Selection Guide Price List 2014

SELECTION GUIDE
Price List 2014

CONTENTS
Welcome to Gunnebo 3
Choosing a product 4
Chubbsafes 6
Air 8
Water 9
Earth 10
Fire 11
Counter Unit 12
Epsilon 13
ForceGuard 14
AlphaPlus 15
Cobra 16
Zeta 17
Deca 18
Cobra Pro 19
Evolve 20
DuoGuard 22
ProGuard 22
Trident 24
Sigma Deposit 26
Omega Deposit 27
Sovereign Deposit 28
ProGuard DT 29
Profile NT 30
Archive Cabinet 31
Executive 32
Duplex 33
Office 34
Record Protection Cabinet 35
DataGuard NT 36
DataPlus 37
Centurion Vault 38
Centurion Door 39
ModuleGuard 40
MagTek A 41
Churchill 42
Magpie Wall Safe 44
Domestic 45
Vector 46
Bulldog 400 47
Sapphire 48
Ruby 49
Emerald 50
Notes 51
Rosengrens 52
2000C Safe Deposit Lockers 54
Sargasso 56
Notes 57
Terms & Conditions 58
Eurosafe is an association of safe
manufacturers in mainland Europe
established over 25 years ago. A
sister organisation, Eurosafe UK was
launched in March 2011 to
represent the interests of British
safe makers, and the suppliers and
installers of safes and security
containers
The primary objective of Eurosafe
UK is to restore confidence in
European standards for testing and
rating cash safes, security cabinets,
document fire safes and computer
data safes.
Eurosafe UK will encourage insurers,
specifiers, buyers and users to
choose cash safes tested and
certified by the BRE/LPCB in the UK
or European test houses affiliated
with the European Fire & Security
Group (EFSG) or those products
certified by the European Certifica-
tion Board•Security (ECB•S).
Member companies will campaign
to resist the lowering of security
standards by manufacturing and
supplying high quality, insurance
approved products.
Those companies specialising in
refurbishing used safes undertake
to adhere strictly to BS7582: 2005
Code of practice for reconditioning
of used safes.
Member companies will be
encouraged to display the Eurosafe
logo as a symbol of quality and
ethical standards.
OUR ICONS EXPLAINED
TOP SELLER
NEW
Top selling product Key lock Burglary protection
Fire protection for
paper documents
New product
for 2014
Electronic lock
Fire protection for
data media
Explosives protection
Approved by
The Association of
Insurance Surveyors

Selection Guide 2014 3
Our product range
Gunnebo is acknowledged as a worldwide leader in security products with a reputation of excellence in quality, reliability and
optimum security. This approach is reflected in the nature of the product range.
Each of the products have been designed, manufactured and tested to benefit you. The result is a flexible and customisable
range of safes, cabinets and vaults. Such a comprehensive product range means that finding a security solution is a simple
process. After all, we do want to solve your problem.
Chubbsafes ...the premier cash & fire protection brand
Domestic users, retailers and banks are forever reviewing the secure storage of cash and
valuables within their environments. Faced with increasing threats to security, users are
constantly striving for products of the highest quality, reliability and technical specification.
Such products can be easily found within the Chubbsafes range. Choice doesn’t end once you
have selected the safe or cabinet that is perfect for you. Each solution can be customised with
a host of options (e.g. locking, fittings and deposit facilities) to meet your security needs.
Churchill Safes ...the premier underfloor safe brand
Churchill Safes are recognised as the leading brand for underfloor safes. Such success is based
upon understanding the security market and meeting customer needs. This commitment
and initiative is reflected in the Churchill Safes product range. Products vary from a small wall
safe to high security underfloor safes. Such a comprehensive range means that finding an
underfloor solution is a simple process.
Rosengrens ...the premier document protection brand
For every business protection of documentation is of paramount importance. Losing this
invaluable information can lead to a disastrous impact on the business.
Common outcomes include the loss of clients and a decline in capacity to attain new business.
With the Rosengrens product range you are sure to find a flexible and secure solution.
Combining unique design and innovative features, each safe or cabinet ensures that your
documents are securely protected to the highest standards.
WELCOME TO THE GUNNEBO
Selection Guide 2014

Picking a new safe for the home or business can be a struggle, especially
when you don’t know where to start.
With Gunnebo, you can be assured that we will guide you carefully
through the selection process, a process which begins by identifying
your security objectives. Once complete, a number of suitable security
solutions will be offered and comprehensive support given regarding
the delivery and installation of the safe.
All in all, Gunnebo aims to make sure the selection process is a flexible,
simple and thorough one.
PLANNING, DELIVERY & INSTALLATION
The complete service
Once you have selected a safe or cabinet, Gunnebo can offer you a
comprehensive installation survey (for certain products only). Gunnebo
will then agree with you a flexible installation schedule. The flexibility
of the installation process is evidence of Gunnebo’s commitment
towards ensuring the cost and time efficient completion of your purchase.
Gunnebo products are delivered and installed by trained Gunnebo
installers. Whatever the delivery environment (e.g. large bank or small
office), you can be assured that the installers will take the greatest care.
We are also focused on making sure the service on offer is achievable,
to the highest standards of workmanship and is promptly completed
within the contracted timescales.
CHOOSING A PRODUCT
IS SIMPLE

DEFINITIONS
Key Lock: A manual key operated lock.
Mechanical Combination: A mechanical keyless dial lock with a
changeable combination.
Electronic Lock: An electronically operated keypad lock with a
changeable combination.
Manager Mode: Allows one user to control the functions of other
combination holders.
Number of Users: The number of users able to program in their own
access code.
Duress Feature: It is possible for an alarm engineer to link the lock
into a monitored alarm system. It is then possible, by a given
procedure, to operate the lock, open the safe and silently signal to the
monitoring station that this is being done under duress.
Time Delay: This feature allows for a pre-set delay between operating
the lock and being able to open the safe. The operation may vary
between lock types.
Time Lock: Time lock allows the user to set periods during which the
lock may be operated, e.g. during business hours only. The options
available will vary between locks.
Audit Trail: The lock is able to give a report (it will vary in detail from
model to model) of usage and may show times of operation, codes
used and operations performed.
Dual Control: Allows two users to enter their details before any
operation can be performed.
Customisation
Dependant on the product grade or size, most safes or cabinets can have a
different lock (e.g. electronic), deposit option (e.g. front facing drawer trap) or
fitting (e.g. cupboard) to meet your customer requirements. For example, the
DataPlus can include pullout drawers so that it can hold more CDs, DVDs or
diskettes.
For further details and technical information regarding customisation please
feel free to contact Gunnebo or your local authorised dealer. As always,
Gunnebo will endeavour to provide a customisation solution which meets
your expectations.
Locking Options
As mentioned, Gunnebo can customise your safe or cabinet with a different
lock.
Our comprehensive lock range includes the latest industry locks which offer a
wide range of features. So whether it be the “mechanical combination”lock
or a more hi-tech electronic solution, Gunnebo are sure to have a lock which
will meet your security needs. We have explained the key terms associated
with locks below.
If you have any additional questions please contact Gunnebo or your local
Gunnebo Authorised Dealer.
CHOOSING THE RIGHT PRODUCT
To find out which product is most suitable for your security requirements you
need to answer the following questions:
1. What do you want to protect?
Cash, Valuables, Documents or Data media
2. What is the volume or size that you want to protect?
Having done this you can either choose from BRE (Burglary Resistant
Equipment) or FRE (Fire Resistant Equipment) products. The BRE range
includes safes, cabinets and vaults designed to protect cash and valuables.
Available in differing sizes and specifications our safes offer optimum
protection for up to £150,000 or £1,500,000 in valuables.
The FRE range includes files and cabinets designed to protect against fire.
You can either protect data media or documents and in some cases a mixture
of both. These products are rated according to their level of fire protection.
Cash Rating
Cash Rating is “The amount an insurance company will cover in a safe/
cabinet overnight.“
The actual amount of cover can vary between insurance companies and
locations and may be different to the manufacturer’s recommended rating. If
this is important to you, you should check what cover your insurance company
will offer.
As a general rule, this rating is multiplied by a factor of 10 for jewellery. Hence,
a Duoguard Grade I with a cash rating of £10,000 will store jewellery in
domestic circumstances worth up to £100,000.
Fire Protection
Measured through tests carried out by Independent testing authorities.
“The longer the period in minutes, the greater the fire resistance offered. The
critical temperature before paper documents combust is 177°C. Whereas,
data media is damaged at temperatures over 52°C or humidity over 85%.”
Care should be taken to ensure that the test certificate held by the
equipment is applicable to modern media i.e a DIS label.
Testing
To provide the appropriate level of protection for our products, Gunnebo
ensures that they are tested against the latest industry standards. These
standards vary according to whether you want to protect data media or
documents. This is because the temperature at which data media (e.g. 52 °C)
and documents (e.g. 177 °C) deteriorate differs according to the item protected.
In order to fully protect data media, industry standards indicate that products
should carry ECB•S EN 1047-1 or NT Fire 017 60/120 DIS.
The ECB•S test monitors the internal temperature of the data cabinet until it
has completely cooled down during the “soak-out”period. Assessing products
during this period is essential since internal temperatures can peak up to 6 to
8 hours after a fire has been extinguished. Such a test ensures that all products
are comprehensively tested and upon passing, will fully protect your data media
for the 60 or 120 minutes stated.
For document protection all products must have an appropriate industry
standard 30 minute paper certificate as a minimum.
EN 15659 (30 P), UL72-Class 350, ECB•S EN 1047-1 or NT Fire 017 are
acceptable standards for paper document protection.

...the premier cash fire protection brand
Domestic users, retailers and banks are forever reviewing the secure
storage of cash and valuables within their environments. Faced with
increasing threats to security, users are constantly striving for products of
the highest quality, reliability and technical specification. Such products
can be easily found within the Chubbsafes range. Choice doesn’t end once
you have selected the safe or cabinet that is perfect for you. Each solution
can be customised with a host of options (e.g. locking, fittings and deposit
facilities) to meet your security needs.
Visit Gunnebo UK on LinkedIn
www.chubbsafes.com

8 Selection Guide 2014
air
£1,000 cash rating
Model above is Air Laptop
View the product videos on
our YouTube channel
www.youtube.com/chubbsafes
Key Features
• Compact safe for the home or office
• Recommended cash rating of £1000
• Suitable for storage of valuables such as jewellery and cameras
• Choice of key lock or electronic lock
• Steel door and body with dual, plated steel moving boltwork
• Two sizes available – 9 and 16 litres – as well as special models for hotels and laptop storage
• Removable shelf in Air 15
Model
External (mm)
Height Width Depth*
Internal (mm)
Height Width Depth
Volume
(litres)
Weight
(kg)
Cash
Rating
Retail
Price
Delivery
Price
Aldridge
Product
Code
Key Lock
Air 10K 200 310 200 190 300 150 9 7 £1,000 £69 £21 L18857
Air 15K 250 350 250 240 340 200 16 10 £1,000 £82 £21 L18859
Electronic Lock
Air 10E 200 310 200 190 300 150 9 7 £1,000 £89 £21 L18858
Air 15E 250 350 250 240 340 200 16 10 £1,000 £110 £21 L18860
Air: Laptop 200 430 350 190 420 300 24 12 £1,000 £126 £21 L18861
Air: Hotel** 200 430 350 190 420 300 24 12 £1,000 £189 £21 L18862
* Lock and handle projection 35mm NB. If base or rear fixing is ordered customer could be asked to sign a disclaimer at time of delivery
** CEU unit and software available at an additional cost
BRE–BurglaryResistantEquipment
For your safe spares please contact Gunnebo Safe Spares on 07919 015975 or 01902 271378
You can now buy spares online www.safespares.co.uk
Available through our preferred distributor – Aldridge Security
Tel: 08444 125 101 (Landline), 03444 125101 (Mobile), Ireland 01 647 0048
E-Mail: sales@aldridgesecurity.co.uk
Web: www.aldridgesecurity.co.uk
Fax: London 0800 137 933, Manchester 0800 137 932, Ireland 01 647 0049
Visit www.chubbsafeselements.com
to find out more
Scan the QR-code with your smartphone
for quick access to the site!

water
£2,000 cash rating
Key Features
• Cash rating of £2000
• Certified by ECB•S according to EN 14450 Level S1 for burglary protection
• Suitable for storage of valuables such as jewellery, cameras or other valuable equipment
• Steel door and body with reinforced bolts and anti-drilling plate for extra protection
• Four sizes available – capacity from 29 to 51 litres
• One removable shelf as standard
• Interior LED light on electronic lock models
Model above is Water 40E
our YouTube channel
Model
External (mm)
Height Width Depth*
Internal (mm)
Height Width Depth
Volume
(litres)
Weight
(kg)
Cash
Rating
Retail
Price
Drop off
Delivery
Price**
Delivery
Position
Price
Aldridge
Product
Code
Key Lock
Water 30K 275 375 350 269 369 294 29 31 £2,000 £225 £21 £115 L18863
Water 40K 375 375 350 369 369 294 40 36 £2,000 £269 £60 £115 L18865
Water 50-1K 375 475 350 369 469 294 51 43 £2,000 £312 £60 £115 L18867
Water 50-2K 475 375 350 469 369 294 51 43 £2,000 £344 £60 £115 L18869
Electronic Lock
Water 30E 275 375 350 269 369 294 29 31 £2,000 £387 £21 £115 L18864
Water 40E 375 375 350 369 369 294 40 36 £2,000 £430 £60 £115 L18866
Water 50-1E 375 475 350 369 469 294 51 43 £2,000 £492 £60 £115 L18868
Water 50-2E 475 375 350 469 369 294 51 43 £2,000 £512 £60 £115 L18870
** Drop off delivery to a kerbside location
EN 14450
S1
EN 1300 EN 1300
to find out more

earth
£4,000 cash rating
Key Features
• Cash rating of £4000
• Certified by ECB•S according to EN 14450 Level S2 for burglary protection
• Body consists of two steel plates filled in-between with a fire-retardant material
• Four sizes available – 15, 38, 54 and 76 litres
• Interior LED light on electronic lock models
Model
External (mm)
Height Width Depth*
Internal (mm)
Height Width Depth
Volume
(litres)
Weight
(kg)
Cash
Rating
Retail
Price
Drop off
Delivery
Price**
Delivery
Position
Price
Aldridge
Product
Code
Key Lock
Earth 15K 300 370 350 210 280 250 15 38 £4,000 £239 £60 £115 L18871
Earth 40K 440 450 400 350 360 300 38 60 £4,000 £344 £60 £115 L18873
Earth 55K 590 450 400 500 360 300 54 76 £4,000 £401 £60 £115 L18875
Earth 75K 790 450 400 700 360 300 76 92 £4,000 £466 £60 £115 L18877
Electronic Lock
Earth 15E 300 370 350 210 280 250 15 38 £4,000 £428 £60 £115 L18872
Earth 40E 440 450 400 350 360 300 38 60 £4,000 £495 £60 £115 L18874
Earth 55E 590 450 400 500 360 300 54 76 £4,000 £644 £60 £115 L18876
Earth 75E 790 450 400 700 360 300 76 92 £4,000 £666 £60 £115 L18878
EN 14450
S2
EN 1300 EN 1300
Model above is Earth 15E
our YouTube channel
to find out more

fire
£4,000 cash rating
Key Features
• Combined fire and burglary protection in one safe
• Perfect for the protection of cash and valuables as well as passports, property records,
legal papers and other important documents
• Certified by ECB•S for 30 minutes fire-resistance (EN 15659, 30 P)
• Certified by ECB•S for Level S2 burglary protection (EN 14450)
• Four sizes available – 18, 26, 31 and 51 litres
Model
External (mm)
Height Width Depth*
Internal (mm)
Height Width Depth
Volume
(litres)
Weight
(kg)
Fire
Rating
(mins)
Cash
Rating
Retail
Price
Drop off
Delivery
Price**
Delivery
Position
Price
Aldridge
Product
Code
Key Lock
Fire 20K 315 445 440 185 334 290 18 52 30 £4,000 £281 £60 £115 L18962
Fire 25K 490 360 440 360 249 290 26 62 30 £4,000 £360 £60 £115 L18963
Fire 30K 460 440 440 330 329 290 31 68 30 £4,000 £378 £60 £115 L18964
Fire 50K 670 440 440 540 329 290 51 91 30 £4,000 £459 £60 £115 L18965
Electronic Lock
Fire 20E 315 445 440 185 334 290 18 52 30 £4,000 £442 £60 £115 L18958
Fire 25E 490 360 440 360 249 290 26 62 30 £4,000 £521 £60 £115 L18959
Fire 30E 460 440 440 330 329 290 31 68 30 £4,000 £544 £60 £115 L18960
Fire 50E 670 440 440 540 329 290 51 91 30 £4,000 £727 £60 £115 L18961
* Lock and handle projection 35mm NB. If base fixing is ordered customer could be asked to sign a disclaimer at time of delivery
EN 14450
S2
EN 1300 EN 1300EN 15659
30 minutes
Model above is Fire 25E
our YouTube channel
to find out more

Key Features
• Helps prevent banknote theft at cash tills
• Mounted under the counter to securely store and protect banknotes
• Easy-to-reach deposit slot
• Stores up to 350 banknotes
• Two key locks – one to open storage unit and one to release from counter for easier emptying
• Solid sheet steel construction
Counter Unit
Burglary protection for banknotes
Model
External dimensions (mm)
Height Width Depth
Note
Capacity
(qty)
Weight
(kg)
Retail
Price
Delivery
Price
Aldridge
Product
Code
CU-350 235 105 190 350 2,4 £45 £21 L18856

Key Features
• Door is made of 6mm steel
• Body is made of 2mm steel
• 16mm diameter steel bolts operating in three directions secure the door
• Epsilon cabinets have a key deposit feature on the side of the safe which allows keys to
be securely deposited inside. Once inside, an anti-fishing plate prevents their removal
• Keys are stored on key hooks which, thanks to internal ladder racking, can be adjusted
to accommodate keys of different lengths
• A four point anchoring kit is supplied so the safe can be securely rear fixed to resist
unauthorised removal once installed
• Double bitted 8 lever key lock
Epsilon
Burglary protection for keys
Model
Height Width Depth
Internal dimensions (mm)
Height Width Depth
Volume
(litres)
Weight
(kg)
Key
Capacity
Retail
Price
Delivery
Price
Aldridge
Product
Code
Key Lock
Size 1 500 400 130 496 396 77 16 18 88 £216 £21 L21769
Size 2 500 400 180 496 396 127 25 23.5 128 £255 £21 L21770
Size 3 500 400 200 496 396 147 29 24 168 £272 £21 L21771
Size 4 500 400 250 496 396 197 39 27.5 208 £319 £21 L21772
NB. If rear fixing is ordered customer could be asked to sign a disclaimer at time of delivery
Model above is
Size 3

Key Features
• Multipurpose cabinet for the protection of cash and valuables (e.g. audio-visual equipment and mobile phones)
• Recommended cash rating of £2,000
• Single wall body constructed from 3mm steel plate. Doors secured by 3-way moving boltwork with a fixed dogging bar
• Secured by a double bitted high security key lock as standard
• Supplied with removable shelves as standard
• Cabinet must be fixed to the floor via the anchoring points in the base
• Available in four sizes
• Finished in a light grey colour
ForceGuard
£2,000 cash rating
Model
Number
of doors
Height Width Depth*
Height Width Depth
Volume
(litres)
Weight
(kg)
Locking
Fittings
(Supplied)
Shelf
Cash
Rating
Retail
Price
Delivery
Base Fixing
Price
Size 1 1 1000 600 450 975 575 400 236 80 Key Lock 3 £2,000 £750 £156
Size 2 2 1500 900 450 1475 875 400 534 140 Key Lock 4 £2,000 £1,245 £183
Size 3 2 1900 900 450 1875 875 400 680 225 Key Lock 4 £2,000 £1,508 £211
Size 4 2 1900 1220 450 1875 1195 400 920 275 Key Lock 4 £2,000 £1,812 £310
* Projection of handle is 50mm NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery
Model above is
Size 4
EN 1300

Key Features
• Suitable for the home and commercial environments
• Constructed with a 6mm steel door
• Double walled construction consisting of 3mm outer steel, 2mm steel inner body with an overall wall thickness
of 40mm. Cavity between the inner and outer body is filled in-between with a fire-retardant material
• Hardened steel plates protect the boltwork and lock against drilling
• 25mm diameter steel bolts secure the door
• Available with double bitted 8 lever key lock or Chubbsafes own programmable electronic lock
• Override key supplied with electronic version
• Fixing kit allows DIY base or rear fixing of safe
• Supplied with removable shelf as standard
AlphaPlus
£3,000 cash rating
Model above is Size 2
our YouTube channel
Model
Height Width Depth*
Height Width Depth
Volume
(litres)
Weight
(kg)
Fittings
(Supplied)
Shelf
Cash
Rating
Retail
Price
Drop off
Delivery
Price**
Delivery
Position
Price
Aldridge
Product
Code
Key Lock
Size 2 270 350 345 190 270 252 13 26 1 £3,000 £169 £21 £115 L21750
Size 3 320 440 395 240 360 302 26 40 1 £3,000 £224 £60 £115 L21752
Size 6 610 460 395 530 380 302 60 65 1 £3,000 £340 £60 £115 L21754
Electronic Lock
Size 2 270 350 345 190 270 252 13 26 1 £3,000 £203 £21 £115 L21751
Size 3 320 440 395 240 360 302 26 40 1 £3,000 £252 £60 £115 L21753
Size 6 610 460 395 530 380 302 60 65 1 £3,000 £382 £60 £115 L21755

Key Features
• A quality cash safe constructed using highly reliable materials
• Tested to European standard EN 14450, level S2
• Offers 30 minutes fire protection for documents. Tested in accordance to JIS S1037
• Manufactured in accordance with Quality Management System ISO 9001:2008
• Supplied with fittings (see table below)
• Available in five sizes
• Supplied as standard with a key lock and a mechanical combination lock
Cobra
£4,000 cash rating
Model above is
Size 2
Model
Height Width Depth*
Height Width Depth
Internal
Volume
(litres)
Weight
(kg)
Locking
Fittings
Shelf Drawer
Fire
Rating
(mins)
Cash
Rating
Retail
Price
Delivery
Base Fixing
Price
Size 1 400 500 475 270 370 320 32 185 Key KC N/A N/A 30 £4,000 £640 £179
Size 2 600 500 475 470 370 320 56 225 Key KC 1 N/A 30 £4,000 £765 £198
Size 3 750 500 475 620 370 320 73 265 Key KC 1 1 30 £4,000 £883 £216
Size 4 750 630 575 620 500 420 130 373 Key KC 1 1 30 £4,000 £1,143 £258
Size 5 980 630 575 850 500 420 179 467 Key KC 1 1 30 £4,000 £1,344 £288
Lock
Additional
Cut Key
All models £49
EN 14450
S2
JIS S1037
30 minutes

Key Features
• Cash safe for the home and commercial environments
• Tested and certified to European Standard EN 1143-1
• Secured by a double bitted key lock or user-friendly electronic lock. Both locks
comply to EN 1300
• Supplied with a shelf/shelves as standard – see table below
• Fixing kit allows DIY securing of safe to floor and/or wall
Zeta
£6,000 cash rating
Model
Height Width Depth
Height Width Depth
Volume
(litres)
Weight
(kg)
Fittings
(Supplied)
Shelf
Cash
Rating
Retail
Price
Drop off
Delivery
Price*
Delivery
Base Fixing
Price
Aldridge
Product
Code**
Key Lock
15K 280 370 350 190 280 250 13 40 1 £6,000 £424 £60 £115 L21756
25K 330 450 400 240 360 300 26 54 1 £6,000 £523 £60 £139 L21757
35 K 450 450 400 360 360 300 39 67 1 £6,000 £608 £60 £141 –
45 K 570 450 400 480 360 300 52 81 1 £6,000 £681 £60 £148 –
55 K 690 450 400 600 360 300 65 94 2 £6,000 £767 £60 £152 –
Electronic Lock
15E 280 370 350 190 280 250 13 40 1 £6,000 £598 £60 £115 L21758
25E 330 450 400 240 360 300 26 54 1 £6,000 £696 £60 £139 L21759
35 E 450 450 400 360 360 300 39 67 1 £6,000 £784 £60 £141 –
45 E 570 450 400 480 360 300 52 81 1 £6,000 £856 £60 £148 –
55 E 690 450 400 600 360 300 65 94 2 £6,000 £942 £60 £152 –
* Drop off delivery to a kerbside location NB. For base or rear fixing installations customer could be asked to sign a disclaimer at time of delivery
** Sizes 15 25 available through Aldridge Security
Model above is
45K
EN 1143-1
Grade 0
EN 1300EN 1300NEW
NOW AVAILABLE
IN 5 SIZES

Key Features
• Grade 1 burglary protection certified by ECB•S in accordance with EN 1143-1
• Certified by ECB•S for 30 mins fire-resistance (EN 15659, 30 P)
• Door can be easily removed for installations via stairs reducing the overall weight
by approximately 15%
• Fitted with either a Class A key lock or a Class B high-security electronic lock,
approved in accordance with European standard EN 1300
• Supplied with 1 x removable shelf as standard
• Electronic lock has 2 users and a time delay feature
• Model 45 will accept certain sizes of laptop safe
Deca
£10,000 cash rating
Model
Height Width Depth*
Height Width Depth
Internal
Volume
(litres)
Weight
(kg)
Fittings
(Supplied)
Shelf
Fire
Rating
(mins)
Cash
Rating
Retail
Price
Drop off
Delivery
Price**
Delivery
Base Fixing
Price
Key Lock
25K 340 500 345 262 424 216 24 93 1 30 £10,000 £543 £60 £136
45K 460 440 430 383 364 300 42 121 1 30 £10,000 £612 £60 £146
Electronic Lock
25E 340 500 345 262 424 216 24 93 1 30 £10,000 £712 £60 £136
45E 460 440 430 383 364 300 42 121 1 30 £10,000 £783 £60 £146
* Add 26mm for hinge projection and handle moulding NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery
Model above is
45E
EN 1143-1
Grade I
EN 1300 EN 1300EN 15659
30 minutes
NEW

Key Features
• Grade I burglary protection certified by ECB•S in accordance with the European standard, EN 1143-1
• Fitted with either a Class A key lock or a Class B high-security electronic lock, approved in accordance with
European standard EN 1300
• Safes equipped with an electronic lock also have an LED light inside
• Ergonomic, soft-touch handle
• Interior ladder racking system for flexible positioning of multiple shelves. One shelf is supplied as standard
• Thinner walls for increased internal capacity
Cobra Pro
£10,000 cash rating
Model
Height Width Depth*
Height Width Depth
Volume
(litres)
Weight
(kg)
Cash
Rating
Retail
Price
Drop off
Delivery
Price**
Delivery
Base Fixing
Price
Key Lock
Size 2K 650 500 510 570 420 370 88 214 £10,000 £898 £60 £190
Size 3K 800 600 550 720 520 410 153 294 £10,000 £1,028 £60 £207
Electronic Lock
Size 2E 650 500 510 570 420 370 88 214 £10,000 £1,139 £60 £190
Size 3E 800 600 550 720 520 410 153 294 £10,000 £1,272 £60 £207
* Handle projection 56mm NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery
EN 1143-1
Grade I
EN 1300 EN 1300
Fitting Shelf
Size 2 £23
Size 3 £31
Model above is Size 3K
our YouTube channel

Chubbsafes
EVOLVE
Combining a smart, sleek design with the highest European standard in
security: now that’s an innovative idea. Chubbsafes Evolve is the only
ergonomic safe with an automated opening and locking system to have
achieved EN 1143-1 certification on the market today. That means you
get a stylish, modern safe designed to enhance your personal comfort
that’s perfect for your home, small office or retail location... all with the
tried-and-tested security you expect from Chubbsafes.
BURGLARY
RESISTANT
AUTOMATED
OPENING
AND LOCKING
SYSTEM
TRIED-AND-TESTED
SECURITY
THE NEXT GENERATION OF SAFES
HAS ARRIVED.
SMART. SECURE. SLEEK.

Automated opening and locking
system with keypad lock placement
at the top of door.
Ergonomic, handle-free design
with chamfered edges.
Class B high-security
electronic lock, approved in
accordance with EN 1300.
Grade 1 burglary protection certified by the European
Certification Board of Security (ECB•S) in accordance
with the European standard, EN 1143-1.
Three sizes that favour height
over depth to adapt to a range of
different spaces.
Ideal for home, small office
or retail location.
Innovative storage options for
quick access to smaller items.
Plug-in version with battery-power
back-up system.
Technical information
Model
H W D
H W D
Volume
(litres)
Weight
(kg)
M100 690 600 500 590 500 328 100 151
M125 876 600 500 776 500 328 125 186
M185 1200 600 500 1100 500 328 185 247
Model
Fittings
(Supplied) Shelf*
Cash
Rating
Retail
Price
Delivery
Base Fixing Price
M100 1 £10,000 £2939 £190
M125 2 £10,000 £3093 £211
M185 2 £10,000 £3496 £238
* Pull out drawers and shelves available on request. POA
NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery

DuoGuard GI ProGuard GII, GIII
£10,000 to £35,000 cash rating (Grade I, II, II)
Model
Height Width Depth*
Height Width Depth
Internal
Volume
(litres)
Weight
(kg)
Fittings
(Supplied)
Shelf
Fire
Rating
(mins)
Cash
Rating
Retail Price Delivery
Base Fixing
PriceKey Lock Electronic
Grade I 40 435 500 456 335 400 295 40 90 1 60 £10,000 £973 £1,136 £190
60 530 500 521 430 400 360 62 115 1 60 £10,000 £1,153 £1,316 £211
110 690 600 561 590 500 386 114 161 2 60 £10,000 £1,353 £1,566 £226
150 875 600 561 775 500 386 150 196 2 60 £10,000 £1,482 £1,640 £238
200 1150 600 561 1050 500 386 203 243 2 60 £10,000 £1,704 £1,862 £276
300 1600 600 561 1500 500 386 290 322 3 60 £10,000 £2,206 £2,368 £318
350 1600 675 585 1500 575 410 354 352 3 60 £10,000 £2,434 £2,596 £354
450 1850 675 615 1750 575 440 443 415 4 60 £10,000 £2,769 £2,931 £354
Grade II 60 530 500 521 430 400 360 62 234 1 N/A £17,500 £1,393 £1,701 £207
110 690 600 561 590 500 386 114 334 2 N/A £17,500 £1,735 £1,972 £219
150 875 600 561 775 500 386 150 402 2 N/A £17,500 £2,025 £2,333 £243
200 1150 600 561 1050 500 386 203 501 2 N/A £17,500 £2,496 £2,803 £335
300 1600 600 561 1500 500 386 290 744 3 N/A £17,500 £2,771 £3,049 £407
350 1600 675 585 1500 575 410 354 846 3 N/A £17,500 £3,043 £3,321 £469
Grade III 110 690 600 561 600 510 396 121 315 2 N/A £35,000 £2,211 £2,544 £214
150 875 600 561 785 510 396 159 377 2 N/A £35,000 £2,487 £2,729 £248
200 1150 600 561 1060 510 396 214 486 2 N/A £35,000 £2,519 £2,805 £331
300 1600 600 561 1510 510 396 305 655 3 N/A £35,000 £3,205 £3,491 £394
350 1600 675 585 1510 585 420 371 703 3 N/A £35,000 £3,744 £3,990 £469
450 1850 675 616 1760 585 451 463 813 4 N/A £35,000 £4,186 £4,493 £508
TOP SELLER EN 1300 EN 1300
EN 1047-1
60 minutes
EN 1143-1
Grade I−III
Key Features
• Constructed using Chubbsafes revolutionary new lightweight barrier material
• Recommended cash rating of up to £35,000 (Grade III)
• Tested and certified by the ECB•S to European standard EN 1143-1
• Offers 60 minutes fire protection for documents (Grade l only). Tested and certified to European Standard EN 1047-1 Class S 60 P
• Supplied with a high security EN 1300 approved class A key lock or class B electronic lock
• Can be customised with locking options and fitting options (e.g. shelf, drawer)
• New modern design with a contemporary two tone satin finish
• Available in a comprehensive range of product sizes
Model above is
Model 200

Fitting Shelf Full width drawer Lockable cupboard
All Grades Size 40 £21 N/A N/A
Size 60 £23 N/A N/A
Size 110–300 £31 £241 £254
Size 350 £36 £274 £285
Size 450 £42 £314 £314
Model Capsules (per 10) Capsule Deposit Envelope Slot
All Grades Size 40 N/A N/A N/A
Size 60 N/A N/A N/A
Size 110–300 £24 £386 £453
Size 350 £24 £386 £453
Size 450 £24 £386 £453
Maximum deposit size:
1. Envelope Slot
25mm x 180mm (H x W)
Lock
Additional
Cut Key
Mechanical
Combination
Two
Key Locks
Key and
Combination
Two
Combinations
Electronic
Key and
Electronic
All Grades* All sizes £59 £141 £155 £237 £265 £333 £346
* Dual locking not available on Grade II size 60

Trident
From £60,000 to £150,000 cash protection, fire protection
and explosives protection (Grades IV, V, VI)
Key Features
• Recommended cash rating of up to £150,000 (Grade VI)
• Tested and certified to the highest industry standards for burglary, fire and explosives protection
• A series of EN 1300 certified key locks, combination locks and electronic locks are available to choose from
• Full access of contents at 90° door opening
• Available in right or left hinge versions
• Can be customised with locking options and fitting options (e.g. shelf, drawer)
• New modern design in a contemporary black finish
• Available in 8 sizes for each grade
Model above is
Model 600
EN 1300EN 1143-1
G
rade IV−VI E
X
EN 1143-1
Grade IV−VI
EN 1300
NT Fire 017
60 minutes
Model
Height Width Depth*
Height Width Depth
Internal
Volume
(litres)
Weight
(kg)
Locking
Fittings
(Supplied)
Shelf
Total depth
with door(s)
at 90° (mm)
Total width
with door(s)
at 180˚ (mm)
Fire
Rating
(mins)
Cash
Rating
Retail
Price
Delivery
Base Fixing
Price
Grade IV Size 110 790 730 560 620 560 320 111 560 Two Key Locks 2 1205 1420 60 £60,000 £3,697 £302
Size 170 920 730 640 750 560 400 168 695 Two Key Locks 2 1285 1420 60 £60,000 £4,010 £335
Size 910 1850 1250 740 1680 1080 500 907 2060 Two Key Locks 4 1385 2568 60 £60,000 £9,716 POA
Grade V Size 110 790 730 560 620 560 320 111 595 Two Key Locks 2 1205 1420 60 £100,000 £4,224 £302
Grade VI Size 110 790 730 560 620 560 320 111 635 Two Key Locks 2 1205 1420 60 £150,000 £6,990 £335
* Projection of handle is 63mm. Depth of hinge is not included in these measurements NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery
NEW
LARGER
SIZE

Fitting Shelf Reinforced Shelf Full Width Drawer
All Grades Size 110 £37 POA N/A
Size 170 £37 POA N/A
Size 210 £37 POA £308
Size 310 £37 POA £308
Size 420 £37 POA £308
Size 600 £49 POA £354
Size 910 N/A POA POA
Size 1120 N/A POA POA
Lock
Additional
Cut Key
Key and
Combination
Two
Combinations
Key and
Electronic
Grade IV V £59 £237 £265 £346
Grade VI £59 £237 £265 £710

Key Features
• Deposit cash safe allows individuals to securely deposit cash, cheques and vouchers
• Deposit slot (170mm x 16mm) fitted with an anti-fishing device to prevent unauthorised removal of deposited items
• Constructed with an 8mm steel door and 3mm steel body. Hardened steel plates protect boltwork and lock against drilling
• Available with double bitted key lock or electronic lock (sizes 2 3 only)
• Override key supplied with electronic version
• Fixing kit allows DIY base or rear fixing of safe
• Shelf supplied as standard
Sigma Deposit
£1,000 cash rating
Model
Height Width Depth*
Height Width Depth
Volume
(litres)
Weight
(kg)
Cash
Rating
Retail
Price
Delivery
Price
Aldridge
Product
Code
Key Lock
Size 1 305 375 350 299 369 289 32 27 £1,000 £168 £21 L21760
Size 2 375 375 350 369 369 289 39 33 £1,000 £190 £21 L21761
Size 3 475 375 350 469 369 289 50 38 £1,000 £227 £21 L21763
Electronic Lock
Size 2 375 375 350 369 369 289 39 33 £1,000 £222 £21 L21762
Size 3 475 375 350 469 369 289 50 38 £1,000 £271 £21 L21764
* Electronic lock projection is 40mm NB. If base or rear fixing is ordered customer could be asked to sign a disclaimer at time of delivery
Model above is Size 2E
our YouTube channel

Key Features
• A quality cash safe for the deposit of cash and valuables
• Door is made from 10mm steel and body is made of 6mm steel
• The door is secured by a three way moving bolt mechanism
• An anti-fishing device prevents unauthorised removal of deposited items
• Available with double bitted key lock or electronic lock
• Deposit opening measures 80mm x 265mm x 220mm (HxWxD)
• Shelf supplied with size 2
Omega Deposit
£3,000 cash rating
Model
Height Width Depth
Height Width Depth
Volume
(litres)
Weight
(kg)
Cash
Rating
Retail
Price
Drop off
Delivery
Price*
Delivery
Base Fixing
Price
Aldridge
Product
Code
Key Lock
Size 1 455 340 380 212 328 308 24 54 £3,000 £263 £60 £139 L21765
Size 2 698 340 380 455 328 308 48 75 £3,000 £370 £60 £153 L21766
Electronic Lock
Size 1 455 340 380 212 328 308 24 54 £3,000 £299 £60 £139 L21767
Size 2 698 340 380 455 328 308 48 75 £3,000 £433 £60 £153 L21768
* Drop off delivery to a kerbside location NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery
Model above is Size 1
our YouTube channel

Key Features
• High quality deposit safe constructed from modern high specification materials
• Recommended cash rating of up to £100,000 (Grade V) see table below
• Deposit feature allows multiple users to constantly deposit cash and valuables securely
whilst the main body of the safe remains locked
• Deposit drawer secured by double bitted key lock
• Can be customised with locking options
Sovereign Deposit
Up to £100,000 cash rating (Grade I, III V)
Model
Height Width Depth*
Height Width Depth
Internal
Volume
(litres)**
Weight
(kg)
Locking
Total depth
with door at
90° (mm)
Fittings
Supplied
Cash
Rating
Retail
Price
Delivery
Base Fixing
Price
Grade I Size 1 882 528 603 460 360 360 60 525 Key Lock 1076 Empty £10,000 £1,449 £207
Size 2 972 668 663 550 500 420 116 694 Key Lock 1276 Empty £10,000 £1,699 £225
Grade III Size 2 972 668 663 550 500 420 116 754 Key Lock 1276 Empty £35,000 £2,166 £469
Grade V Size 2 972 668 663 588 538 444 140 798 Two Key Locks 1276 Empty £100,000 £5,108 £469
Size 3 1272 668 663 888 538 444 212 1052 Two Key Locks 1276 Empty £100,000 £5,991 £529
* Projection of handle is 56mm Max Deposit size is 110 x 320 x 200mm (HxWxD)
** Internal volume does not include allowance for anti-fishing devices NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery
Lock
Additional
Cut Key
Mechanical
Combination
Two
Key Locks
Key and
Combination
Two
Combination
Electronic
Key and
Electronic
All Grades All sizes £59 £141 £155 £237 £265 £333 £346
Model Retaining Shelf Retaining Cupboard
All Grades All sizes £122 £388
Model shown is
Size 2
NEW
AVAILABLE
FROM MAY 2014

ProGuard DT GI GII
Up to £17,500 cash rating (Grade I, II)
Key Features
• Constructed using Chubbsafes lightweight barrier material
• Up to 30% lighter than the previous version. Leads to easier product handling during installations
• Recommended cash rating is £10,000 (Grade I) or £17,500 (Grade II)
• Tested and certified by the ECB•S to European Standard EN 1143-2 D in Grades DI II
• Deposit feature allows multiple users to constantly deposit cash and valuables securely whilst the
main body of the safe remains locked
• Deposit drawer equipped with an anti-fishing device to prevent anyone removing the contents of the
safe through the drawer
• Supplied with a high security EN 1300 approved class A key lock
• Available in four sizes in Grade I or II
Model
Height Width Depth*
Height Height* Width Depth
Internal
Volume
(litres)
Weight
(kg)
Locking
Fittings
Supplied
Cash
Rating
Retail
Price
Delivery
Base Fixing
Price
Grade I Size 60 687 500 521 587 314 400 360 45 144 Key Lock Empty £10,000 £2,004 £221
Size 110 847 600 561 747 474 500 386 91 203 Key Lock Empty £10,000 £2,262 £238
Grade II Size 60 687 500 521 587 314 400 360 45 329 Key Lock Empty £17,500 £2,273 £238
* Projection of handle is 65mm Maximum Deposit size for Size 60 is 30 x 330 x 220 (mm) Height* and litres* shown are usable heights and volumes below anti-fishing devices
Maximum Deposit size for Sizes 110, 150, 200 is 30 x 430 x 220 (mm) NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery
Lock
Additional
Cut Key
Mechanical
Combination
Two
Key Locks
Key and
Combination
Electronic
Two
Combinations
Key and
Electronic
All Grades* All sizes £59 £141 £155 £237 £333 £265 £346
* Dual locking not available on Grade ll size 60
EN 1300
EN 1143-2 D
Grade I−II
Model shown is
Size 150

Key Features
• Highly reliable document protection using modern materials and technology
• Tested and certified to NT Fire 017 – 60 Paper (25 model) or NT Fire 017 – 120 Paper (30 model)
• Fire resistance up to 120 minutes (30 models)
• Each drawer is protected from fire. Even if one of the drawers is accidently left open,
the other closed drawers are still protected by the built in fire resistant partitions
• Designed to accommodate foolscap or A4 filing
Profile NT
60 or 120 minutes document protection
Profile NT60
25 Fire File
External dimensions (mm
Height Width Depth
Internal dimensions (mm)*
Height Width Depth
Volume
(litres)
Weight
(kg)
Fire Rating
(mins)
Retail
Price
Delivery
Position
Price
Profile 1HR 2DR 734 544 638 291 387 481 108 120 60 £646 £136
Profile 1HR 4DR 1408 544 638 291 387 481 216 200 60 £1,094 £158
Profile NT120
30 Fire File
Height Width Depth
Internal dimensions (mm)*
Height Width Depth
Volume
(litres)
Weight
(kg)
Fire Rating
(mins)
Retail
Price
Delivery
Position
Price
Profile 2HR 2DR 734 544 776 291 387 619 139 172 120 £855 £136
Profile 2HR 3DR 1071 544 776 291 387 619 208 229 120 £1,134 £158
Profile 2HR 4DR 1408 544 776 291 387 619 278 287 120 £1,438 £177
* Each drawer’s internal dimensions
Model above is
Profile 4DR
NT Fire 017
60 minutes
NT Fire 017
120 minutes
FRE–FireResistantEquipment

Model shown is Size 325
Key Features
• Archive Cabinet has a steel, double-wall construction insulated with special fire-resistant barrier
material.
• Available in four sizes with a generous storage capacity ranging from 325–880 litres. Sizes 640
and 880 available as double door versions
• Secured by three-way boltwork, locking at the top, bottom and side of the door.
• Class A (EN 1300) key lock fitted as standard.
• Can be customised with a range of fittings (eg.lockable compartments, pull-out frames)
• Anchor points in the base allow the cabinet to be fixed to the floor.
• All cabinets have a light-grey, powder-coated finish, suitable for any office space.
Archive Cabinet
£1,000 recommended cash rating
Model
Height Width Depth*
Height Width Depth
Volume
(litres)
Weight
(kg)
Fittings
(Supplied)
Shelf
Cash
Rating
Retail
Price
Delivery
Position
Price
Size 325 1500 700 550 1290 594 430 325 95 3 £1,000 £744 £136
Size 450 1950 700 550 1780 594 430 450 120 4 £1,000 £867 £136
Size 640 1950 950 550 1780 844 430 640 150 4 £1,000 £1,154 £136
Size 880 1950 1260 550 1780 1154 430 880 200 4 £1,000 £1,352 £173
* Projection of handle is 50mm NB. If base fixing is ordered customer could be asked to sign a disclaimer at time of delivery
Fitting Shelf Pull-out Frame Lockable Compartment
Size 325 £52 £147 £252
Size 450 £52 £147 £252
Size 640 £68 £175 £320
Size 880 £85 £180 £421
EN 1300

Key Features
• Compact fire safe designed to protect valuable documents (eg. passports, receipts and
insurance documents)
• Tested and certified to UL72 Class 350 and NT Fire 017 – 60 Paper offering 60 minutes
fire protection
• Secured by either a key lock or user-friendly programmable electronic lock
• All sizes come with internal fittings as standard – see table below
• Anchoring points in base allow safe to be fixed to the floor
Executive
60 minutes document protection
Model shown is Size 40
our YouTube channel
Fittings Supplied Tray Shelf
Size 15 1 –
Size 25 1 –
Size 40 1 1
Size 65 – 2
NT Fire 017
60 minutes
U
L72 Class 35
0
1 hour
Model
Height Width Depth
Height Width Depth
Volume
(litres)
Weight
(kg)
Fire Rating
(mins)
Retail
Price
Drop off
Delivery
Price*
Delivery
Position
Price
Key Lock
Size 15 300 390 320 210 310 215 14 25 60 £150 £21 £115
Size 25 345 425 450 240 320 320 25 45 60 £182 £60 £115
Size 40 525 410 450 415 305 320 41 57 60 £241 £60 £115
Size 65 670 550 510 515 395 340 71 120 60 £557 £60 £115
Electronic Lock
Size 15 300 390 320 210 310 215 14 25 60 £203 £21 £115
Size 25 345 425 450 240 320 320 25 45 60 £235 £60 £115
Size 40 525 410 450 415 305 320 41 57 60 £293 £60 £115
Size 65 670 550 510 515 395 340 71 120 60 £599 £60 £115
* Drop off delivery to a kerbside location Dimensions exclude handle and hinge projections
NB. If base fixing is ordered customer could be asked to sign a disclaimer at time of delivery

Model shown is
550
Additional Fitting Shelf Pull-out File Frame
450 £65 £199
550 £54 £178
775 £65 £199
Key Features
• Certified to protect documents from fire for up to one hour (EN 15659 – 60 Paper)
• Tested and certified to European standard EN 14450, level S2
• EN 1300 Class A certified key lock fitted as standard
• Shelves fitted as standard see table below. Shelves are designed to accept hanging folders
suspended underneath
• Pull out filing frames and additional shelves available as an optional extra
• Available in 3 sizes with capacities ranging from 446 to 773 litres. All models have double doors
Model
Height1
Width Depth1
Height2
Width2
Depth
Internal
Volume
(litres)
Weight
(kg)
Fittings
(Supplied)
Shelf
Fire Rating
(mins)
Retail
Price
Delivery
Position
Price
Key Lock
450 1200 1250 585 1030 1110 390 446 440 2 60 £2,572 £177
550 1950 940 585 1760 800 390 550 460 4 60 £2,796 £191
775 1950 1250 585 1785 1110 390 773 650 4 60 £3,737 £225
NB. If base fixing is ordered customer could be asked to sign a disclaimer at time of delivery
EN 15659
60 minutes
EN 1300EN 14450
S2
NEW
Duplex
60 minutes document protection, up to £4,000 cash rating

Model shown is
Size 300
Key Features
• Fire-resistant safe designed to protect documents from fire and theft
• Ideal for offices and small businesses
• Tested and certified in accordance with NT Fire 017 – 120 Paper. Offering 120 minutes fire protection
• Secured by a user friendly programmable electronic lock
• Supplied with removable shelves as standard
• Available in seven sizes
Office
Model
Height Width Depth*
Height Width Depth
Volume
(litres)
Weight
(kg)
Fittings
(Supplied)
Shelf
Fire Rating
(mins)
Retail
Price
Delivery
Position
Price
Size 115 795 580 510 635 425 345 94 185 2 120 £672 £136
Size 125 995 585 510 830 425 345 123 200 3 120 £846 £158
Size 225 1175 645 635 1010 480 460 226 285 3 120 £1,174 £177
Size 300 1285 740 635 1120 575 460 301 340 3 120 £1,497 £191
Size 385 1600 740 635 1435 575 460 385 380 4 120 £1,570 £275
Size 450 1600 835 635 1435 670 460 447 410 4 120 £1,822 £295
Size 785 1695 1210 655 1535 1045 485 783 670 4 120 £2,762 £348
* Projection of handle is 40mm NB. If base fixing is ordered customer could be asked to sign a disclaimer at time of delivery
NT Fire 017
120 minutes

Model shown is
Size 24-2
EN 1300NT Fire 017
120 minutes
Key Features
• Quality document protection using high specification materials
• Tested to NT Fire 017 – 120 Paper
• Fire resistance of 120 minutes
• Can be customised by using fixed shelves, filing rails and lockable cupboards
Record Protection Cabinet
120 minutes document protection, up to £1,500 cash rating
Model
Height Width Depth*
Height Width Depth
Internal
Volume
(litres)
Weight
(kg)
Locking
Fittings
(Supplied)
Shelf
Fire Rating
(mins)
Retail
Price
Delivery
Position
Price
Size 12-2 859 759 549 700 600 382 160 235 Key Lock 1 120 £1,560 £158
Size 18-2 1209 759 549 1050 600 382 240 313 Key Lock 2 120 £1,922 £177
Size 24-2 1559 759 549 1400 600 382 321 391 Key Lock 3 120 £2,465 £191
Size 30-2 1909 759 549 1750 600 382 401 470 Key Lock 4 120 £2,736 £207
* Projection of handle is 65mm. Depth of hinge is not included in these measurements
Fitting Shelf Pull-out File Frame Lockable Cupboard
Size 12-2 £23 £100 £104
Size 18-2 £23 £100 £104
Size 24-2 £23 £100 £104
Size 30-2 £23 £100 £104

Model shown is
120
Additional Fitting Shelf Drawer
25 £34 £115
40 £34 £115
80 £35 £135
120 £45 £159
DataGuard NT
120 minutes data media protection
Key Features
• Certified NT Fire 017 – 120 Diskette for two-hour protection of data media from fire
• Single-door safe with no insert required – means internal capacity is maximised and up to
60% more storage space than other safes in the same class
• User-friendly, slam-action door, which when shut provides full fire protection without
needing to be locked
• Fittings supplied as standard – see table below for details
• Available in four sizes, ranging from 30–128 litres
• Secured by either a key lock or electronic lock
Model
Height1
Width Depth1
Height2
Width2
Depth
Internal
Volume
(litres)
Weight
(kg)
Fittings Fire Rating
(mins)
Retail
Price
Delivery
Position
PriceShelf Drawer
Key Lock
25 530 546 566 280 346 306 30 145 1 0 120 £804 £136
40 700 546 566 450 346 306 48 190 1 1 120 £971 £146
80 1025 546 590 775 346 330 89 263 1 2 120 £1,278 £158
120 1025 702 590 775 502 330 128 330 1 2 120 £1,521 £207
Electronic Lock
25 530 546 566 280 346 306 30 145 1 0 120 £869 £136
40 700 546 566 450 346 306 48 190 1 1 120 £1,036 £146
80 1025 546 590 775 346 330 89 263 1 2 120 £1,345 £158
120 1025 702 590 775 502 330 128 330 1 2 120 £1,586 £207
1
External heights and depths include plinth and handle projection NB. If base fixing is ordered customer could be asked to sign a disclaimer at time of delivery
2
Internal heights and widths are also equal to the clear opening measurements
NT Fire 017
120 minutes

DataPlus
£4,000 Cash rating, 120 minutes data media protection
Key Features
• Quality media protection using high specification materials
• Tested to highest international standards EN 1047-1, UL72 Class 125 and EN 14450 S2
• Fire resistance of 120 minutes
• Can be customised by using fixed shelves, pull out drawers and lockable cupboards
• Electronic and mechanical combination locks available
• Available in five sizes
Model
Height Width Depth*
Height Width Depth
Internal
Volume
(litres)
Weight
(kg)
Locking Cash Rating
Fire Rating
(mins)
Retail
Price
Delivery
Position
Price
Size 1 911 746 780 565 490 400 111 315 Key Lock £4,000 120 £3,378 £225
Size 2 1191 746 780 845 490 400 167 390 Key Lock £4,000 120 £3,842 £234
Size 3 1471 746 780 1125 490 400 221 490 Key Lock £4,000 120 £4,414 £248
Size 4 1941 746 780 1595 490 400 313 640 Key Lock £4,000 120 £5,457 £424
Size 5 1941 1036 830 1570 780 450 556 860 Key Lock £4,000 120 £6,966 £439
* Handle projection is 65mm NB. If base fixing is ordered customer could be asked to sign a disclaimer at time of delivery
Fitting Fixed shelf
Extensible shelf with
adjustable dividers
Lockable cupboard
Size 1 £36 £125 £216
Size 2 £36 £125 £216
Size 3 £36 £125 £216
Size 4 £36 £125 £216
Size 5 £57 £173 £249
EN 1047-1
120 minutes
U
L72 Class 12
5
2 hours
EN 14450
S2
Model above is
Size 1

Key Features
• Optimum protection for high value assets
• Consists of modular panels which are assembled together using a welded or bolted method of construction
• Tested and certified by the ECB•S to the latest security standard, EN 1143-1
• Can be integrated into various environments (for example new buildings, existing buildings and to strengthen strong room units)
• Can be designed on a bespoke basis, to suit any shape or size, subject to a full and comprehensive site survey
• Available in a range of security grades
Centurion Vault
Protection of high value assets
Grade
Wall thickness
(mm)
Weight
per m2
wall, floor, ceiling
(kg)
Max span (clearance)
for a permissible ceiling load of Retail
Price
Delivery
Installation
Price100 kp/m2
500 kp/m2
Euro V 85 300 3350 3350 POA POA
Euro VI 85 300 3350 3350 POA POA
Euro VII 85 300 3350 3350 POA POA
Euro V 100 360 4000 4000 POA POA
Euro VI 100 360 4000 4000 POA POA
Euro VII 100 360 4000 4000 POA POA
Euro VIII 100 360 4000 4000 POA POA
Euro IX 125 440 5250 4750 POA POA
Euro IX CD 125 440 5250 4750 POA POA
Euro X 150 520 5200 5000 POA POA
Euro X CD 150 520 5200 5000 POA POA
Euro XI 220 730 5060 5060 POA POA
Euro XI CD 220 730 5060 5060 POA POA
Euro XII 280 920 4960 4960 POA POA
Euro XII CD 280 920 4960 4960 POA POA
HighValueAssetProtection

Key Features
• Optimum protection for high value assets
• Consists of a door frame, grille gate and the main strong room door
• Tested and certified by the ECB•S to the latest security standard, EN 1143-1
• Supplied with one key lock and one mechanical combination lock (up to grade Euro XCD) as standard.
One key lock and two mechanical combination locks on Grades Xl and Xll
• Can be customised with locking and alarm options to meet your specific security needs
• Available in a range of security grades
Centurion Door
Grade Number of bolts
Total Weight
(kg)
Frame Depth
(mm)
Clear opening
H x W (mm)
Retail
Price
Delivery
Installation
Price
Euro V 6 1500 230 1970 x 900 POA POA
Euro VI 6 1500 230 1970 x 900 POA POA
Euro VII 6 1500 230 1970 x 900 POA POA
Euro VIII 6 1700 290 1970 x 900 POA POA
Euro IX 6 1700 290 1970 x 900 POA POA
Euro IX CD 6 1700 290 1970 x 900 POA POA
Euro X 6 3000 415 1970 x 900 POA POA
Euro X CD 6 3000 415 1970 x 900 POA POA
Euro XI 6 3000 415 1970 x 900 POA POA
Euro XI CD 6 3000 415 1970 x 900 POA POA
Euro XII 10 3500 415 1970 x 900 POA POA
Euro XII CD 10 3500 415 1970 x 900 POA POA

Key Features
• ModuleGuard security enclosures are certified Grade II–lll by ECB•S in accordance with the EN 1143-1
certification for burglary resistance
• ModuleGuard door can also be supplied with embrasure as single item to suit wall thickness less than 280mm
• The lightweight panels reduce transportation costs, ease installation and allow for placement higher up in
buildings where floor loads are limited
• Possible applications include reinforced protection for cash-counting rooms, archives and storerooms
• ModuleGuard has also been granted level CR4 according to the EN 1627-30 standard. It has also undergone
certified ballistics test and has been certified level FB4 in accordance with EN 1522
ModuleGuard
Lightweight security enclosure
Doors
Clear Opening
H x W (mm)
Weight
(kg)
Retail Price
Embrasure less
than 280mm
Delivery
Installation
Grade ll 2055 x 750 500 £7,546 £408 POA
Grade ll 2055 x 900 600 £8,000 £408 POA
Grade ll 2055 x 1050 700 £8,140 £544 POA
Grade ll 2055 x 1200 800 £8,233 £680 POA
Grade ll 2055 x 1350 900 £8,444 £815 POA
Grade ll 2055 x 1500 1000 £8,903 £952 POA
Grade lll 2055 x 750 500 £8,085 £408 POA
Grade lll 2055 x 900 600 £8,539 £408 POA
Grade lll 2055 x 1050 700 £8,679 £544 POA
Grade lll 2055 x 1200 800 £8,772 £680 POA
Grade lll 2055 x 1350 900 £8,983 £815 POA
Grade lll 2055 x 1500 1000 £9,442 £952 POA
Door supplied with single key lock as standard. Other locking options are available POA
Panels Width (mm) Thickness (mm)
Max Panel Length
(mm)
Weight (kg m2
) Retail Price
Delivery
Installation
Grade ll 300 75 2240 69 POA POA
Grade lll 300 75 2240 73 POA POA

Optional Extras Supply Price
Alarm Sensor £39
FB4 Bullet resistance to EN 1522 £115
FB6 Bullet resistance to EN 1522 POA
3 Point Self-locking POA
Door Closer POA
Panic Bar Internal Release POA
Extra Keys (ordered with door) £19
Glazed infill Full Height £200
Glazed infill Half Height £227
MagTek A4 RC4
Overall Dimensions (mm) HxW 2130 x 1150
Passage Dimensions (mm) HxW 2040 x 900
Retail Price £5,028
Delivery Installation Price POA
MagTek A
Aluminium manual attack resistant door
Key Features
• Elegantly designed to protect sensitive areas such as cash transit rooms, back office rooms and
security enclosures
• Fitted with a European profile cylinder key lock as standard, other lock options are available,
eg. biometric, push button. 3 x keys supplied as standard
• Single leaf door set with 3-point Euro Lock and handle on both secure and attack sides as standard.
Double leaf option also available
• Fixed aluminium frame with inclusion of special steel armour for fixing into finished masonry
opening
• Level 4 certification in accordance with XP ENV 1627-30. Other security levels available. Optional
ballistic protection available up to FB6 NS in accordance with EN 1522
• Door can be fitted as left or right opening for more convenience
• Available in indoor or outdoor versions
• Option of RAL 9010, 9006, 7035 or 7037 powder coated finish as standard on indoor version.
Other colours available on request
• Can be used in conjunction with CityWall to form a secure enclosure

...the premier underfloor safe brand
Churchill Safes are recognised as the leading brand for underfloor safes.
Such success is based upon understanding the security market and
meeting customer needs. This commitment and initiative is reflected in
the Churchill Safes product range. Products vary from a small wall safe
to high security underfloor safes. Such a comprehensive range means that
finding an underfloor solution is a simple process.

Key Features
• Wall safe designed to protect cash and valuables
• Construction includes a 10mm door 6mm outer frame
• Equipped with a double bitted key lock as standard
• Can be customised with combination or digital locking option
• Sizes 4 and 5 supplied with shelf
Magpie Wall Safe
£1,000 cash rating
Model
Door (mm)
Height Width
Height Width Depth*
Weight
(kg)
Locking
Fittings
(Supplied)
Shelf
Cash
Rating
Retail
Price
Delivery
Price
M2 127 178 140 229 121 9 Key Lock N/A £1,000 £182 £21
M3 210 178 229 229 121 12 Key Lock N/A £1,000 £224 £21
M4 293 178 306 229 165 18 Key Lock 1 £1,000 £291 £21
M5 369 240 381 305 165 27 Key Lock 1 £1,000 £341 £21
*Please add 30mm for dial projection
Model
Additional
Cut Key
Mechanical
Combination
Electronic
All models £32 £141 £181
Model shown is
M5
WallSafe
NEW

Key Features
• Traditional underfloor safe which protects cash and valuables
• Recommended cash rating of up to £4,000
• Easy upgrade option: can be upgraded to £6,000 (by using the Vector door)
• Construction includes a 30mm thick door coated in a unique and
environmentally friendly coating
• Secured by a double bitted key lock (VdS class 1) as standard
• Unique spring loaded escutcheon
• Can be customised with combination or electronic locking option
• Available in three models
• Deposit facility available – supplied with 12 capsules
• Supplied with full installation instructions
Domestic
£4,000 cash rating
Model
Additional
Cut Key
Mechanical
Combination
Electronic
All models £35 £141 £333
Model
Height* Width Depth
Height Width Depth
Safe Opening
(mm)
Weight
(kg)
Locking
Cash
Rating
Retail
Price
Delivery
Price
D2L 375 240 240 229 215 215 140 14.5 Key Lock £4,000 £295 £21
D3L 455 315 315 305 290 290 140 24.5 Key Lock £4,000 £328 £21
D4L Deposit 455 315 315 305 290 290 140 26.5 Key Lock £4,000 £421 £21
* External height includes a 125mm neck
Model above is
D3L
TOP SELLER VdS Class 1
UnderfloorSafes

UnderfloorSafes
Key Features
• Traditional underfloor safe which protects cash and valuables
• Construction includes a 45mm thick door coated in a unique and environmentally friendly coating
• Secured with a double bitted key lock (VdS class 1) as standard
• Available in three models
Vector
£6,000 cash rating
Model
Additional
Cut Key
Mechanical
Combination
Electronic
All models £35 £141 £333
Model
Height* Width Depth
Height Width Depth
Safe
Opening
(mm)
Weight
(kg)
Locking
Cash
Rating
Retail
Price
Delivery
Price
V2 375 240 240 229 215 215 140 16 Key Lock £6,000 £463 £21
V3 455 315 315 305 290 290 140 26 Key Lock £6,000 £496 £21
V4 Deposit 455 315 315 305 290 290 140 28 Key Lock £6,000 £544 £21
Model above is
V3
VdS Class 1

UnderfloorSafes
Key Features
• Large capacity square door underfloor safe which protects cash and valuables
• Supplied with an air pump assisted door for easy lift
• Available in two models
Bulldog 400
£6,000 cash rating
Model
Additional
Cut Key
Mechanical
Combination
Electronic
All models £35 £141 £333
Model
Door
(mm)
Height * Width Depth
Height Width Depth
Safe
Opening
(mm)
Weight
(kg)
Locking
Cash
Rating
Retail
Price
Delivery
Price
CBS11 356 x 255 425 490 350 255 458 330 240 x 300 45 Key Lock £6,000 £810 £60
CBS12 356 x 255 590 490 350 420 458 330 240 x 300 50 Key Lock £6,000 £871 £60
* External height includes 150mm neck
Model above is
CBS12
VdS Class 1

Key Features
• Easy upgrade options: can be upgraded to £17,500 recommended cash rating by using a Ruby door
• The door is constructed from stainless steel protecting the contents from thermal and mechanical attack
• All deposit versions include a lockable deposit cap
• Available in 2 models
• Supplied with reinforcing mesh and full installation instructions
Sapphire
Model above is
ES4 Deposit
Model
Additional
Cut Key
Mechanical
Combination
Electronic
All models £35 £141 £333
Model
Height* Width Depth
Height Width Depth
Safe
Opening
(mm)
Weight
(kg)
Locking
Cash
Rating
Retail
Price
Delivery
Price
ES3 470 300 300 300 290 290 140 27 Key Lock £10,000 £787 £21
ES4 Deposit 470 300 300 300 290 290 140 27 Key Lock £10,000 £959 £21
UnderfloorSafes
VdS Class 1

Key Features
• Underfloor safe which protects cash and valuables
• The door is constructed from stainless steel protecting the contents from
thermal and mechanical attack
Ruby
Model above is
ER14 Deposit
Model
Additional
Cut Key
Mechanical
Combination
Electronic
All models £35 £141 £333
Model
Height* Width Depth
Height Width Depth
Safe
Opening
(mm)
Weight
(kg)
Locking
Cash
Rating
Retail
Price
Delivery
Price
ER13 470 300 300 300 290 290 140 29 Key Lock £17,500 £1,349 £21
ER14 Deposit 470 300 300 300 290 290 140 29 Key Lock £17,500 £1,472 £21
UnderfloorSafes
VdS Class 1

Key Features
• Underfloor safe which protects cash and valuables
• The door is constructed from solid stainless steel 45mm thick
protecting the contents from thermal and mechanical attack
Emerald
Model
Height* Width Depth
Height Width Depth
Safe
Opening
(mm)
Weight
(kg)
Locking
Cash
Rating
Retail
Price
Delivery
Price
EE23 560 300 300 300 290 290 140 32 Key Lock £35,000 £1,469 £60
EE24 Deposit 560 300 300 300 290 290 140 32 Key Lock £35,000 £1,647 £60
Model
Additional
Cut Key
Electronic
All models £35 £333
UnderfloorSafes
Model above is
EE24D
TOP SELLER VdS Class 2

Notes
Notes

...the premier document protection brand
For every business protection of documentation is of paramount importance. Losing this
invaluable information can lead to a disastrous impact on the business.
Common outcomes include the loss of clients and a decline in capacity to attain new business.
With the Rosengrens product range you are sure to find a flexible and secure solution.
Combining unique design and innovative features, each safe or cabinet ensures that your
documents are securely protected to the highest standards.

Key Features
• Dual control locking mechanism.
• Each locker is secured by client lock 32A81S, second lock is custodian controlled.
32A81S lock can be supplied in brass or chrome finish.
• Can be upgraded to Gunnebo’s unique semi automated box access/
management system*. All columns are supplied pre-wired for this function as
standard.
• Fast and easy to install.
• Unique security design.
Inner containers
• Fibre inner container supplied as standard.
• Steel finish available as an optional extra.
Numbering
• Numbering as per customer’s requirements.
Total Security
• Safe deposit lockers can be integrated into a vault room which is secured by a
vault door for extra security.
• Manufactured in accordance with the ISO 9001 quality management system
and the ISO 14001 environmental management system.
Locker Groups
• Locker columns available in three heights as standard.
• Special column height dependent on locker quantity available on request.
• Numerous configurations to suit all customer requirements available, using
standard column heights and locker heights (50–650mm).
Finish
• Painted powder coat to RAL number of choice. Stainless steel finish available as
an optional extra.
2000C Safe Deposit Lockers
Suitable for Banks, Hotels and Independent Locker Rental Companies
*Safe Control Access/
Management System
Key Features
• Smoother locker rental and service
for customers. Features include
invoice generation, registration
and pricing.
• Real time information eg. locker
availability.
• Access management – options
include swipe card and pin number.
• Events history.
• Offsite management – using safe
control, guardian locks can be
deactivated remotely.
• Database of client information.

For further information please contact the
Gunnebo sales department on 01902 455111.
Standard Column Heights
Cassette sizeLocker Sizes Available
1720mm
2020mm
2220mm
1720
2020
2220
1720W
2020W
2220W
260mm
310mm
390mm
435mm
50
310 620
200
325
525/
650
75
100
125
175
300
475/
600
Horizontal view
FOLIO
320x230mm
For wide columns
multiply width x 2

Key Features
• Optimum solution for the protection of documents
• Tested and certified by the ECB•S to the European standard EN 1047-1 Class S 120 P
Offering 120 minutes fire protection for paper documents
• Secured by key lock as standard. Can be equipped with electronic or dual locking as an option
• Can be customised with a wide range of fittings (e.g. fixed shelf, lockable cupboard)
• Available in two sizes
Sargasso
Model
Height Width Depth*
Height Width Depth
Weight
(kg)
Volume
(litres)
Locking
No. of Lever
Arch Files**
Fittings
Supplied
Fire
Rating
(mins)
Retail
Price
Delivery
Position
Price
P120 1403 890 664 1203 733 434 458 383 Key Lock 30 Empty 120 £3,772 £225
P177 1970 1250 664 1770 1093 434 801 840 Key Lock 75 Empty 120 £5,956 £407
* Projection of handle is 50mm ** Lever Arch width 75mm
Fitting Fixed Shelf Extensible Shelf Extensible A4 File Frame Lockable Cupboard Data Insert
P120 £36 £109 £174 £301 £968
P177 £42 £146 £278 £570 £968
Lock Two Key Locks Combination Electronic
All sizes £155 £141 £333
Model above is
P177
EN 1047-1
120 minutes

Notes
Notes

Terms Conditions
Preamble
1. Our Terms Conditions shall apply in all instances.
Gunnebo reserves the right, at any time, to modify,
alter, or update the terms of use, product prices and
product information and you agree to be bound by such
modifications, alterations, or updates on subsequent
visits. Your placement of an order indicates your
acceptance of these terms and conditions.
Definitions
2. For the avoidance of doubt, the following expressions
shall (unless the context otherwise admits) have the
following meanings:
i. “Contract”shall mean the written agreement between
the two parties concerning performance of the
Works, encompassing the tender enquiry, subsequent
submission and agreement of any pricing considerations
made therein;
ii. “Contract Sum”shall mean the value of Gunnebo’s works,
based upon Gunnebo’s tender submission, subject to any
variances, to be ascertained and paid in accordance with
the provisions hereinafter;
iii. “Customer”shall mean the party to whom Gunnebo are
directly contracted; an end user Client, Main Contractor
or Sub-Contractor;
iv. “Gunnebo”shall mean Gunnebo UK Ltd or their
designated representatives;
v. “Works”shall mean the equipment and resources
necessary to enable the completion of the Contract;
vi. “Equipment”shall mean all materials pertinent to
the tender submission, subject to any variances, and
necessary plant, solely for our use, to facilitate the Works;
vii. “Delivery Period”shall mean the length of time required
to facilitate design and manufacture of equipment
necessary for the completion of the Works;
viii. “Site”shall mean the place where the Works are to take
place, including an allowance of space for any necessary
unloading, safe storage and consideration for efficient
transportation of equipment;
ix. “In Writing”shall mean communication by document
signed by the parties, or by letter, facsimile, and electronic
mail;
x. “Gross Negligence”shall mean an act or omission
implying a failure to pay due regard to serious
consequences, which a conscientious party would
normally foresee as likely to ensue.
Product Information
3. All information and data generated during the tender
process are binding only to the extent that they are by
reference expressly included in the Contract.
Intellectual Property
4. All drawings and technical information relating to the
Works shall remain the property of the submitting
party. Drawings and technical information received by
one party shall not, without the consent of the other
party, be used for any other purpose than that for which
they were provided. They may not, without the consent
of the submitting party, otherwise be used or copied,
reproduced, transmitted or communicated to a third
party.
5. Where, under a separate contract, it is a contractual
requirement of the Customer’s to provide their customer
with an Operational and Maintenance Manual, Gunnebo
reserve the right to charge for this service.
Quality Assurance
6. Should the need arise for either the Customer to inspect
equipment prior to dispatch, a request In Writing
would be necessary a minimum of 72 hours before any
proposed visit. Unless otherwise agreed, any inspection
would be at the place of manufacture, during normal
working hours. Any tests undertaken will be carried out
in accordance with general practice in the appropriate
branch of industry concerned in the country of
manufacture. All costs associated with an inspection visit
are to be borne solely by the Customer.
7. Records of Quality Inspections are maintained by
Gunnebo and can be provided, on receipt of a request In
Writing.
Preparatory Work
8. Gunnebo will provide information in good time, detailing
the manner in which equipment will be installed and
offer the Customer advice to aid their preparation
of suitable foundations, access requirements and
interfacing with others, where necessary.
9. The Customer shall recognise the limitations of
Gunnebo’s responsibilities and ensure that all preparatory
work outside of Gunnebo’s remit is completed in time for
the commencement of the Works.
10. Gunnebo will conform to the Customer’s site induction
procedures. Should this be required to take place prior to
commencement, Gunnebo reserve the right to charge for
this provision.
11. Gunnebo operatives will be provided with a project
specific method statement and risk assessments
pertinent to the environment that they will face.
12. The Customer shall provide welfare facilities free of
charge for the use of Gunnebo operatives, available from
the date of commencement and throughout the duration
of the Works.
13. The Delivery Period shall commence once Gunnebo are
in receipt of all pertinent information. The duration of
this period will be governed by capacity in production and
completeness of information received.
14. The date of commencement will be determined by the
duration of the Delivery Period. Should information
prove to be incomplete, Gunnebo shall identify the
remedial action required by the Customer. Gunnebo
may endeavour to furnish the Customer with
indicative timescales, but will not commit to a date
of commencement until all outstanding matters are
resolved.
15. Due to the manner with which Gunnebo commencement
is determined, Gunnebo shall not be held liable for any
conflict between the date of commencement and any
target of the Customer.
Impact on Commencement or Continuity
16. If the Customer anticipates that the fulfilment of their
obligations will delay the completion of the Works;
whether this manifests as a delay to commencement
or leads to Gunnebo’s progress being hampered; the
Customer shall notify Gunnebo In Writing, stating the
reason and, if possible, the time when they will be able
to comply with their obligations. The amount of time
permitted to Gunnebo for the completion of the Works
shall be automatically extended accordingly. Gunnebo
shall endeavour to provide timely advice as to the impact
upon duration and cost, and seek amendment of the
Contract Sum, where applicable.
17. Without prejudice to Gunnebo’s rights elsewhere in this
document, if the Customer fails to fulfil, correctly and
timely, his obligations necessary for completion of the
Works, the following remedies shall apply:
i. If the equipment has not been delivered to Site, Gunnebo
shall arrange for temporary storage at the Customer’s
risk and cost;
ii. The element of the Works completed shall be valued
accordingly and the Customer shall pay any part of the
Contract Sum which, but for such delay, would have
become due;
iii. Gunnebo may suspend in whole or in part his
performance of the Contract. Notice to the Customer
shall be raised forthwith In Writing;
iv. The Customer shall reimburse Gunnebo for any costs
which are reasonably incurred as a result of measures
undertaken to mitigate the situation.
18. Should the Customer’s inability to fulfil their obligations
not be attributable to Force Majeure, Gunnebo may, by
notice In Writing, require the Customer to remedy the
default within a determined and reasonable period.
If, for any reason, the Customer fails to remedy the
default within such period, Gunnebo may, by notice In
Writing, terminate its employment under the Contract.
Gunnebo shall then be entitled to compensation for the
losses incurred as a result of the Customer’s default. The
compensation shall not exceed the Contract Sum.
Variations
19. During the currency of the Contract and subject to
provisions elsewhere in this document, Gunnebo will act
upon requests In Writing from the Customer, to vary the
scope, design and construction of the Works.
20. To minimise impact upon the overall duration of the
Works, the Customer shall ensure that any request
contains an exact description of the variation required.
21. As soon as possible after receipt of a request for a
variation, Gunnebo shall notify the Customer In Writing
whether it is possible to conform with the request.
Should the request fall within Gunnebo‘s sphere of
expertise, then Gunnebo shall advise In Writing the value
of such work and the extent of the impact upon the
overall duration of the Works, assuming continuity can
be achieved. The amount of time permitted to Gunnebo
for the completion of the Works shall be automatically
extended accordingly, with the Contract Sum amended,
as applicable.
22. Gunnebo shall not be obliged to carry out variations
required by the Customer until either the parties have
agreed on how the variations will affect the Contract
Sum, the time for completion and other terms of the
Contract, or the dispute has been settled through
Adjudication or Arbitration.
23. If completion of the Works is delayed as a result of
disagreement between the parties on the consequences
of variations, the Customer shall pay any part of the
Contract Price which would have become due if the
Works had not been delayed.
Commissioning
24. Where specifically requested at the moment of enquiry,
commissioning tests shall be carried out to determine
whether the equipment is fit for purpose.
25. The Customer shall provide free of charge any power,
lubricants, water, fuel, raw materials and other materials
or equipment to enable such tests.
26. Any such tests shall be carried out during normal working
hours, conducted in accordance with general practice in
the appropriate branch of industry.
27. If the commissioning tests show the Works not to be
in accordance with the Contract, Gunnebo will within
a determined and reasonable period remedy any
deficiencies.
28. The Customer is not entitled to use the Works or any
part thereof before commissioning. If the Customer does
so without Gunnebo’s consent In Writing, he shall be
deemed to have taken over the Works. Gunnebo shall
then be relieved of their duty to carry out such tests.
Completion
29. The Works shall be considered complete when either
the commissioning has proved equipment to be fit
for purpose or the Client has begun making use of
equipment.
30. If Gunnebo anticipates that they will not be able to
comply with their obligations within the times specified
in the Contract, they shall forthwith notify the Customer
thereof In Writing, stating the reason, and, if possible,
when compliance can be expected. If Gunnebo fails
to give such notice, the Customer shall be entitled to
compensation for certain additional costs which will be
incurred and which could have been avoided had such
notice been received.
31. Should there be no reasonable entitlement to an
extension of time great enough to accommodate for
the eventual completion date of the Works; Gunnebo’s
delay entitles the Customer to liquidated and ascertained
damages from the date at which completion should have
occurred. Liquidated and ascertained damages shall not
exceed 1% of the Contract Sum per week and are capped
at a maximum of 10% of the Contract Sum, calculated
on a pro-rata basis against the Works. All other claims
for compensation against Gunnebo based on such delay
shall be excluded, except where Gunnebo has been guilty
of Gross Negligence.
32. The liquidated and ascertained damages become due
at the Customer’s request In Writing but not before
commissioning or termination of the Contract.
33. If Gunnebo’s delay is such that the Customer has become
entitled to the maximum level of damages and the Works
are still not completed, the Customer may demand In
Writing completion within a final reasonable period
which shall not in any event be less than one week. If
Gunnebo does not complete the Works within such final
period and this is not due to any circumstance for which
the Customer is responsible, then the Customer may
by notice In Writing to Gunnebo terminate Gunnebo’s
employment under the Contract.
34. It shall be a condition precedent to the Customer’s right
to liquidated and ascertained damages that he shall
lodge a claim In Writing for such damages within three
months after the time when completion should have
taken place.
35. Gunnebo shall be entitled to an extension of the time for
completion if delay occurs:
i. because of any of the circumstances covered under the
heading Force Majeure;
ii. as a result of variation to the Works;
iii. as a result of suspension of the Works;
iv. by an act or omission on the part of the Customer;
v. by an act or omission on the part of another trade
engaged on the same project.
36. The extension of time shall be reasonable having regard
to all the circumstances. This provision applies regardless
of whether the reason for the delay occurs before or after
the agreed time for completion.

Payment
37. Subject to a demonstrable level of credit worthiness, and
unless otherwise agreed, payment shall be made within
30 days from the date of the invoice.
38. Each invoice will identify the percentage of equipment on
site and installed in relation to the Contract Sum.
39. Should the installation be delayed due to a cause for
which the responsibility rests with the Customer or any
of their contractors other than Gunnebo, the Customer
shall compensate Gunnebo for:
i. waiting time and time spent on extra journeys;
ii. costs and extra work resulting from the delay, including
removing, securing and setting up the installation
equipment;
iii. additional costs, including costs as a result of Gunnebo
having to keep his plant on Site for a longer time than
expected;
iv. additional costs for journeys and board and lodging for
Gunnebo’s personnel;
v. additional financing costs and costs of insurance;
vi. other documented costs incurred by Gunnebo as a result
of changes in the installation programme.
40. Should the installation element be measured on a time
related basis, all pertinent expense incurred will be
incorporated into the Contract Sum.
41. If the Customer fails to pay by a stipulated date,
Gunnebo shall be entitled to interest from the day on
which payment was due. The rate of interest shall be 8%
above the Bank of England base rate at that time when
payment was due. In cases of late payment Gunnebo
may, after having notified the Customer In Writing,
suspend performance of the Contract until payment
is received. If the Customer has not paid the amount
due within three months, Gunnebo shall be entitled to
terminate its employment under Contract by notice In
Writing and to claim compensation for the loss.
Retention of Title and Transfer of Risk
42. The equipment shall remain the property of Gunnebo
until paid for in full.
43. Gunnebo shall be liable for any damage to the equipment
which occurs before the risk has passed to the Customer.
This applies irrespective of the cause of the damage,
unless the damage has been caused by the Customer or
anyone for whom he is responsible in connection with
performance of the Contract.
44. Gunnebo shall be liable for damage to the Customer’s
property occurring before commissioning of the Works
only if it is proved that such damage was caused by
negligence on the part of Gunnebo or anyone for whom
we are responsible in connection with the performance
of the Contract. Gunnebo shall, however, under no
circumstance be liable for loss of production, loss of profit
or any other consequential economic loss.
45. The risk of loss or damage to the equipment shall
pass to the Customer on handover or commissioning
of the Works, unless such loss or damage results from
Gunnebo’s negligence.
Product Liability
46. Gunnebo shall remedy any defect or non-conformity
in the Works resulting from faulty design, materials or
workmanship. However, we shall not be liable for loss
of production, loss of profit or any other consequential
economic loss.
47. Gunnebo’s liability is limited to defects in the Works
which appear within a period of one year from
commissioning. If the daily use of the equipment
exceeds that which is agreed, this period shall be reduced
proportionately. If commissioning has been delayed for
reasons for which the Customer is responsible, Gunnebo’s
liability for defects shall not be extended beyond 18
months after delivery.
48. The Customer shall without undue delay notify Gunnebo
In Writing of any defect which appears. Such notice shall
under no circumstance be given later than two weeks
after the expiry of the period stated previously. The notice
shall contain a description of the defect. If the Customer
fails to notify Gunnebo In Writing of a defect within the
set time limit, the right to have the defect remedied is
lost. Where the defect is such that it may cause damage,
the Customer shall immediately inform Gunnebo In
Writing. The Customer shall bear the risk of damage
resulting from his failure so to notify.
49. Should no defect be found for which Gunnebo is liable,
we shall be entitled to compensation for the costs
incurred as a result of acting upon the notice.
50. If, within a reasonable time, Gunnebo does not fulfil our
obligations, the Customer may, by notice In Writing, fix
a final time for completion of Gunnebo’s obligations. If
Gunnebo fails to fulfil his obligations within such final
time, the Customer may himself undertake or employ a
third party to undertake necessary remedial works at the
risk and expense of Gunnebo. Where successful remedial
works have been undertaken by the Customer or a third
party, reimbursement by Gunnebo of reasonable costs
incurred by the Customer shall be in full settlement of
Gunnebo’s liabilities for the said defect.
51. Where the defect has not been successfully remedied,
Gunnebo offer either of the following remedies:
i. The Customer is entitled to a reduction of the Contract
Sum in proportion to the reduced value of the Works,
provided that under no circumstance shall such reduction
exceed 10% of the revised Contract Sum, or;
ii. Where the defect is so substantial as to significantly
deprive the Customer of the benefit of the Contract,
the Customer may terminate Gunnebo’s employment
under the Contract by notice In Writing to Gunnebo. The
Customer is then entitled to compensation for the loss
he has suffered up to a maximum of 10% of the Contract
Sum.
Force Majeure
52. Either party shall be entitled to suspend performance of
their obligations under the Contract to the extent that
such performance is impeded or made unreasonably
onerous by any of the following circumstances beyond
the control of the parties:
industrial disputes, fire, war, extensive military
mobilisation, insurrection, requisition, seizure, embargo,
restrictions in the use of power.
53. A circumstance referred to in this clause, occurring
after the formation of the Contract, shall give a right to
suspension only if its effect on the performance of the
Contract could not be reasonably foreseen at the time of
the formation of the Contract.
54. The party claiming to be affected by Force Majeure shall
notify the other party In Writing without delay on the
occurrence of any Force Majeure and on the cessation
of such circumstance. If Force Majeure prevents the
Customer from fulfilling his obligations, they shall
compensate Gunnebo for expenses incurred in securing
and protecting the Works.
55. Regardless of what might otherwise follow from these
General Terms and Conditions, either party shall be
entitled to terminate the Contract by notice In Writing
to the other party if performance of the Contract is
suspended under Force Majeure for more than six
months.
Anticipated Non-Performance
56. Notwithstanding other provisions in these General
Terms and Conditions regarding suspension, each party
shall be entitled to suspend the performance of their
obligations under the Contract, where it is clear from
the circumstances that the other party will not be able
to perform his obligations. A party suspending their
performance of the Contract shall forthwith notify the
other party thereof In Writing.
Consequential Loss
57. Save as otherwise stated in these General Terms and
Conditions there shall be no liability for either party
towards the other party for loss of production, loss
of profit, loss of use, loss of contracts or for any other
consequential or indirect loss whatsoever.
Settlement of Disputes
58. In the event that an adjudicator has not been nominated
during the formulation of the Contract, any dispute or
difference arising under out of or in connection with
these General Terms Conditions may be referred to
adjudication at anytime to an adjudicator nominated by
the president or vice-president for the time being of the
Chartered Institute of Arbitrators and shall be conducted
in accordance with the Scheme for Construction
Contracts (England Wales) Regulation 1998 SI No
649 or any amendment or re-enactment thereof. The
Adjudicator’s decision shall be final and binding on
the parties until the dispute of difference is finally
determined either by agreement between the parties or
the courts.
Governing Law and Jurisdiction
59. These General Terms Conditions shall be governed by
and construed in all respects in accordance with the laws
of England and Wales, and the English Courts shall have
jurisdiction with regard to all matters arising from these
General Terms Conditions.
Severability
60. If any condition, clause or provision of these General
Terms Conditions is held to be illegal or unenforceable,
it may be severed and the validity or enforceability of the
remainder of these General Terms Conditions shall not
be affected thereby.
Third Party Rights
61. Notwithstanding any other provision of these General
Terms Conditions, nothing in these General Terms
Conditions confers or purports to confer any right to
enforce any of its terms on any person who is not a party
to it and the provisions of the Contracts (Rights of Third
Parties) Act 1999 shall be of no effect in respect of the
Agreement.
Construction Industry Scheme
62. Gunnebo shall provide the Customer with its unique
taxpayer reference number and company registration
number in sufficient time to allow the Customer to verify
Gunnebo’s payment status for the purposes of Chapter
3 of Part 3 of the Finance Act 2004 and the Income
Tax (Construction Industry Scheme) Regulations 2005.
Gunnebo warrants that at the date of this Contract it is
registered for gross payment under section 63(2) of the
Finance Act 2004 and that it shall remain registered for
gross payment until all payments under this Contract
have been made.
CDM Regulations
63. Gunnebo shall comply with the Health and Safety at
Work Act 1974, the Factories Act 1961, the Offices,
Shops, Railway Premises Act 1963, the Management of
Health and Safety at Work Regulations 1992 and The
Construction (Design and Management) Regulations
2007 (CDM) and amendments and regulations made
under or thereto.
Return Policy
64. We appreciate that there may well be a time when
a purchase may not prove to be of satisfaction and a
refund will be sought. Should a customer wish to return
a product from our standard safe range, the following
conditions shall apply:
• Gunnebo will only accept returns within seven (7) days
of delivery;
• Goods shall be returned to Gunnebo point of dispatch,
as identified on the proof of delivery notice and
invoice;
• A re-stocking charge, equal to 25% of the Contract
Sum will apply.
• Any postage and packing costs incurred on returned
items are non-refundable.
The returned product must be in a condition that can
only be described “as new”and securely packaged with
the original packaging or a suitable alternative of similar
quality;
Any and all manuals and accessories must be returned in
conjunction with the product.
With the above criteria having been satisfied, a refund
will be issued, minus our outgoing delivery cost.
Delivery Installation
65. Where ‘Delivery’is priced in this Selection Guide this
is drop off only and does not include base fixing or
positioning.
66. All products have a separate delivery and position or
delivery and base fixing price. This price includes delivery
to ground floor or upper floor (via a lift) with clear access.
Ground floor is defined as level with pavement and no
external steps. Delivery must occur during the working
day hours of 8.30am – 5.30pm. Delivery outside these
hours will incur an additional cost (POA). Gunnebo can
also remove and dispose of your old safe/cabinet after
delivering your new product (POA).
Delivery location
67. Delivery charges are for within mainland UK. However,
certain postcodes are considered geographic extremities
(Northern Ireland, Isle of Man, Channel Islands, Scottish
Islands, Scilly Islands).
Gunnebo can deliver to these locations and outside the
UK at an additional cost.
Prices
68. The full price of your product and delivery will be shown
on your order acknowledgement.

Gunnebo UK Ltd
Fairfax House
Pendeford Business Park
Wobaston Road
Wolverhampton
West Midlands
WV9 5HA
United Kingdom
Phone: +44 (0) 1902 455111
Fax: +44 (0) 1902 351961
marketing.uk@gunnebo.com
www.gunnebo.co.uk
FM 01305
EMS 577165
Gunneboreservestherighttomodify,alterorupdateproductinformationwithoutnotice.GUGB.uk.9107.R1

Selection Guide Price List 2014

More Related Content

Similar to Selection Guide Price List 2014

More from Gunnebo UK

Selection Guide Price List 2014