2. • Contract law is based on the Latin phrase
pacta sunt servanda i.e. ‘promises must be
kept’.
• History : During ancient times, Bartering, the
way by which contract was taking place.( (Grains
V/s Cattle) (Clothes V/s Fruits), Consideration- Return Promise)
• Todays time : we enter into contracts so
many times in a day that ‘contract’ has become
an indispensable part of our life. (Purchase of milk,
TV, electronics goods, house, services, telephone, internet, transport etc
3. CONTRACTS
• No individual or section of people can be fully
independent or self-reliant in a developed
society. One needs other’s help. To enforce
commitment in this mutual give and take, one
enters into written agreement with the other
party.
• Contract : Legally binding exchange of
promises or agreement between parties
enforceable by law.
4. INDIAN CONTRACT ACT
INDIAN CONTRACT ACT, 1872: Determines the
circumstances under which the promises made by
the contract shall be legally binding on them.
Offer + Acceptance = Agreement
Agreement + Enforceability at law = Contract
5. • ESSENTIALS ELEMENTS of CONTRACT
– Offer and its acceptance
– Free consent of both parties (not caused by coercion,
undue influence, fraud, misrepresentation or mistake)
– Mutual and lawful consideration for agreement
– It should be enforceable by law (hence, intention
should be to create legal relationship)
– Parties should be competent to contract
– Object should be lawful
– Certainty and possibility of performance
– Contract should not have been declared as void under
Contract Act or any other law
• Communication, acceptance and revocation of
proposals
6. • Void Contract (An agreement not enforceable by law is said to be void)
– Agreement by incompetent person ( power of attorney , Legal owner)
– Parties under mistake of fact ( Agreement to sale the goods on ship which has
already sunk)
– Unlawful object or consideration
– Agreement without consideration
– Agreement in restraint of marriage
– Agreement in restraint of trade
– Agreement in restraint of legal proceedings
– Uncertain agreement [Agreement to sell valves, oil etc.]
– Wagering agreement [ eg. Election which party will win ]
– Agreement to do an impossible Act [Frustration- renting of hall which
was burned subsequent to contract, death of party, change of law-
import goods banned)
• Consequences of Breach of Contract – Compensation / Penalty is payable
for breach of contract.
7. Remedies for breach of Contract
• Rescession of the contract ( Non supply of items, payment need not to be
done)
• Suit for damage (Compensation to injured party)
• Suit upon quantum merit ( as much as earned -as part supply or part
performance)
• Suit for specific performance ( Land , used vehicles)
• Suit for injunction (sale of property to another person X after agreeing to sell it to Y)
8. • CLASSIFICATION of CONTRACTS
– According to formation:
a) Express contracts
b) Implied contracts
c) Quasi contract
• TYPES OF CONTRACT
– Based on the scope of work required to be executed in CMM, NPCIL:
(a) SUPPLY CONTRACT
(b) ERECTION CONTRACT
(c) SERVICE CONTRACT
– Based on the method of execution :
(a) LUMP SUM CONTRACT
(b) ITEM RATE CONTRACT
(c) RATE CONTRACT [DGS & D- Only Rates & Period fixed but not qty. ]
(d) RUNNING CONTRACT [DGS & D- Apart from rates & period qty is also fixed]
(e) COST PLUS CONTRACTS
(f) TURN-KEY CONTRACTS
11. GENERAL CONDITIONS OF
CONTRACT
1. INTRODUCTION
2. SUBJECT MATTER OF CONTRACT
3. GUARANTEES AND LIABILITIES
4. CONTRACT EXECUTION
5. CHANGE IN CONTRACT ELEMENTS
13. SUBJECT MATTER OF CONTRACT
1. Scope of Facilities
2. Time for Completion
3. Contractor’s Responsibilities
4. Purchaser’s Responsibilities
5. Payment
6. Price Adjustment
7. Terms of Payment
8. Taxes & Duties
9. Securities
14. GUARANTEES & LIABILITIES
1. Completion Time Guarantee
2. Defect Liability
3. Functional Guarantees
4. Transfer of Ownership
5. Care of Facilities
6. Indemnity
7. Limitation of Liability
8. Insurance
9. Change in Laws & Regulations
10. Force Majeure
11. War Risks
15. CONTRACT EXECUTION
1. Representatives
2. Work Program
3. Subcontracting
4. Subletting & Assignment of Contract
5. Design & Engineering
6. Procurement
16. CONTRACT EXECUTION (…Contd.)
7. Installation
8. Insurance
9. Quality Assurance, Inspection, Acceptance
& Rejections
10. Completion of Erection and Pre-
Commissioning of The Facilities
11. Commissioning & Operational Acceptance
of Facilities
17. CHANGE IN CONTRACT ELEMENTS
1. Change in Facilities
2. Extension of time for completion
3. Foreclosure of Contract
4. Suspension of Site Works
5. Determination/ Cancellation/ Termination
of Contract in full or part
6. Settlement of Disputes
7. Secrecy
18. 1. PREAMBLE
1. The scope of the contract in brief.
2. The status of the General Conditions of
Contract in the contract.
3. The authority in NPCIL to exercise the
rights and discretions for and on behalf of
NPCIL.
19. 2. DEFINITIONS
The words and phrases may have different
meanings depending upon the context they are
used. Therefore, it is necessary to define
exclusive meaning of some important words and
phrases used in the contract.
Some of the important definitions are :
20. "Contract" or "Purchase Order" shall mean the
communication or document signed for and on behalf of
the Purchaser by an Officer duly authorised confirming
the acceptance of Tender or Offer of the contractor for
and on behalf of the Purchaser on the terms and
conditions mentioned or referred to in the said
communication and other documents including Tender
Document, Terms and Conditions of the contract and
such other documents as may be expressly incorporated
in the Contract by reference.
“Contractual Delivery Date” shall mean the stipulated
date on which the contractor shall attain ‘completion’ of
the Facilities, as specified in the purchase order.
21. “Contractual Mile Stone Date” shall mean the
stipulated date on which contractor complete
intermediate mile shall stone of despatch, erection,
testing etc. as specified in the Special Conditions of
Contract (SCC) / Purchase Order.
“Contract Price” shall mean the price as specified in
“Section A – Item and Price Schedule” of the Contract
subject to such addition and adjustment thereof or
deduction there from, as may be made pursuant to the
contract.
22. “Defect Liability Period” shall mean the period of
validity of the warranties given by the contractor
during which the contractor is responsible for
defects with respect to the facilities or the relevant
part thereof as provided in GCC clause 6.4 (Defect
Liability).
“Effective Date” or "Commencement Date" shall
mean the date of issue of Purchase Order on which
the contract shall come into force.
23. "Excepted Risks" are the risks due to war, hostilities
or warlike operations (whether a state of war be
declared or not), invasion, act of foreign enemy &
civil war, rebellion, revolution, insurrection, mutiny,
usurpation of civil or military government, civil
commotion, nuclear reaction, nuclear radiation,
radioactive contamination, or any other occurrences
that a contractor could not insure against, insofar as
such risks are not normally insurable on the
insurance market and are mentioned in the general
exclusions of the policy of insurance taken out under
the contract.
24. "Latent Defect" shall mean a defect, inherently
lying within the material or arising out of design
deficiency, which do not manifest themselves and/or
was not reasonably discoverable during Defect
Liability period.
25. 3. Interpretation
Priority of documents
Purchase contract issued by NPCIL comprises a
number of documents all forming part of the
contract. There may be overlapping areas addressed
in more than one document. For the purpose of
interpretation, the priority of documents are given in
the GCC in the following order :-
a)The contract agreement/Purchase Order
b)Special Conditions of Contract (SCC)
c)General Conditions of Contract (GCC)
d)Tender document excluding (b) & (c)
26. Purchaser’s Representative
For commercial matters :
Authorised Officer of C&MM –
SGM/GM/AGM/DGM
Nodal Agency for contract execution for all
technical matters :
Project Manager from Procurement/Indenting
Group.
All Site related activities :
Engineer-In-Charge as designated by
PD/CCE
27. Subject Matter of Contract
1.Scope of Facilities
General overall scope of EPC/Supply
Contract(s) are specified in the respective
GCC. For EPC Package, the scope is
defined right from design, engineering,
procurement, manufacture, shop testing,
quality assurance, transportation, unloading
and storage at site, all site work - erection,
commissioning, performance, testing and
handing over.
28. 1. Scope of Facilities (…contd.)
Unless specifically excluded in the contract,
the Contractor has to supply the materials
that may not have been specifically
mentioned in the tender/contract but that can
be reasonably inferred being required for the
Contractor to attain completion of his
obligation.
29. 2. Time for Completion
Time is the essence of the contract.
Failure to deliver in time is construed as
breach of contract.
A breach in contract entitles the party
suffering from such breach to claim damages
from the other party who has breached the
contract.
30. 2. Time for Completion(..contd)
In EPC Contract, in addition to overall
completion date, intermediate milestone
dates for supply/part installation can also be
specified in the contract. These milestone
dates are enforceable contractually and the
Contractor can be made to pay damages
(LD) for not adhering to these milestone
dates.
31. 2. Time for Completion(..contd)
However, in the event of overall completion
within the final CDD, damages recovered for
not adhering to intermediate milestone dates
are refundable to the Contractor.
32. Contract Price and Payment
Contract Price
1. For contract(s) with contractual delivery
period upto 12 months, the contract price
shall be firm.
2. For contract(s) with contractual delivery
period exceeding 12 months, the contract
price shall be subject to price adjustment
either in positive or in negative side.
33. Contract Price and Payment (…contd)
Price Basis
1. Price of supply items shall be on safe
delivery basis to site.
2. Basic price (except for civil works) shall
be exclusive of all taxes and duties.
3. For civil works, prices are inclusive of all
taxes and duties.
34. Contract Price and Payment (…contd)
Price Basis
4. For indigenous supply items break-up shall be
shown between Ex-works price and safe
delivery charges (i.e. inland transportation and
transit insurance).
5. For imported supply items break-up shall be
shown as FOB Price, ocean/air freight and
marine insurance, port handling/customs
clearance (excluding customs duty), inland
transportation and inland transit insurance.
6. Price of commissioning/start-up spares shall be
inclusive of basic price of the main equipment.
35. Contract Price and Payment (…contd)
Contract Currency
1. For contract awarded through global tendering,
foreign as well as Indian bidders can quote their
price in Indian rupees and/or in any other three
freely tradable foreign currencies, for supply
items and expatriate field labour/ Supervisor for
site work.
2. For other prices like transportation charges
(both import and indigenous), transit insurance,
port handling charges, erection &
commissioning etc. and civil works in Indian
rupees.
36. Contract Price and Payment (…contd)
Price Adjustment
Component of price eligible for price adjustment
1. Ex-works of price indigenous plant and
equipment including spares.
2. FOB price of imported plant and equipment
including spares.
For the above (1) & (2) Price Adjustment ceiling
of 20% of the total Ex-works/FOB price in
respective contract currencies shall apply.
3. Erection and commissioning price.
4. Civil works price.
37. Contract Price and Payment (…contd)
Component of price eligible for price adjustment
5. No price adjustment is allowed on spares,
tools, tackles and accessories. Engineering
charges, testing charges, analysis charges etc.
payable separately shall also not be eligible
for price adjustment.
38. PRICE ADJUSTMENT FORMULA
FOR SUPPLY PORTION
The price adjustment formula to be applied to the ex-
works/ FOB price- component of the supply items shall
be as follows:
EC ( F + a.Ml f1+ b.Nl f2 + c.Ol f3+ d.Pl f4+ e.Ql f5+ lb.Ll flb )
M0 N0 O0 P0 Q0 L0
f = Z0
Z1
Subscript ‘1’ refers to the indices/ exchange rates as on:
a)90 days prior to the date of dispatch for labour component, and
b)The expiry of 2/3rd period from the date of purchase order to the
date of dispatch, for material component.
39. PRICE ADJUSTMENT FORMULA
FOR ERECTION PORTION
Indian Currency portion of the Erection &
Commissioning Services
The formula for calculation of the monthly price
variation of the cost of erection portion of the
works is indicated and explained below:
E1 = E0 (0.25 + 0.75F1)
F0
41. 7. Terms of Payment
For supply –
(a) 10% advance on unconditional order
acceptance.
(b) 60% on pro-rata basis on despatch of items to
site.
(c) 20% on receipt of items at site.
(d) 7.5% on handing over of facilities to the
Purchaser.
(e) 2.5% on completion of material accounting.
Spares –
(a) 75% on despatch of items to site.
(b) 25% on receipt and acceptance of items at site.
42. 7. Terms of Payment (…contd)
For erection & commissioning –
(a) 10% on site mobilisation.
(b) 68% on pro-rata basis on
completion of milestones as per
approved billing schedule.
(c) 2% on compliance of industrial
safety requirement, along with (b)
above.
(d) 15% on handling over of facilities
to the Purchaser.
(e) 5% on completion of material
accounting.
43. 7. Terms of Payment (…contd)
For civil works –
(a) 10% on site mobilisation.
(b) 78% on pro-rata basis on completion of
milestones as per approved billing schedule.
(c) 2% on compliance of industrial safety
requirement, along with (b) above.
(d) 10% on handling over of facilities to the
Purchaser.
44. 7. Interest on Delayed Payment
Interest will be paid to the Contractor in the event of
delay in release of balance payment.
a)In case of supply order, delay beyond 95 days from
the date of receipt of goods at site.
b)In EPC contract, delay in release of payment
against MRICAR beyond 95 days from the date of
receipt of goods at site.
c)For final payment against handing over of
facilities, delay beyond 45 days from the date of
receipt of all supporting documents in acceptable
form.
45. 7. Interest of Delayed Payment(…Contd)
Rate of Interest Payable :
a) For Indian currency :
Prime Lending Rate (PLR) of State Bank
of India.
b) For Foreign currency :
London Inter Bank Offered Rate (LIBOR)
46. 8. Taxes & Duties
TO BE DEALT SEPARATELY IN DIFFERENT
MODULE
47. 9. Securities
1. Contract security for Performance Bond as well
as for advance/stage payments shall be only in
the form of Bank Guarantee
2. Bank Guarantee shall be from scheduled
commercial bank in India or from a branch of
Indian bank abroad.
3. Bank Guarantee shall be exactly as per the
format given in the GCC.
48. 9. Securities (…contd)
4. Performance Security Bond (PSB) Bank
Guarantee of 10% of total contract value
(supply plus erection) to be submitted within 30
days from the date of award of contract.
5. PSB BG validity till satisfactory completion of
defect liability period and further claim period
of 3 months. In case of EPC Contractor of
foreign origin assigning site work to another
entity, the entity for the site work shall submit
another PSB Bank Guarantee of 10% of the
value of the work assigned to him.
49. 9. Securities (…contd)
6. Performance Security Bond (PSB) Bank
Guarantee is extendable for extension in defect
liability period.
7. PSB can be released on successful completion
of defect liability period including extension, if
any.
50. 9. Securities (…contd)
Bank Guarantee for advance/stage payments :
1. Bank Guarantee of the full value of advance/stage
payments valid till contractual delivery date with a
further claim period of three months.
2. Bank Guarantee can be cancelled/reduced in value once
in 6 months to the extent of adjustment of the
advance/stage payment against bills paid.
3. Contractor has to extend the validity of both the Bank
Guarantees for delay in supply/completion.
4. In the event of delay being caused by reasons
attributable to Purchaser, Bank Guarantee extension
charges shall be borne by the Purchaser.
51. 9. Securities (…contd)
Latent Defect Bank Guarantee :
1. 1% of the total value of supply items to
be submitted at the end of defect liability
period valid for 5 years therefrom.
Indemnity Bond for Free Issue Material
(FIM) :
1. Indemnity Bond indemnifying Purchaser
against loss or damage of FIM issued for
fabrication at Contractor’s works outside
Purchaser’s site.
52. 1. Completion Time Guarantee
The Contractor is deemed to have given a guarantee
for completion of Contract which shall be attained
on or before contractual delivery date.
He is also deemed to have guaranteed that he shall
adhered to contractual milestone dates.
53. 2. Delay in Supply
Delay in Supply
Reasons for delay in supply can be classified into
the three heads :
1. Delay attributable to the Contractor.
2. Delay attributable to the Purchaser.
3. Delay due to occurrence of one or more Force
majeure events.
54. Delay in Supply(…contd)
Consequences of Delay
Where delay attributable to the Contractor
This provides option to the Purchaser :
1. Accept the delayed supply with recovery of
liquidated damages at specified rate applicable
for the Contractor.
2. To terminate the contract in full or parts and
exercise the rights to the Purchaser available in
GCC.
55. 3. Liquidated Damages
It is a predetermined compensation the Purchaser is
entitled to recover from the Contractor in the event
of delayed supply.
Rate of liquidated damages are 1%, 0.5% and
0.25% for contracts upto 1 year, beyond 1 year and
upto 2 years and beyond 2 years duration of
contracts respectively.
Only supply contract, liquidated damages to be
levied on the value of the delayed portion only.
56. Liquidated Damages (…contd)
For EPC Contract, liquidated damages to be levied
for the total contract value.
In addition, for EPC Contract, liquidated damages
to be also levied for failure by the Contractor on
certain specified milestone dates of supply and/or
erection activities.
In the event of such levy of liquidated damages on
mile stone rates, if the final date is achieved the
liquidated damages recovered on milestone to be
refunded.
57. 4. Defect Liability
The Contractor shall give warranty for plant, equipment and
facilities supplied by them till completion of defect liability
period.
Defect liability period for only supply contract is 18 months
from the receipt at site or 12 months from the acceptance,
whichever is earlier.
Defect liability for EPC packages, 18 months from the date
of completion of facilities (satisfactory erection and pre-
commissioning) or 12 months from the date of operational
acceptance of the facilities, whichever occurs first.
If the Contractor fails to make desired repairs/replacement
during the defect liability period, within 15 days of issue of
notice, the Purchaser can get repaired/replaced done from
alternative sources at the cost of the Contractor.
58. Extension of Defect Liability Period
a) If facilities supplied under a contract could not
be operated during defect liability period due to
defects, the defect liability period of the facility
shall be extended by period equivalent to such
non-availability period.
b) Defective parts of the facilities repaired in defect
liability period shall have an independent 12
months warranty from the date of completion of
such repair/replacement.
59. 5. Latent Defect Liability
From the end of defect liability period, the
Contractor will continue to be liable for
latent defects of the plant and equipment
supplied by him for another period of 5
years.
60. 6. Transfer of Ownership
Ownership of goods to pass from Contractor to the
Purchaser for :
a)For indigenous goods supplied from within the same State
as a site is located ownership of transfer when the goods are
brought to site.
b)Ownership of indigenous stores in interstate transaction
shall be transferred on sale in transit basis.
c)Ownership of imported stores, for direct order shall be
transferred on FOB basis.
d)Ownership of imported goods (through Indian Contractor)
shall be transferred on high sea sale basis.
e)In EPC Contract, transfer of ownership to the Purchaser
notwithstanding the Contractor shall continue to responsible
for successful handing over of the facilities to the
Purchaser.
61. 7. Care of the Facilities
From commencement of the work on the facilities
at site till successful handing over to the Purchaser,
the Contractor shall remain responsible for care and
custody of the facilities.
In the event of any loss and/or damage of the
facilities or the equipment, the Contractor at its own
expenses repair the affected items.
The Contractor shall also be responsible for loss or
damage to the facilities caused by him or his sub-
contractor in the course of work carried under his
defect liability obligation.
62. 7. Care of the Facilities(…Contd)
Above obligation notwithstanding, the Contractor
shall not be liable for any loss or damage to the
facilities at site for which he could not get any
insurance from the market to cover his risk.
There are only two risk which falls under this
category namely-War and Nuclear incident.
The Purchaser should bear these loss even before
handing over of the facilities.
The Contractor is also not liable for losses, loss of
use in design, data or specifications provided by the
Purchaser.
63. 8. Indemnity
The Contractor to provide the following Indemnity
to the Purchaser.
1)Intellectual Property Rights (IPR Identification)
2)Indemnity against physical loss or damage to the
facilities before handing over to the Purchaser.
3)Indemnity against latent defects for a period of 5
years starting from completion of defect liability
period.
4)Indemnity against non-compliance of statue.
5)Indemnity against damage of FIM.
6)Indemnity against third party life and property
loss claims arising out of nuclear events at site.
7)Indemnity against taxes and duties.
64. 9. Limitation of Liability
The Contractor shall not liable for any
indirect or consequential loss or damage, loss
of use, loss of production, loss of profit or
interest costs. The liability of the Contractor
to the Purchaser shall not exceed the total
contract price.
65. 10. Insurance
The Contractor to take at his own cost, the following
insurances for an EPC package contract.
a)Transit insurance as per ICC Clause A with war and
SRCC provisions.
b)Storage-Cum-Erection risk insurance policy.
Both the above insurance policies shall be taken at full
replacement value of the plant and machinery.
c) Insurance for contractor’s personnel.
d) Third party liability insurance.
e) Automobile liability insurance.
Insurance claim Proceeds shall come to the purchaser fisst
The Purchaser shall disburse the amount to the Contractor
for expenses incurred in respect of repair/re-installation of
the damage facilities.
66. 11. Force Majeure
Force majeure shall mean any event which is beyond the control
of the Contractor or the Purchaser, which substantially affects the
performance of the contract.Eg:
a) War, hostilities or warlike operations (whether a state of war be
declared or not), invasion, act of foreign enemy and civil war,
b) Rebellion, revolution, insurrection, mutiny, usurpation of civil
or military government, civil commotion,
c) Embargo, import restriction, confiscation, nationalization,
mobilization, commandeering or requisition by or under the order
of Central, State Government or Local Authority in India or any
other act or failure to act, of any local, state or national
government in India,
d) Riot, state/region/country wide transporters strike,
e) Earthquake, landslide, volcanic activity, fire, flood or
inundation, tidal wave, typhoon or cyclone, hurricane, storm,
lightning and pressure waves or other natural disaster,
f) Nuclear event causing nuclear radiation, radioactive
contamination.
67. 11. Consequences of Force Majeure
No delay or non-performance by either party
caused by any event of force majeure shall :
a)Constitute a default or breach of the contract can
b)Give rise to any claiming for damages or
additional expenses caused thereby.
c)The contract period shall get extended to cover
delay caused by force majeure without levy of
liquidated damages.
d)Any increase in taxes and duties is also payable in
the case of such extensions due to force majeure.
e)No price adjustment to be applied during such
extensions due to force majeure.
68. 12. Change in Facilities
Both Purchaser and the Contractor have the right to
propose a change in facilities during the
performance of the contract provided such change
falls in the general scope of facility and does not
constitute unrelated work.
No change made necessary because of any default
of the Contractor shall be deemed to be a change
and such change shall not result in any adjustment
of the contract price or time for completion.
69. 12. Change in Facilities(…Contd)
When a change is proposed either by the Purchaser
or the Contractor, the Contractor shall prepare a
‘Request for change proposal’ which shall include
among the others the following :
a)Description of the change.
b)Effect on the time for completion.
c)Cost of change
d)Effect on functional guarantees.
e)Effect on any other provisions of the contract.
70. 12. Change in Facilities(…Contd)
The Purchaser and the Contractor shall mutually agree upon
all related points of the change proposal. On such
agreement Purchaser shall intimate to the Contractor
whether or not to proceed with the change.
If the Purchaser and the Contractor can not reach agreement
on the price for the change and/or equitable time for
completion or any other matters related to such change
proposal, Purchaser may still instruct the Contractor to
proceed with the change.
The Contractor to proceed with the change as per such
instruction by the Purchaser. However, all issues need to be
settled within 90 days from the date of issue of instruction to
the Contractor to proceed with the change, failing which
matter can be referred to arbitration.
71. 13. Pricing the Change Proposal
For EPC contracts in which detailed engineering and BOQ
is given by the Purchaser any change in quantity will be
regulated as follows.
a)Items for which rates are available in the purchase order,
total additional quantity upto +25% of the original purchase
order value ordered within CDD will be paid at purchase
order rate plus price adjustment.
b)For additional quantity beyond +25% of the purchase
order value, any quantity ordered beyond CDD and for other
new items, will be paid at FOR site price + 15%.
c)Any deduction in purchase order quantity will be done at
purchase order rate.
72. 14. Time for Extension
Time for completion shall be extended if the Contractor is
delayed in the performance by reason of any of the
following :-
a) Any change in the facilities.
b) Any occurrence of force majeure.
c) Any suspension order given by the Purchaser.
d) Any delay in approval of drawing.
e) Any default of the contract by the Purchaser.
f) Delays attributable to the Purchaser.
g) Any delay in issuing Erection Completion Certificate.
73. 15. Time Overrun
In the event of delay in completion and
handing over of the facilities beyond CDD
by the Contractor due to specific site related
issues for which Purchaser is responsible, the
Contractor shall be entitled to compensate
for additional expenses for extended stay at
site to the extent required for such reasons in
addition to extension of time.
74. 16. Suspension of Work
Purchaser may order the Contractor suspend the
work by giving notice for the following reasons :
a) On account of any default of the Contractor.
b) For proper execution of the facilities or part
thereof.
c) For safety of the facilities or part thereof such
notice should clearly specify :
i)Which performance (work) to be suspended.
ii)Effective date of the suspension
iii)Reasons thereof.
75. 16. Suspension of Work(…Contd.)
The Contractor shall be entitled to an extension of
the time equal to the period of every such
suspension plus 25% based on above reasons.
If suspension period exceeds 30 days, the
Contractor shall also be entitled for compensation.
Contractor may demobilize resources if suspension
period exceeds 30 days.
However, the Contractor is not entitled for
extension/compensation, if any default of the
Contractor.
76. 17. Prolonged Suspension
If suspension order given by the Purchaser, other than the reason of the Contractor’s default or breach of the
contract and Contractor’s works get suspended for more than 90 days then the Contractor may give a notice to the Purchaser for resumption
of works (within 28 days of receipt of notice).
If the Purchaser fails to do so within such period, the Contractor may by a further notice to the purchase to
delete such part or whole of the facilities, as termination of the contract.
No claim for deletion portion of the work by the Contractor.
77. 18. Resumption of Work
Once permitted, the Contractor and the
Purchaser shall jointly examine the facilities,
plant and material affected by the
suspension.
78. 19. Foreclosure of Contract
After acceptance of the tender/during execution of
work, the Purchaser shall decide to abandon or
reduce the scope of work.
The Purchaser or Engineer-In-Charge shall give
notice to the Contractor for foreclosure of contract.
Upon receipt of the notice, the Contractor shall :
a)Cease all further work.
b)Terminate all sub-contract.
c)Stop all further purchasing and/or sub-
contracting.
d)Remove all Contractor’s equipment from the site.
79. 19. Foreclosure of Contract(…Contd)
In such cases, the Purchaser shall have the option to
take over Contractor’s material or any part thereof.
In the event of foreclosure of the contract under
GCC, the Purchaser shall pay to the Contractor.
The full amount of contract rates, properly
attributable to supplies completed and/or the part of
the facilities executed by the Contractor as of the
date of foreclosure.
80. 20. Termination of Contract in full or Part
The Purchaser without prejudice to any other right
may terminate the contract forthwith as a whole or
only such item of work in default, in the following
circumstances.
a)The Contractor shall offer or agree to give to any
person in the Purchaser’s service any gift or
consideration of any kind as an inducement.
b) The Contractor shall enter into contract with the
Purchaser in connection with which commission
has been paid or agreed to be paid.
c) The Contractor shall obtain a contract with the
Purchaser as a result of wrong tendering.
81. 20. Termination of Contract
in full or Part(…Contd)
d) Adopts or has engaged ‘fraudulent practice’.
e) Adopts or has engaged in ‘coercive practice’.
f) Being an individual or if a firm, any partner
thereof, shall at any time be adjudged insolvent.
g) Being a company, shall pass a resolution or the
court shall make an order for the liquidation of its
affair.
h) Shall suffer an execution being levied on his
goods.
i) Attempt to assign, transfer or sub-contract the
entire works or any portion thereof without the
prior written approval of the Purchaser.
82. 20. Termination of Contract
in full or Part(…Contd)
In the event of default by the Contractor, the
Purchaser may without prejudice to any other right,
give a notice to the Contractor in the following
circumstances : If the Contractor –
a) Has abandoned or repudiated the contract.
b) Has without valid reason failed to commence
work.
c) Persistently fail to execute the contract.
d) Refuse or is enable to provide sufficient material
services etc.
e) At any time makes default in proceeding with the
works with due diligence.
83. 20. Termination of Contract
in full or Part(…Contd)
f) Commits default in complying with any of the
terms and conditions of the contract.
g) Fail to deliver the stores.
h) Fail to complete the facilities and hand over it.
84. 21. Termination of Contract on Death
If the contractor is an individual or a
proprietary concern and the individual or the
proprietor dies or if the contractor is a
partnership concern and one of the partners
dies then unless the purchaser is satisfied that
the legal representative of the contractor are
capable, the purchaser shall be entitled to
cancel the contract as to its incomplete part
without the purchaser being in any way
liable to pay any compensation to the estate,
of the deceased contractor and/or surviving
partners.
85. 22. Settlement of Dispute
Settlement by mutual consultation
If any dispute arise between the purchase and the
contractor in connection with the contract regarding
its existence, validity or termination or execution at
the facilities, the parties shall seek to resolve any
such dispute or difference by mutual consultation.
In case parties fail to resolve such dispute or
difference by all such mutual consultations then the
either party may give a thirty(30) days notice to the
other party conveying its intention to commence
Arbitration.
86. 23. Settlement of Dispute (…Contd)
Settlement by Arbitration
Any dispute in respect of which notice of intention
to commence Arbitration has been given, shall be
finally settled by arbitration.
Consequent to issue of notice of intention to
commence Arbitration by either party, both the
purchase and the contractor shall appoint one
Arbitrator each. These two Arbitrators shall agree
between themselves and shall appoint third
Arbitrator. The issue in dispute shall then be
referred to these Arbitrators. The decision either by
consensus or by majority of these three Arbitrators
shall be final and binding on both the parties.
87. 23. Settlement of Dispute (…Contd)
Settlement by Arbitration(…Contd)
For contract awarded to a foreign contractor or to a
consortium in which the Foreign contractor is the
lead partner, Rules of Conciliation and Arbitration
of the International Chamber at Commerce shall
apply to Arbitration proceedings.
For contract awarded to public sector enterprise, all
matters in dispute to be settled through arbitration
shall be referred to the permanent Arbitration
mechanism (PAM) of the Dept. of Public
Enterprise, Govt. of India.