Park named a) Common area maintenance charges (i.e., CAM) [For providing common services and facilities in said space]
‘SPIRE TEC’ (i.e., said complex) to be constructed & developed by M/s. Spire Techpark Private Limited, 5-D, Plaza M-6, District Centre, Jasola, New Delhi (i.e., developer) at Plot No. TZ-13A,
b) Contribution to Sinking Fund [This fund will be used for major repairs or replacement or purchase of new equipments for common use]
Sector Tech Zone, Greater Noida Industrial Development Area, District Gautam Budh Nagar (Uttar Pradesh) (i.e., said plot) and these are indicative terms and conditions of allotment.
c) Interest Free Maintenance Security
1. Applicant(s) has checked, verified and appraised himself with all laws, rules, regulations, notifications, circulars, policies of Government including those of Greater Noida Industrial
d) Charges for consumption of water
Development Authority (i.e., “GNIDA”) applicable on said plot & on said complex and also the developer’s authorities & entitlements to develop and market said complex.
e) Cost of insurance of building of said complex
2. Applicant(s) understands and agrees that building plans for said complex; specifications, quality, standard & quantity of material to be used in construction of said complex and
nature of facilities to be provided in said complex shall be exclusively determined by developer. Applicant(s) shall have no say in these regards. 20. Charges mentioned in clause 19 shall be payable to maintenance agency nominated/appointed by developer for rendering common services in said complex. These charges shall
be in accordance with then prevailing industry standards. These charges shall be payable with effect from expiry of thirty days from the date of offer of possession by developer.
3. Amount equivalent to twenty percent of total basic price shall be deemed to be ‘earnest money’ for the said space. This earnest money shall stand forfeited by developer in case of
In case applicant(s) is allotted lockable space, these charges shall be payable by applicant(s) and in case applicant(s) are allotted unlockable space these charges shall be payable
non fulfillment of these terms & conditions and also those of other documents/indentures executed between applicant(s) and developer in respect of said space.
by occupant/lease facilitation centre.
4. Size of said space mentioned in accompanying application is tentative. However, developer shall endeavor that size of said space does not vary by more than fifteen percent from
21. Consideration/Price for said space and all other charges including CAM charges shall be calculated on the basis of ‘super area’. ‘Super area’ includes the area of said space and
what has been stated in accompanying application. In any case accounts will be settled on the basis of actual super area which applicant(s) will finally get.
proportionate share of common areas/spaces in said complex. Total efficiency of a floor plate will be about 65%-70% of total super area of that undivided floor plate.
5. Consideration for said space payable by applicant(s) shall include Basic Price and Preferential Location Charges [if and as applicable]. All Statutory Charges, Taxes, Fees, etc.
22. Developer shall execute agreement to lease regarding allotment of said space only after receiving 100% or 50% of total consideration (with service tax) as per applicable payment
(by whatever name they be called) applicable on said space or on any payment made by applicant(s) or on any amount to be paid to applicant(s) shall be borne and paid by
plan. However, prior to execution of agreement to lease, developer may at any stage and at any time reject/cancel the applicant’s application for registration unilaterally without
applicant(s). If such Statutory Charges, Taxes, Fees, etc. are payable for the said complex as a whole, applicant(s) shall pay the same in proportion to the Super Area of said space.
assigning any reason whatsoever and in case of such rejection/cancellation by developer, applicant(s) will be entitled only to the refund of amount paid by him to developer without
6. Timely payment by applicant(s) of installments of consideration/price for allotment of said space, as per applicable payment plan is essence of this transaction. In case of delay in
any interest/penalty/damages/compensation.
payment, applicant(s) shall be liable to pay interest @ 18% per annum on defaulted amount for delayed period. However, if any amount remains unpaid for a period of 60 (sixty) days
23. In case prior to execution of aforesaid agreement to lease, applicant(s) wishes to get the accompanying application/booking cancelled or reduce the area of said space,
from its due date for any reason whatsoever, developer shall have the right to cancel the booking/allotment. Any payment made by applicant(s) shall be first adjusted towards
applicant(s) shall be liable to pay a sum of Rupees Eleven Thousand Only to developer towards administrative charges. After execution of agreement to lease, applicant(s) shall not
outstanding interest and than towards basic price/preferential location charges.
be entitled to reduce the area of said space or seek cancellation of allotment/agreement. Developer shall not be liable to refund any portion of the money/consideration received
7. Applicant(s) shall make all payments towards consideration/price for allotment of said space by way of cheques/drafts/pay orders issued in favour of M/s. Spire Techpark Private Limited
from applicant(s). However developer may in its sole discretion/prerogative accept applicant(s) request (if any) to cancel the allotment/Lease/agreement but in such a situation
(payable at New Delhi). All cheques/drafts/pay orders shall be deemed to be accepted by developer subject to their realization only.
developer shall be entitled to forfeit the earnest money for the whole unit (in case of cancellation). Developer shall also be entitled to deduct all discounts availed by applicant(s) and
8. Applicant(s) shall be entitled to get returns/rent as per details given in payment plan opted by applicant(s), provided the applicant(s) has made the complete payment at all stages commissions/incentives paid by developer to the broker for applicant(s) allotment/agreement. Allottee shall not be entitled to claim any interest or appreciation from developer.
in accordance with said payment plan. In case of default in payments as per payment plan opted by applicant(s), developer shall be released/discharged from its all liabilities to pay After the execution of sub-lease deed no cancelation or refund shall be made under any circumstances, whatsoever.
returns/rent to applicant(s). However if applicant(s) subsequently makes the due payment with interest, developer shall resume payment of assured return/rent as per said
24. Foreign applicant(s), applicant(s) having NRI/PIO status shall himself be exclusively responsible to comply with necessary formalities as laid down in Foreign Exchange Management
payment plan from the date applicant(s) clears its all dues with interest. Amount of interest paid by applicant(s) shall never be included for calculation of assured return.
Act, Reserve Bank of India Act and/or any other law governing this transaction including remittance of payments in India and acquisition of immovable properties in India. It shall be
9. Subject to compliance of all terms & conditions of allotment by applicant(s) and also subject to payment of total consideration/price & other charges applicable on said space by the sole responsibility of applicant(s) to ensure that payment is remitted only through authorised accounts/channels. Developer shall not be responsible in any manner if any third
applicant(s), developer shall effect/cause execution of sub-lease deed of said space in due course. It shall be valid till 31st December, 2096. It may be further extended in party makes any payment/remittances on behalf of applicant(s) and developer shall issue payment receipts in favour of applicant(s) only. All financial and penal consequences
accordance with norms and approvals of GNIDA and developer. All expenses (including Stamp Duty) involved in its registration including renewals thereof (if any) shall be borne by (if any) for violation of any law or rule shall be borne exclusively by applicant(s) himself. In case it is ever found that any provision of any applicable law is not complied with, allotment
applicant(s). of said space shall be liable to be cancelled and in such a situation developer shall be entitled to forfeit earnest money and shall refund, without any interest, the remaining amount
(if any) paid by the applicant(s) to the developer for said space after deducting broker’s commissions/discounts.
10. Since construction of said complex is a large project, developer shall construct the same in Phases. Irrespective of whether construction of other phase(s) is complete or not,
developer will offer possession of said space after completion of construction of phase, wherein said space situates. Applicant(s) shall never have any objection to developer 25. Developer shall send all letters/notices and communications to the sole/first applicant(s) at his address given in the application form through registered/speed post or through
constructing or continuing with the construction of remaining structures in said complex or other buildings adjoining the said space. All major common facilities shall be completed courier. All such letters/notices and communications so sent to the sole/first applicant(s) shall be deemed to have been duly received by all applicants within 5 (five) days from the
and provided only after completion of construction of all phases. However all services necessary for making use of said space like air-conditioning, power backup, etc. shall be date of dispatch. Developer shall not be liable to send separate communication, letters and notices to the second applicant(s) or to applicant(s) other than the first applicant(s).
activated at the time of delivery of possession of said space.
26. No one, (including any broker/dealer or even any employee of developer) is authorised to make any concession in any of the terms and conditions contained herein. Developer shall
11. Applicant(s) understands that expression ‘Lockable space’ shall mean space which is enclosed between walls made from such material as may be considered appropriate by not be bound by any oral or written commitments beyond the scope of these terms and conditions made by any person including any broker or employee of developer.
developer with door for ingress/egress. Expression ‘Unlockable space’ shall mean undivided space in said complex.
27. For all intents and purposes including for interpretation of these terms and conditions a word or an expression which denotes a natural person shall include an artificial person
12. Allottee(s) of Lockable Spaces must take the possession of said space within thirty days from the date of offer of possession and shall be entitled to use only the covered area of (and vice versa), any one gender shall include other genders, singular shall include plural (and vice versa).
said space. Allottee(s) of Unlockable and Undivided Space will not get the actual physical possession of their space. All Unlockable spaces in the complex shall be controlled and
28. This transaction shall be governed by laws of India.
managed by Lease Facilitation Centre, which will be a body of allottees and may be constituted as a ‘Company’, ‘Trust’ or ‘Society’ on in any other form. Lease Facilitation Centre shall
29. Developer has informed the applicant(s) that GNIDA has allotted said plot to M/s. Sundaram I. T. Parks Private Limited on lease for setting up an Information Technology Park.
either use or allow use or further sub-lease the unlockable spaces for common benefits of its members/allottees and shall after deducting its total expenses and brokerage/fees
Said M/s Sundaram I. T. Parks Private Limited entered into an agreement with developer by virtue of which developer got rights to setup and market Information Technology Park
paid, distribute the income generated from use/further sub-lease of unlockable units/spaces amongst the allottees of unlockable units as per its rules. Lease Facilitation Centre
on said plot. Accordingly developer is developing said complex on said plot. Allottee has satisfied himself with developer’s authorities & entitlements to develop and market said complex.
shall be established prior to execution of sub-lease deed of said space and applicant(s) shall cooperate with developer in all ways for establishing said body including by way of
execution of necessary documents. In case applicant(s) fails to cooperate with developer in establishing said body or fails to execute/provide necessary documents, developer will 30. In case of any dispute between the parties hereto (including their successors) concerning accompanying application or matters arising there from, the same shall be adjudicated
be immediately released/discharged from its all liabilities towards applicant(s). by way of arbitration, which shall be conducted by an arbitrator nominated by developer. Venue of arbitration shall be at New Delhi. Arbitration shall be conducted in accordance
with Indian Arbitration and Conciliation Act, 1996. It is clarified that if due to any law or any other reason, this arbitration clause could not be enforced in the same manner as has
13. Developer will give possession of said space in finished condition i.e., ready to move in state with flooring, ceiling, painting and internal wiring done. Developer will provide furniture
been stated herein, it will be considered that there is no arbitration clause/agreement between the parties.
and equipments as per details given in Payment Plan. Interior decoration, specifications and brands of furniture, fittings, equipments etc. to be provided by developer, shall be of
developer’s choice only and in case of any defect in said furniture, fittings, equipments etc. applicant(s) shall make the complaint directly to the concerned service centers at their
own costs and responsibility. Use of these furniture, fittings, equipments etc. by sub-lessee/occupant shall be subject to wear and tear thereof, for which developer shall have no
responsibility.
14. Developer shall endeavor to offer possession of said space within a period of three years from the date of execution of agreement to lease between developer and applicant(s). Save
what has been stated in applicable payment plan, developer shall never be liable to pay any damages/compensation/penalty/interest in case of any delay in construction of
concerned phase of said complex or delay in offer of possession of said space. Signatures of sole/first applicant Signatures of second applicant (if any)
15. Developer shall be always free to raise/construct additional floor/units in the building or any additional structure in said complex and to transfer the same to such person(s) on (With rubber seal in case of a Company) (With rubber seal in case of a Company)
such terms and conditions, which the developer may deem fit and proper. Developer shall be always free to change the lay-out plans, building plans and/or floor plans of
Name of Signatory _________________________ Name of Signatory _________________________
buildings/structures in said complex in such manner, which the developer may deem fit and proper. Applicant(s) shall never have any objections in these regards.
16. Said space will be a part of Information Technology Park and can be used only for IT/ITES activities as accepted/approved by Government of Uttar Pradesh and GNIDA. Designation _______________________________ Designation _______________________________
17. Applicant(s) shall not be entitled to transfer/assign his rights/claims/interests in said space without prior written approval of the developer. Developer may in its sole discretion, Date: __________ Place: ___________________ Date: __________ Place: ___________________
permit such transfer/assignment on such terms and conditions (including levying of transfer fees/charges) as it may deem fit and proper. However, there will be no transfer fee for
the first transfer of said space.
18. Subject to prior written approval of developer, allottee of lockable space shall have the right to grant further sub-lease of said space, which shall always be subject to terms and
conditions of lease deed executed by GNIDA and sub-lease deed referred to in clause 9, above.
Signature of Applicant(s)______________________ Signature of Applicant(s)______________________
Page 7 of 10 Page 8 of 10